Public companies are required to disclose risks that can affect the business and impact the stock. These disclosures are known as “Risk Factors”. Companies disclose these risks in their yearly (Form 10-K), quarterly earnings (Form 10-Q), or “foreign private issuer” reports (Form 20-F). Risk factors show the challenges a company faces. Investors can consider the worst-case scenarios before making an investment. TipRanks’ Risk Analysis categorizes risks based on proprietary classification algorithms and machine learning.
Nam Tai Property disclosed 47 risk factors in its most recent earnings report. Nam Tai Property reported the most risks in the “Finance & Corporate” category.
Risk Overview Q4, 2017
Risk Distribution
43% Finance & Corporate
28% Legal & Regulatory
15% Production
6% Ability to Sell
6% Macro & Political
2% Tech & Innovation
Finance & Corporate - Financial and accounting risks. Risks related to the execution of corporate activity and strategy
This chart displays the stock's most recent risk distribution according to category. TipRanks has identified 6 major categories: Finance & corporate, legal & regulatory, macro & political, production, tech & innovation, and ability to sell.
Risk Change Over Time
S&P500 Average
Sector Average
Risks removed
Risks added
Risks changed
Nam Tai Property Risk Factors
New Risk (0)
Risk Changed (0)
Risk Removed (0)
No changes from previous report
The chart shows the number of risks a company has disclosed. You can compare this to the sector average or S&P 500 average.
The quarters shown in the chart are according to the calendar year (January to December). Businesses set their own financial calendar, known as a fiscal year. For example, Walmart ends their financial year at the end of January to accommodate the holiday season.
Risk Highlights Q4, 2017
Main Risk Category
Finance & Corporate
With 20 Risks
Finance & Corporate
With 20 Risks
Number of Disclosed Risks
47
+18
From last report
S&P 500 Average: 31
47
+18
From last report
S&P 500 Average: 31
Recent Changes
19Risks added
1Risks removed
9Risks changed
Since Dec 2017
19Risks added
1Risks removed
9Risks changed
Since Dec 2017
Number of Risk Changed
9
+9
From last report
S&P 500 Average: 1
9
+9
From last report
S&P 500 Average: 1
See the risk highlights of Nam Tai Property in the last period.
Risk Word Cloud
The most common phrases about risk factors from the most recent report. Larger texts indicate more widely used phrases.
Risk Factors Full Breakdown - Total Risks 47
Finance & Corporate
Total Risks: 20/47 (43%)Below Sector Average
Share Price & Shareholder Rights5 | 10.6%
Share Price & Shareholder Rights - Risk 1
Added
The interests of our largest shareholder may differ from the interests of other shareholders.
Based on the Schedule 13D/A filed with the SEC on December 15, 2017, Kaisa Group Holdings Ltd. ("Kaisa") beneficially owned approximately 24.5% of our outstanding shares as of December 14, 2017. An affiliate of Kaisa, Mr. Ying Chi Kwok, also serves as our chief executive officer and executive director. Our company is mindful of protecting the interest of minority shareholders. Our corporate governance procedures, including the election of a board that comprises of majority independent directors, is set up to safeguard the interests of all shareholders, particularly our minority shareholders, and not to favor any significant shareholder. However, under most circumstances, we cannot prevent companies that are controlled by Kaisa or its affiliates from engaging in activities that may compete directly with the development of our Nam Tai Inno Park and Nam Tai Inno City projects or other activities that may have an adverse effect on our business. Further, as shareholders, they could also influence the outcome of any corporate transaction or other matters submitted to our shareholders for approval, including the election of directors, mergers and acquisitions, and other significant corporate actions, to the extent they are not required to abstain from voting in respect of such transactions. The interests of Kaisa and its affiliates may differ significantly from, or compete with, our interests or the interests of our other shareholders, and we cannot assure you that Kaisa and its affiliates would always exercise influence over us in a manner that is consistent with the interests of our other shareholders
Share Price & Shareholder Rights - Risk 2
Changed
Our directors, senior management and principal shareholders own a large portion of our common stock allowing them to control or substantially influence the outcome of matters requiring shareholder approval.
On January 31, 2018, members of our senior management, our Board of Directors and principal shareholders including Kaisa as a group beneficially owned approximately 44.0% of our common shares. As a result, acting together, they may be able to control and substantially influence the outcome of all matters requiring approval by our shareholders, including the election of directors and approval of significant corporate transactions. This ability may have the effect of delaying or preventing a change in control of Nam Tai, or causing a change in control of Nam Tai that may not be favored by our other shareholders.
Share Price & Shareholder Rights - Risk 3
The market price of our shares will likely be subject to substantial price and volume fluctuations.
The markets for equity securities have been volatile and the price of our common shares has been and could continue to be subject to wide fluctuations in response to variations in our operating results, news announcements, trading volume, sales of common shares by our officers, directors and our principal shareholders, customers, suppliers or other publicly traded companies, general market trends both domestically and internationally, currency movements and interest rate fluctuations. Other events, such as the issuance of common shares upon the exercise of our outstanding stock options could also materially and adversely affect the prevailing market price of our common shares.
Further, the stock markets have often experienced extreme price and volume fluctuations that have affected the market prices of the equity securities of many companies and that have been unrelated or disproportionate to the operating performance of such companies. These fluctuations may materially and adversely affect the market price of our common shares.
Share Price & Shareholder Rights - Risk 4
Future issuances of preference shares could materially and adversely affect the holders of our common shares or delay or prevent a change of control.
Our Board of Directors may amend our Memorandum and Articles of Association without shareholder approval to create from time to time, and issue, one or more classes of preference shares (which are analogous to preferred stock of corporations organized in the United States). While we have never issued any preference shares and we have none outstanding, we could issue preference shares in the future. Future issuance of preference shares could materially and adversely affect the rights of the holders of our common shares, or delay or prevent a change of control.
Share Price & Shareholder Rights - Risk 5
Our status as a foreign private issuer in the United States exempts us from certain of the reporting requirements under the Securities Exchange Act of 1934, and corporate governance standards of the New York Stock Exchange, or NYSE limiting the protections and information afforded to investors.
We are a foreign private issuer with the meaning of the rules under the Securities Exchange Act of 1934, as such we are exempt from certain provisions applicable to a U.S. domestic public company, including:
- the rules under the Securities Exchange Act of 1934 requiring the filing with the SEC of quarterly reports on Form 10-Q, current reports on Form 8-K or annual reports on Form 10-K;- the section of the Securities Exchange Act of 1934 regulating the solicitation of proxies, consents or authorizations respect of a security registered under the Exchange Act;- the section of the Securities Exchange Act of 1934 requiring directors, officers and 10% holders to file public reporting of their stock ownership and trading activities and imposing liability on insiders who profit from trades made in a short period of time;- the selective disclosure rules under Regulation FD restricting issuers from selectively disclosing material nonpublic information; and - the sections of the Securities Exchange Act of 1934 requiring insiders to file public reports of their stock ownership and trading activities and establishing insider liability for profits realized from any "short-swing" trading transaction (i.e. a purchase and sale, or sale and purchase, of the issuer's equity securities within less than six months).
In addition, because the Company is a foreign private issuer, certain corporate governance standards of the NYSE that apply to domestic companies listed on that exchange may not be applicable to us. For information regarding whether our corporate governance standards differ from those applied to U.S. domestic issuers, see the discussion under "NYSE listed Company Manual Disclosure" in ITEM 6. Directors and Senior Management of this Report.
Because of these exemptions, investors are not afforded the same protections or information generally available to investors holding shares in public companies organized in the United States or traded on the NYSE. See reference "*" on page 52 of this Report under the heading "Compensation on an Individual Basis" for information and risks associated with disclosures we have made in this Report or may make in our proxy statements regarding compensation we have paid to our directors and senior management on an individual basis.
Accounting & Financial Operations10 | 21.3%
Accounting & Financial Operations - Risk 1
Due to inherent limitations, there can be no assurance that our system of disclosure and internal controls and procedures will be successful in preventing all errors or fraud, or in informing management of all material information in a timely manner.
Our management, including the Chief Executive Officer and the Chief Financial Officer, does not expect that our disclosure controls and internal controls and procedures will prevent all errors and all fraud. A control system, no matter how well conceived and operated, can provide only reasonable, not absolute, assurance that the objectives of the control system are met. Further, the design of a control system reflects that there are resource constraints, and the benefits of controls must be considered relative to their costs. Because of the inherent limitations in all control systems, no evaluation of controls can provide absolute assurance that all control issues and instances of fraud, if any, within the Company have been or will be detected. These inherent limitations include the realities that judgments in decision-making can be faulty and that breakdowns can occur simply because of error or mistake. Additionally, controls can be circumvented by the individual acts of some persons, by collusion of two or more people, or by management override of the control.
The design of any system of controls is also based in part upon certain assumptions about the likelihood of future events. There can be no assurance that any design will succeed in achieving its stated goals under all potential future conditions. Over time, a control may become inadequate because of changes in conditions, or the degree of compliance with the policies or procedures may deteriorate.
Because of the inherent limitations in a cost-effective control system, misstatements due to error or fraud may occur or may not be detected.
Accounting & Financial Operations - Risk 2
There are inherent uncertainties involved in estimates, judgments and assumptions used in the preparation of financial statements in accordance with U.S. GAAP. Any changes in estimates, judgments and assumptions could have a material adverse effect on our business, financial position and results of operations.
The consolidated financial statements included in the periodic reports we file with the SEC are prepared in accordance with U.S. GAAP. The preparation of financial statements in accordance with U.S. GAAP involves making estimates, judgments and assumptions that affect reported amounts of assets (including intangible assets), liabilities and related reserves, revenues, expenses and income. Estimates, judgments and assumptions are inherently subject to changes in the future, and any such changes could result in corresponding changes to the amounts of assets, liabilities, revenues, expenses and income. Any such changes could have a material adverse effect on our financial position and results of operation.
Accounting & Financial Operations - Risk 3
Payment of dividends by our subsidiaries in the PRC to our subsidiaries outside of the PRC and to us, as the ultimate parent, is subject to restrictions under PRC law. If we determine to continue our payment of dividends to our shareholders, the PRC tax law could force us to reduce the amount of dividends we have historically paid to our shareholders or possibly eliminate our ability to pay any dividends at all.
Under PRC law, dividends may only be paid out of distributable profits. Distributable profits with respect to our subsidiaries in the PRC refers to after-tax profits as determined in accordance with accounting principles and financial regulations applicable to PRC enterprises ("PRC GAAP") less any recovery of accumulated losses and allocations to statutory funds that we are required to make. Any distributable profits that are not distributed in a given year are retained and available for distribution in subsequent years. The calculation of distributable profits under PRC GAAP differs in many respects from the calculation under U.S. GAAP. As a result, our subsidiaries in the PRC may not be able to pay a dividend in a given year as determined under U.S. GAAP. China's tax authorities may also change the determination of income which would limit our PRC subsidiaries' ability to pay dividends and make other distributions.
Prior to the EIT law, which became effective on January 1, 2008, PRC-organized companies were exempt from withholding taxes with respect to earnings distributions, or dividends, paid to shareholders of PRC companies outside the PRC. However, under the EIT, dividends payable to foreign investors which are derived from sources within the PRC are subject to income tax at the rate of 5% to 15% by way of withholding unless the foreign investors are companies incorporated in countries which have tax treaty agreements with the PRC and then the rate agreed by both parties will be applied. For example, under the terms of the tax treaty between Hong Kong and the PRC, which became effective in December 2006, distributions from our PRC subsidiaries to our Hong Kong subsidiary, will be subject to a withholding tax at a rate ranging from 5% to 10%, depending on the extent of ownership of equity interests held by our Hong Kong subsidiary in our PRC enterprises. As a result of this PRC withholding tax, amounts available to us in earnings distributions from our PRC enterprises will be reduced. Since we derive most of our profits from our subsidiaries in the PRC, the reduction in amounts available for distribution from our PRC enterprises could, depending on the income generated by our PRC subsidiaries, force us to reduce, or possibly eliminate, the dividends we have paid to our shareholders historically. For this reason, or other factors, we may decide not to declare dividends in the future. If we do pay dividends, we will determine the amounts when they are declared and even if we do declare dividends in the future, we may not continue them in any future period.
Accounting & Financial Operations - Risk 4
Changed
We may be required to write down our long-lived assets, which could result in a significant impairment charge that would adversely affect our operating results.
As of December 31, 2017, we had $89.4 million in long-lived assets on our balance sheet. In 2017, we also wrote down the demolished buildings on the site of Nam Tai Inno City – Phase I by $4.6 million. The valuation of our long-lived assets requires us to make assumptions about future interest income. Our assumptions are used to forecast future undiscounted cash flows. Given the current economic environment, uncertainties regarding the duration and severity of these conditions, forecasting future business is difficult and subject to modification. If actual market conditions differ or our forecasts change, we may be required to reassess long-lived assets and we may have to record an impairment charge. Any impairment charge relating to long-lived assets would have the effect of decreasing our earnings or increasing our losses in such period. If we are required to take a substantial impairment charge, our operating results could be materially adversely affected in the periods and year in which the charge is incurred.
Accounting & Financial Operations - Risk 5
Changed
We might not regain profitability for several years, if ever.
We are owner and developer of research and development parks. In April 2014, we ceased our core liquid crystal display modules (LCM) production business, changed our company name from Nam Tai Electronics, Inc. to Nam Tai Property Inc. and switched our business focus to the redevelopment of two parcels of land in Shenzhen, China, which formerly housed our manufacturing facilities, into high-end research and development complexes. We have named these property development projects in Guangming and Gushu, Shenzhen, "Nam Tai Inno Park" and "Nam Tai Inno City", respectively. Upon the completion of the development, we will be the landlord and manager of these research and development complexes, and our core business will then become property development and management. During this development transition period, all overhead expenses, development costs and dividend distributions will be funded from our interest income and rental income together with our cash on hand and bank facilities. Subsequently, we believe that we will derive our principal income in the future from the rental income generated through these commercial complexes. As each of these projects may take around four to seven years to complete and we have no other source of significant income during this period, we do not anticipate that we will be profitable until at least the completion of these two projects.
Accounting & Financial Operations - Risk 6
Changed
Our declaration and payment of dividends is not assured. Although our Board has declared dividends for 2014, 2015, 2016, 2017 and 2018, we may not declare or pay dividends thereafter.
We declared the payment of quarterly dividends of $0.02, $0.02, $0.02, $0.07 and $0.07 per share for 2014, 2015, 2016, 2017 and 2018, respectively. The payment of dividends in 2014, 2015, 2016, 2017 and 2018 does not necessarily mean that dividend payments will continue thereafter. Whether future dividends after 2018 will be declared will depend on our future growth and earnings at each relevant period, of which there can be no assurance, and our cash flow needs for our business transformation. Accordingly, there can be no assurance that cash dividends on the Company's common shares will be declared beyond those declared for 2018, what the amounts of such dividends will be or whether such dividends, once declared for a specific period, will continue for any future period, or at all. For additional information on the dividends we declared for 2018 and historically, please see ITEM 8. Financial Information - Dividends on page 60 of this Report.
Accounting & Financial Operations - Risk 7
Added
Certain information contained herein is derived from unofficial publications.
Certain information in this Report relating to the growth of the Shenzhen city, including statistics relating to the growth of its GDP and industry sectors, is derived from various government publications. Such information may not be consistent with those prepared by other independent market research within or outside of the mainland China. Such information also has not been independently verified by us.
Accounting & Financial Operations - Risk 8
Added
We might not be able to carry all of our operating losses forward.
Our operating activities in the short term will consist principally of capitalized project investments. While certain operating losses may be carried forward as tax credits in future years; if there are changes in the relevant PRC tax policy with respect to the real estate industry, our forecasted profits in the future may also be affected.
Accounting & Financial Operations - Risk 9
Added
Our margins may be affected by increases in our operating and other expenses.
Our operations may be subject to increases in operating and other expenses due to a number of factors including, but not limited to, any of the following:
- increases in raw material prices;- increases in labor costs;- increases in construction costs;- increases in the rate of inflation;- changes in laws, regulations or government policies that increase the cost of compliance with such laws, regulations or policies;- increases in insurance premiums;- increases in customs duties, business taxes, property taxes and other statutory changes;- adverse changes in the cost of existing and future debt financing; and - other unanticipated circumstances or cost increases.
Any increase in the above operating and other expenses would have an adverse effect on our cash flows. Furthermore, any sustained increases in our operating and other expenses could result in all or a portion of our operations becoming unprofitable, thereby resulting in an adverse effect on our business, financial condition and results of operation.
Accounting & Financial Operations - Risk 10
Added
The appraised values of our properties may be different from the actual realizable value and are subject to change.
The appraised values of our properties made available by us on our website were prepared by Savills, Cushman & Wakefield and Jones Lang LaSalle as real estate feasibility studies that are based on multiple assumptions containing elements of subjectivity and uncertainty, including, among other things, that:
- we will complete development projects on time;- we have obtained or will obtain on a timely basis all approvals from regulators necessary for the development of the projects; and - we have obtained valid land titles to the development projects.
As a result, the appraised values of our properties may differ materially from the price we could receive in an actual lease or sale of the properties in the market and should not be taken as their actual realizable value or a forecast of their realizable value. Unforeseeable changes to our development of the property projects, as well as national and local economic conditions, may affect the value of our properties. In particular, the valuation of our properties could stagnate or even decrease if the market for comparable properties in Shenzhen, China experiences a downturn whether as a result of Government policies directed to the property sector or otherwise.
Information contained in or that can be accessed through the website mentioned in this Report does not form part of this Report.
Debt & Financing2 | 4.3%
Debt & Financing - Risk 1
Changed
We may not have adequate financing, whether through bank loans or other arrangements, to fund our currently planned or future property developments, and such capital resources may not be available on commercially reasonable terms, or at all.
Property development is capital intensive and we require significant capital resources to fund our existing and future construction and real estate development activities. Our ability to finance our capital expenditure plans is subject to a number of risks, contingencies and other factors, some of which are beyond our control. To the extent that our funding requirements exceed our financial resources, we may be required to seek additional debt or equity financing or to defer planned expenditures. As of December 31, 2017, we have a total cash balance of $165.2 million and no debt. We plan to finance our property developments using our interest income together with our cash on hand and bank facilities. With our current cash position, we believe our financial position remains sufficient to fund the initial stages of these property development projects through 2018. While our cash on hand is expected to drop continuously, most of the expenses to be incurred are expected to be for project development, which will be capitalized as real estate properties under development (non-current asset) on our balance sheet. To address any potential shortage of funds beyond 2018, we will consider utilizing banking facilities or issuing debt securities to raise funds. We cannot assure you that banks or other lenders will grant us sufficient financing in the future on favorable terms or at all. There are certain PRC laws and regulations that not only govern financing policies of PRC financial institutions with respect to the property development sector but impose more stringent requirements on banks in terms of providing loans to property development enterprises, and it is possible that the PRC government may decide to further tighten such restrictions. These property-related financing policies may limit our ability and flexibility to use bank borrowings to finance our property development projects, thereby causing us to maintain a relatively higher level of internally generated cash to serve our funding needs. If our financing measures are not successful, we may face liquidity and other financial risks, which could materially impair any property development efforts.
Furthermore, any adverse developments in the international equity capital or credit markets could be a barrier for us to raise additional financing and could increase the overall cost of our funds. We may also require additional financing to fund day-to-day operations and debt service payments. Additional financing, when needed, might not be available on acceptable terms, or at all. Our incurrence of additional debt would result in increased debt service obligations and could result in additional operating and financing covenants, or liens on our assets that may restrict our operations. Without the required financing, we might not be able to continue our operations, implement our planned projects, hire, train and retain employees or respond to competitive pressures. The lack of adequate funding facilities on acceptable terms, or at all, may adversely affect our ability to fund the development and expansion of our business. Our inability to obtain sufficient funding to support our operations or development strategies could have an adverse effect on our business, financial condition and results of operations.
Debt & Financing - Risk 2
Changed
Our income will continue to drop due to the decrease in interest income from our deposits as well as the cessation of rental income upon expiration of the lease agreement that rented out our Gushu property in October 2017.
We currently derive a majority of our income from interest and rental income. The rates of interest receivable on our PRC time deposits are adjustable based on the range of 0% to 43% of the People's Bank of China (PBOC) benchmark rate, which fluctuates from time to time. The PBOC benchmark rate for a seven days' notice deposit was 1.35% as of December 31, 2017. As of December 31, 2017, the principal amount of our aggregate outstanding time deposits was $166.1 million. A hypothetical 1% decrease in annual interest rates would decrease our interest income by $1.7 million based on our deposit level at December 31, 2017. Since 2017, we have seen a stabilizing trend for the benchmark interest rates in China. However, due to the current economic conditions in China, we expect the PBOC to keep Renminbi-denominated official time deposit interest rates in China at a low level throughout 2018, which in turn would keep our interest income low. This lower interest rate environment will be compounded as a result of our rental income ceasing following the expiration of the lease agreement in October 2017 that rented out our existing manufacturing facilities of approximately 48,422 square meters in Gushu, Shenzhen. We will continue to expect operating losses in 2018 and beyond.
Corporate Activity and Growth3 | 6.4%
Corporate Activity and Growth - Risk 1
We may encounter difficulties in transforming our core business, which could adversely affect our growth and business prospects.
We are a property development and management company located in Shenzhen, China. Prior to becoming a property development and management company, we were an electronic manufacturing service (EMS) company. In April 2014, we ceased our LCM manufacturing business and switched our business focus to the redevelopment of two parcels of land in Gushu and Guangming, Shenzhen, China, which formerly housed our manufacturing facilities into high-end commercial complexes designated as "Nam Tai Inno City" and "Nam Tai Inno Park", respectively.
We cannot assure you that we will be able to obtain all requisite permits and approvals from relevant government authorities in relation to the redevelopment of the land, or to successfully redevelop the two parcels of land. The development of these real estate projects is subject to significant risks and uncertainties, including, without limitation, the following:
- we do not currently have strong brand recognition or relationships in the real estate development and management business;- we may not be able to obtain all requisite permits and approvals from relevant government authorities in relation to the redevelopment of the land, or to successfully redevelop the two parcels of land for our property development projects in a timely manner or at all;- we face intense competition from real estate developers that have been operating in this business for years;- our experience and expertise gained from our EMS business may not be highly relevant or applicable to the real estate development and management business; and - we may not be able to generate enough revenues to offset our costs in our real estate development and management business.
If we are not successful in the development of our two property development projects, our growth, business, financial condition and results of operations could be adversely affected.
Corporate Activity and Growth - Risk 2
Changed
The Process of PRC Real Estate Development Projects
The following flow chart summaries the technical process of typical real estate developing projects in the PRC:
Planning and Design
Our project planning and design process includes concept and architectural design, construction and engineering design, budgeting, financial analysis and projections as well as arranging for financing. We believe careful planning is essential to control costs, quality and timing of our projects.
We outsource our design work to reputable third-party design firms. For Nam Tai Inno Park, we will appoint a renowned professional architectural firm to complete the design. Our planning and development team works closely with project managers as well as our external designers and architects to ensure that our designs comply with PRC laws and regulations, and meet our design and other project objectives as a part of our design management process. Our senior management is also actively involved in the process, especially in the master planning and architectural design of our projects. We conduct preliminary planning and scheduling for each stage of the development project, including planning our outsourcing requirements for the project construction stage.
We seek to integrate technology in our projects by incorporating various sensors to our building automation systems with designs that focus on the comfort and convenience of the tenants. In determining the architectural designs of our projects, we consider the proposed type of products to be developed in light of the surrounding environment and neighborhood.
In selecting external design firms, we consider, among other things, their reputation for reliability and quality, their track record in the market, the design proposed and the price quoted. Design firms can participate in the tender process by our invitation only. Our planning and design team monitors the progress and quality of the design firms to ensure that they meet our requirements.
Construction and Management
We outsource all of our construction work to independent construction companies which are selected mainly through our invitation to tender bids for the project. We generally hire one or more main contractors for each of our projects with a number of subcontractors. The main contractors are responsible for a designated portion of the project. We have established a selection procedure in order to ensure compliance with our quality and workmanship standards. We take into account the construction companies' professional qualifications, reputation, track record and financial condition and resources when inviting candidates to bid. We also review the qualifications and performance of our construction contractors periodically. We closely supervise and manage the entire project construction process, to monitor and analyze information regarding quality of the construction and material purchased on a real-time basis. We collect information throughout the development cycle on the entire project, including information from our third-party contractors, to avoid unanticipated delays and cost overruns.
Our construction contracts typically provide for limited flexible payments, which provide for adjustments for some types of excess, such as design changes during construction or changes in government-suggested steel and cement prices, as well as labor costs. The contractors are typically responsible for procuring the necessary raw materials, as well as providing engineering and construction services. We procure certain ancillary fixtures for installation, such as elevators, windows and entrance doors. For our purchases of such fixtures, we use a centralized procurement process to help increase our negotiating power and lower our unit costs. We maintain good relationships with our suppliers and have not encountered any significant supply shortages or disruptions in the past.
Marketing, Sales and Leasing
We maintain an internal marketing team for our development projects and will build up a sales force and operating team during 2018. We may also use outside agencies on our projects when appropriate. Our marketing teams had surveyed the demographics of each project area to determine the appropriate unit sizes and design features. They will work also work with the sales force and outside agencies to prepare the advertising, promotion, and selling plans for each project. The sales force at each project will be responsible for following through on the entire sales and leasing process including setting monthly sales or leasing targets, controlling prices, implementing special promotions, monitoring external agency performance, and processing customer feedback.
To fully utilize the large amount of research and development space that may be released to the market upon the completion of our Nam Tai Inno Park and Nam Tai Inno City projects, we plan to establish our own sales force and operating team, which will work in conjunction with other external agents, consultants and advisers to make further detailed plans of our operation and tenancy requirements. We plan to leverage our geographical advantages of locating within the Greater Bay Area at the mouth of the Pearl River Delta and being on the corridor between Qianhai free-trade-zone and Shenzhen International Airport and Convention Center. By taking advantage of the scale of our building complexes and the services it may provide as a technology research and development platform, we intend to roll out attractive and differentiated products.
Delivery, After-Sale Services and Property Management Operation
We assist customers in arranging for and providing information relating to financing. We also assist our customers in various title registration procedures relating to their properties, and we have set up an ownership certificate team to assist purchasers in obtaining their property ownership certificates. We offer various communication channels to customers to provide their feedback about our products or services. We also cooperate with property management companies that manage our properties and ancillary facilities, such as schools and clubhouses, to handle customer feedback.
We endeavor to deliver the units to our customers on a timely basis. We closely monitor the progress of construction of our property projects and conduct pre-delivery property inspections to ensure timely delivery. Once a property development has been completed, has passed the requisite government inspections and is ready for delivery, we notify our customers and hand over keys and possession of the properties.
To ensure smooth operation of our building complexes and quality property management, we may also provide property management for each research and development centers. It is envisioned that our property management services will include security, landscaping, building management and management of public facilities and equipment, and additional services, such as cultural activities, housekeeping and repair.
Corporate Activity and Growth - Risk 3
Added
We have a comparatively limited track record in the real estate development business and cannot guarantee our continued success.
In contrast to our 30 years of experience in the electronic manufacturing industry, we entered the real estate development business relatively recently. Nam Tai Inno Park and Nam Tai Inno City represent our first two projects. Given that the real estate development business in China is highly competitive and dominated by several large, experienced real estate developers, our limited track record may impact our ability to continue our real estate development business successfully. In addition, the success of our real estate development business will depend upon our ability to:
- complete construction of our self-developed properties on time and within estimated budgets;- obtain, on a timely basis, all approvals necessary to develop and operate our properties;- develop properties in locations that are desirable to prospective tenants;- accurately anticipate the requirements of prospective tenants; and;- respond to dynamic market conditions.
Our ability to manage these risks will directly impact the success of our real estate development business and, our failure to do so could adversely impact our overall financial condition, results and cash flows.
Legal & Regulatory
Total Risks: 13/47 (28%)Above Sector Average
Regulation6 | 12.8%
Regulation - Risk 1
Changed
We may fail to obtain, or experience material delays in obtaining, requisite licenses, certificates, permits or governmental approvals for our property developments, and as a result our development plans, business, results of operations and financial condition may be materially and adversely affected.
As owner/developer, we face various execution risks that may adversely affect our revenue and operations. Property development in the PRC is heavily regulated, long and complicated process, generally requiring large amounts of capital and involving numerous parties, including designers, construction material suppliers, contractors, developers and individual consumers. Property developers in China must abide by various laws and regulations, including implementation rules promulgated by local governments to enforce these laws and regulations. At various stages of our property development projects, we are required to obtain and maintain certain licenses, certificates, permits and governmental approvals, including, but not limited to, qualification certificates, land use rights certificates, land use permits, construction planning permits, construction permits, pre-sale permits, construction acceptance certificates and property ownership certificates. Before the government authorities issue any license, certificate or permit, we must also satisfy specific conditions and requirements. We cannot assure you that we will not encounter other material delays or difficulties in fulfilling the necessary conditions to obtain all necessary licenses, certificates or permits for our property developments in a timely manner, or at all, in the future. The progress and costs of a property development project can also be adversely affected by many factors beyond delays in obtaining necessary licenses, permits, certificates or approvals from government agencies or authorities, including shortages of materials, equipment, contractors and skilled labor, labor disputes, construction accidents, natural catastrophes, adverse weather conditions, and changes in government policies. Construction delays, cost overruns, or failure to complete and deliver a property development project on schedule and in accordance with specifications due to any or all of the above factors may affect our business, financial condition and results of operations and may also cause reputational damage. Also, we might not be able to adapt to new PRC land policies that may come into effect from time to time with respect to the property development industry. Any failure to obtain the necessary licenses, certificates, permits and approvals may result in us not being able to continue with our development plans, which may then materially adversely affect our business, results of operations and financial condition. There can be no assurance that we will not experience any significant delays in completion or delivery of any of our property development projects, or that we will not be subject to any contractual liabilities for any such delays. Moreover, if the design or construction of a property development fails to meet applicable requirements, our revenues could be adversely affected. Claims that we have failed to produce property developments of sufficient quality could result in our involvement in legal disputes, which in turn could have an adverse effect on our business and results of operation.
Regulation - Risk 2
The PRC legal system has inherent uncertainties that could materially and adversely impact our ability to enforce the agreements governing our properties and their development and to do business.
We occupy our former manufacturing facilities under China land use agreements with agencies of the PRC government. Our operations depend on our relationship with the local governments in the regions which our facilities are located. Our operations and prospects could be materially and adversely affected by the failure of the local government to honor these agreements or an adverse change in the law governing them. In the event of a dispute, enforcement of these agreements could be difficult in China. Unlike the United States, China has a civil law system based on written statutes in which judicial decisions have limited precedential value. The PRC government has enacted laws and regulations dealing with economic matters such as corporate organization and governance, foreign investment, commerce, taxation and trade. However, its experience in implementing, interpreting and enforcing these laws and regulations is limited, and our ability to enforce commercial claims or to resolve commercial disputes in China is unpredictable. These matters may be subject to the exercise of considerable discretion by agencies of the PRC government, and forces and factors unrelated to the legal merits of a particular matter or dispute may influence their determination.
Regulation - Risk 3
We may be deemed to be an investment company under the United States Investment Company Act of 1940, which could have a significant negative impact on our results of operations.
We may be deemed to be an investment company under the United States Investment Company Act of 1940 (the "1940 Act"), and may suffer adverse consequences as a result. Generally, the 1940 Act provides that a company is an investment company if the company (i) holds itself out as or proposes to be engaged primarily in the business of investing, reinvesting or trading in securities or (ii) is engaged or proposes to engage in the business of investing, reinvesting, owning, holding or trading in securities and owns or proposes to acquire "investment securities" having a value exceeding 40% of the value of its total assets (exclusive of U.S. government securities or cash items) on an unconsolidated basis. For purposes of the foregoing test, investment securities include, among other things, securities of non-majority owned businesses.
Due to deteriorating business conditions, we ceased our original core LCM production business in April 2014, and are switching over to property development and management. In addition, we completed the sale of all of our EMS manufacturing equipment as of September 2014 to third parties and our last remaining production line in Wuxi was removed in September 2014. As a result of these transactions, we have a significant amount of cash. See ITEM 4. Information on the Company - Historical Business Overview for additional information. Consequently, there is a risk that we could be deemed to be an investment company.
We intend to continue to conduct our businesses and operations so as to avoid being deemed to be an investment company. If, nevertheless, we are deemed to be an investment company, because we are a foreign company, in the absence of a grant by SEC of an exemptive order permitting us to register under the 1940 Act, the 1940 Act would prohibit us and any person deemed to be an underwriter of our securities from offering for sale, selling or delivering after sale, in connection with a public offering, any security issued by us in the United States. Additionally, we may be unable to continue operating as we currently do and might need to acquire or sell assets that we would not otherwise acquire or sell in order to avoid being treated as an "investment company" as defined under the 1940 Act. We may incur significant costs and management time in this regard, which could have a significant negative impact on our results of operations.
Regulation - Risk 4
Changes in foreign exchange regulations of China could adversely affect our operating results.
Some of our earnings are denominated in yuan, the base unit of the RMB. The People's Bank of China, or PBOC, and the State Administration of Foreign Exchange ("SAFE") regulate the conversion of RMB into foreign currencies. Under the current unified floating exchange rate system, the PBOC publishes a daily exchange rate for RMB based on the previous day's dealings in the inter-bank foreign exchange market. Financial institutions may enter into foreign exchange transactions at exchange rates within an authorized range above or below the exchange rate published by the PBOC according to market conditions. Since 1996, the PRC government has issued a number of rules, regulations and notices regarding foreign exchange control designed to provide for greater convertibility of RMB. Under such regulations, any FIE must establish a "current account" and a "capital account" with a bank authorized to deal in foreign exchange. Currently, FIEs are able to exchange RMB into foreign exchange currencies at designated foreign exchange banks for settlement of current account transactions, which include payment of dividends based on the board resolutions authorizing the distribution of profits or dividends of the company concerned, without the approval of SAFE. Conversion of RMB into foreign currencies for capital account transactions, which include the receipt and payment of foreign currencies for loans and capital contributions, continues to be subject to limitations and requires the approval of SAFE. There can be no assurance that we will be able to obtain sufficient foreign currencies to make relevant payments or satisfy other foreign currency requirements in the future.
Regulation - Risk 5
Regulatory initiatives in the United States, such as the Dodd-Frank Act and the Sarbanes-Oxley Act have increased, and may continue to increase the time and costs of being a U.S. public company and any further changes would likely continue to increase our costs.
In the United States, changes in corporate governance practices due to the Dodd-Frank Act and the Sarbanes-Oxley Act, changes in the continued listing rules of the New York Stock Exchange, new accounting pronouncements and new regulatory legislation, rules or accounting changes have increased our cost of being a U.S. public company and may have an adverse impact on our future financial position and operating results. These regulatory changes and other legislative initiatives have made some activities more time-consuming and have increased financial compliance and administrative costs for public companies, including foreign private issuers like us. In addition, any future changes in regulatory legislation, rules or accounting may cause our legal and accounting costs to further increase. These new rules and regulations require increasing time commitments and resource commitments from our company, including from senior management. This increased cost could negatively impact our earnings and have a material adverse effect on our financial position results of operations.
Regulation - Risk 6
PRC Regulations on Real Estate Development and Management
The PRC government regulates the real estate industry. This section summarizes the principal PRC regulations relating to our business.
We operate our business in China under a legal regime consisting of the National People's Congress, State Council, which is the highest authority of the executive branch of the PRC central government, and several ministries and agencies under its authority, including the Ministry of Housing and Urban-Rural Development, or the MOHURD, the Ministry of Land and Resources, or the MLR, the Ministry of Commerce, or the MOFCOM, the National Development and Reform Commission, or the NDRC, the State Administration for Industry and Commerce, or the SAIC, the State Administration of Taxation, or the SAT, and the State Administration of Foreign Exchange, or the SAFE, and their respective authorized local counterparts.
Shenzhen City Zoning Measures
Urban Planning Criteria and Standards of Shenzhen City promulgated by the People's Government of Shenzhen City on January 1, 2014, among other things, classifies zoning of land. "M" stands for the industrial land that is mainly used for the production, manufacture and fine machining of products. Other auxiliary use includes research, design, testing, management and other activities. Within the M zone, "M-1" refers to common industrial land that is mainly zoned for factory buildings for the production and manufacturing. Other uses for this type of land include warehouse, small business, staff dormitory, attachable public facilities, attachable transportation facilities and other auxiliary facilities. "M-0" refers to a new type of industrial zone that combines research, originality, design, test pilot production, pollution-free production, other innovative industry and relevant supporting services. Land zoned as such is mainly used for the factory buildings (pollution-free production) and research and development building and can also be used for the associated commercial and staff building, attachable public facilities, attachable transportation facilities and other auxiliary facilities.
Compared to M-1, M-0 has a lower minimum usable area for partial transfer of property rights, which for M-1 according to current regulations is 500 square meters, and for M-0 is 180 square meters. If the draft for public comments on "the Measures on Administration of Industrial Block and Line of Shenzhen City" issued on December 22, 2017 is passed and formally promulgated, the minimum usable area for subdivision and partial transfer of property rights will be raised to 1,000 square meters for M-1 and 500 square meters for M-0. We believe a smaller subdivision and partial transfer area will be more beneficial to us for the sale of constructed units, as it would give us greater flexibility. Further, buildings in M-0 zone must follow certain legal planning construction index allocation for a percentage of the buildings to be designated as research and development offices, commercial, and apartments, while index for buildings in M-1 zone must be designated as factory buildings, small commercial and auxiliary dormitory. As a result, we believe the planning construction index for M-0 zone offers us greater commercial advantages. Finally, the permitted floor area ratio for M-0 is 6:1, compared with 4:1 for M-1. Higher floor area ratio means permission for larger building areas and potentially higher value for the projects as constructed.
As stipulated in the Measures on Administration of Industrial Occupancy Zoning Transformation of the City Renewal Project in the Baoan district, Shenzhen, the site of Phase I of Nam Tai Inno City falls within the city renewal project of the Baoan district industrial red line zone and can generally only be rezoned into the common industrial zone M-1, unless otherwise approved by relevant government department to change into the new type industrial zone, M-0.
Currently, the site of our Nam Tai Inno Park is zoned as M-1 with 50 years of Land Use Rights starting from 2007. Phase I of Nam Tai Inno City, the eastern section, is zoned as M-0 with 50 years of Land Use Rights starting from 1993, but we plan to re-execute the land use rights contract with the urban planning, land and resource department in the second quarter of 2018, which would restart the 50 years Land Use Rights from the date of re-execution. Phase II of Nam Tai Inno City, the western section, is currently zoned as M-1 with 50 years of Land Use Rights starting from 1999. We plan to apply for the M-0 zoning approval on June 2020, after our existing facilities on the site have aged for 15 years, or earlier if permitted. We plan to re-execute the land use rights contract at the same time, which would also restart the 50 years Land Use Rights from the date of re-execution.
Shenzhen City Renewal Measures
Our two development projects, Nam Tai Inno Park and Nam Tai Inno City are located within the municipality of Shenzhen city. Our development must be made in compliance with the relevant rules and regulations of Shenzhen City.
The Shenzhen City Renewal Measures promulgated by the Shenzhen government on November 12, 2016 restricts city renewal projects as follows:
- city renewal refers to activities in certain types of building construction in areas of the city (including old industrial parks, old commercial districts, old residential districts, urban villages and old housing districts) and existing of comprehensive improvement, functional alteration, or demolition and reconstruction ;- demolition and reconstruction of a city renewal project should strictly follow the city renewal unit plan and city annual renewal plan; and - the responsible body of demolition and reconstruction of a city renewal project should sign a land use rights supplementary contract or re-execute a land use rights contract with the Urban Planning, Land and Resource department after obtaining the documents of approval of city renewal project. In such circumstances, the term for land use rights will be recalculated and the responsible body needs to pay the additional premium according to the relevant regulations.
Our Nam Tai Inno City project is a demolition and reconstruction city renewal project. Phase I of the Nam Tai Inno City project has received the approval documents for city renewal. We plan to re-execute the land use rights contract with the urban planning, land and resource department in the second quarter of 2018, so that the 50 years term of Land Use Rights will restart from the date of the re-execution. As a part of re-executing the land use rights contract, however, we are required to pay an additional land premium which would bring up the costs basis of our land. The amount of the land premium differs based on the different property usage or transfer method in the future. As we obtained our land at a relatively low cost historically, we may be subject to significant additional land premium when we re-execute the land use right contracts.
The Interim Measures on Strengthening and Improving City Renewal Implementation promulgated by Shenzhen government on December 29, 2016 and effective as of January 1, 2017 provide that:
- to apply to demolish and reconstruct buildings as a part of a city renewal projects, the age of the building must be no less than 20 years for buildings located in residential districts; and for buildings located in industrial or commercial districts, not less than 15 years; and - to demolish and reconstruct buildings as a part of a city renewal project located in the state-owned industrial land, warehousing land, land for logistics purposes, land for urban infrastructure and public service facilities' updating and rebuilding for industrial purposes or for industry that government encourages to develop, their correction factor for land granting premium based on the public benchmark land price will be: 0.1 for private use; 0.7 for wholly transfer; 1.0 for partial transfer of industrial plants or new industrial occupancy; and 5 for auxiliary facilities.
Our Nam Tai Inno City project is a demolition and reconstruction city renewal project in an industrial district, the buildings of which shall be no less than 15 years old before it can be demolished and reconstructed. The buildings located on the site of Phase I of Nam Tai Inno City, the eastern section, were built in 1996, thus they have satisfied the 15 years age requirement. However, for buildings located on the site of the Phase II of Nam Tai Inno City, the western section, they will satisfy the 15 years age requirement on schedule in June 2020. However, we may speed up the process for earlier zoning approval through discussions with the relevant authorities.
Furthermore, the floor area ratio of Nam Tai Inno City project has greatly increased from 2.3: 1 for our prior facilities located on the site of Phase I of Nam Tai Inno City to 6:1 for Phase I of Nam Tai Inno City. For Phase II of our Nam Tai Inno City project, it is also expected that the floor area ratio will increase from 1.6:1 from our prior facilities to 6:1 for Phase II of Nam Tai Inno City. This results in a large increase in the floor area ratio in the Nam Tai Inno City project compared to the floor area ratio granted to us previously for our prior facilities. According to the regulations and policy direction, further limitations, including a requirement that certain portion of a renewal project of old industrial districts, especially ones with a large increase in floor area ratio, may also be subject to usage limitations or required to be self-owned and not sold to third parties, which could further limit our ability to sell our units.
On December 22, 2017, the Economic, Trade and Information Commission and Urban Planning, Land and Resources Commission of Shenzhen Municipality jointly promulgated Measures on Administration for Industrial Block Line of Shenzhen Municipality (the draft for public comments), which, among other things, provides:
- If Industrial land which falls into block line is used for research and development buildings, the proportion reserved for self-ownership should be no less than 60%.
- The authority shall strictly control the transformation from M-1 into M-0 within the block line and the whole proportion of such transformation should be no more than 20% within the block line in each district. The transformation should be finally approved by municipal government after district government's collection of suggestions of Urban Planning, Land and Resources Commission and Industry Management Department.
- If the transferor transfers industrial land within the first-tier industrial line or partially transfers an industrial building, the transferee must be an industrial enterprise above state designated scale or an enterprise that has been engaged in manufacturing for more than 3 years and has paid all legal tax and the transferee cannot change the usage of buildings. The minimum transfer area of factory building for M-1 or M-0 shall be no less than 1,000 square meters and the minimum transfer area of research and development building for M-0 shall be no less than 500 square meters.
- Buildings in the M-0 zone shall be mainly used for construction of the factory buildings (pollution-free production) and research and development buildings. The floor area of factory buildings and research and development buildings shall be no less than 70% of the total floor area. If factory buildings and research and development buildings coexist in a project, the floor area of factory building (including comprehensive buildings combining factory buildings with research and development buildings) shall be no less than 30% of the total floor area.
- Factory buildings within both M-1 and M-0 zones shall not be changed to apartments. Research and development buildings and auxiliary facilities shall not adopt apartment-like design. The floor area of one set of offices shall be no more than 50% of the floor area of that floor. The floor area of one set of offices for M-1 shall be no less than 1,000 square meters and 500 square meters for M-0.
- The site of Nam Tai Inno City is on an industrial land within the first-tier line of industrial block line where the government strictly controls the proportion of transformation from M-1 into M-0 on this type of land. Phase I of Nam Tai Inno City has obtained the government approval to rezone into M-0, while we plan to apply for M-0 zone on Phase II of Nam Tai Inno City upon the maturity of the building age requirement around June 2020, or earlier through discussions with the relevant authorities. We may confront difficulty in acquiring such an approval from the government owing to certain proportion requirements within the City Renewal Measures, so that not all M-1 zones can be rezoned as M-0. The requirement that a proportion of industrial land must be dedicated as factory buildings or research buildings also restricts us from developing other types of auxiliary facilities. In addition, the restriction that ownership of industrial buildings must be held by enterprises and the minimum size of subdivision may also affect the sale of our units. We cannot assure you that we will obtain the M-0 zoning for Phase II of our Nam Tai Inno City. If we failed to obtain the M-0 zoning approval, we will have to develop Phase II of Nam Tai Inno City under the M-1 zoning approval. Our business, financial condition, and results of operations could be adversely affected as a result.
Regulations on Development of a Real Estate Project
The following is a summary of the relevant permits and certificates we must obtain to complete our projects, together with the applicable regulations. Please see "ITEM 4. Information on the Company – Our Land Development Projects – Estimated Timetable for the Two Projects" for the estimated timetable of when we expect to obtain each of the following permits and certificates: (a) Land Use Permit, (b) Land Use Rights Certificates (c) Construction Planning Permit, (d) Construction Permit, (e) Construction Acceptance Certificate, and (f) Property Ownership Certificate.
Regulations on Land
The Law of the PRC on Land Administration, promulgated on June 25, 1986 and amended on August 28, 2004 by the Standing Committee of National People's Congress, distinguishes between the ownership of land and the right to use land. All land in the PRC is either state-owned or collectively-owned, depending on location. Generally, land in urban areas within a city or town is state-owned, and all land in the rural areas of a city or town and all rural land, unless otherwise specified by law, are collectively-owned.
Land Use Permit
The Law of the PRC on Urban and Rural Planning, promulgated by the National People's Congress on October 28, 2007 and effective as of January 1, 2008, as amended on April 24, 2015, replacing the previous City Planning Law of the PRC, and the Measures for Control and Administration of Grant and Assignment of Right to Use Urban State-owned Land promulgated by the Ministry of Construction in December 1992 and amended in January 2011, provides that a developer who has obtained land use rights by grant must, after obtaining approval for a construction project and signing a land use rights grant contract, apply to the city planning authority for the Land Use Permit before applying for the land use rights certificate as more fully described below.
Amendment 3 to the land use right grant dated July 8, 2015 for the site underlying our Nam Tai Inno Park project requires us to complete certain building structures by July 7, 2018. If we failed to do so we may be subject to certain penalty.
Land Use Rights Certificate
Although all land in the PRC is owned by the governments or by the collectives, private individuals and businesses are permitted to hold, lease and develop land for a specified term without ever owning the land, the duration of which depends on the use purpose of the land. These rights to use land are termed "Land Use Rights". Under the Interim Regulations of the PRC on Grant and Transfer of the Right to Use State-owned Land in Urban Areas, promulgated on and effective as of May 19, 1990 by the State Council, a system of assignment and transfer of the right to use state-owned land is adopted. Enterprises, companies and other organizations who intend to hold, lease and develop the land, or the "Land Users", pay a land premium to the government as consideration for the grant of the Land Use Rights on terms of use prescribed by the government, and a Land User may transfer, lease and mortgage or otherwise commercially exploit the land use rights within such terms of use. The land administration authority enters into a contract with the Land User for grant of the land use rights. The Land User pays the land premium as stipulated in the grant contract. After paying the land premium in full, the Land User registers with the land administration authority and obtains a "Land Use Rights Certificate". The certificate evidences the acquisition of the Land Use Rights. The maximum term with respect to the assigned Land Use Rights are determined respectively in the light of the purposes listed below: (a) 70 years for residential purposes; (b) 50 years for industrial purposes; (c) 50 years for the purposes of education, science, culture, public health and physical education; (d) 40 years for commercial, tourist and recreational purposes; and (e) 50 years for comprehensive utilization or other purposes.
The Property Law of the PRC, or the Property Law, promulgated on March 16, 2007 and effective as of October 1, 2007, further clarified Land Use Rights in the PRC with the following rules:
- the Land Use Rights for residences will be automatically renewed upon expiry;- the car parks and garages within the building area planned for vehicle parks must be used to meet the needs of the owners who live in the building first;- the construction of buildings must abide by relevant laws and regulations with regard to the construction planning and may not affect the ventilation of or lighting to the neighboring buildings; and - where the Land Use Rights for construction use are transferred, exchanged, used as a capital contribution, donated to others or mortgaged, an application for modification registration must be filed with the registration department.
Construction Planning Permit
The Measures for Control and Administration of Grant and Assignment of Right to Use Urban State-owned Land promulgated by the Ministry of Construction in December 1992 and amended in January 2011 provides that a developer who has a proposed construction project within the planning area of a city or town must, after obtaining a Land Use Permit, prepare the necessary planning and design work, and submit the detailed planning and design report, together with the Land Use Rights Certificate, to the city planning authority or the town government designated by the provincial government, and apply for the Permit for Construction Works Planning.
Construction Planning Permit is different from Land Use Permit. Land Use Permit is a certificate proving that the land use act such as the location, scope and development intensity of the project corresponds with the requirement of urban planning, while Construction Planning Permit is a certificate proving that the design of construction engineering satisfy the requirement of urban planning.
The Law of the People's Republic of China on Urban and Rural Planning also provides regulations with respect to the formulation, implementation, modification, control, supervision and related legal liability of measures aimed at curbing problems that may arise as a result of conflicts between city and rural construction developments. The scope of the measures includes the planning, layout and construction of cities, towns with administrative status, market towns and villages. In order to effectively prevent construction that is in breach of rules and regulations, the Urban and Rural Planning Law stipulates that where any construction project is commenced without obtaining a Construction Planning Permit, or where a Construction Planning Permit has been obtained but construction has proceeded not in accordance with that permit, the Urban and Rural Planning Department at the county level or above may issue an order to cease construction. In the case that the construction can be remedied to conform to the relevant planning rules, an order can be made to rectify the construction in a prescribed period of time and a fine totaling between 5% to 10% of the total construction cost may be imposed. Where the construction cannot conform to relevant planning rules, an order for its demolition will be issued or, where demolition is not possible, the property and/or illegal income derived from the property will be confiscated and a fine totaling 10% or less of the construction cost will be imposed.
Construction Permit
On June 25, 2014, the MOHURD promulgated the Measures for the Administration of Construction Permits for Construction Projects, superseding its 1999 version. When the site has been properly prepared and is ready for the commencement of construction works, the developer must apply for a Construction Permit from the construction authorities at or above the county level according to the Measures for Administration of Granting Permission for Commencement of Construction Works promulgated by the MOHURD in June 2014. According to the Notice Regarding Strengthening and Regulating the Administration of Newly-commenced Projects issued by the General Office of the State Council on November 17, 2007, before commencement of construction, all projects shall fulfill certain conditions, including, among other things, compliance with national industrial policy, development plan, land supply policy and market access standard, completion of all approval and filing procedures, compliance with zoning plan in terms of site and planning, completion of proper land use procedures and obtaining proper environmental valuation approvals and construction permit or report.
Construction Permit is a prerequisite to start the main construction. In addition, Construction Permit is a statutory requirement of engineering acceptance examination, pre-sale and sale of commodity house and registration of property rights. If we fail to obtain the Construction Permit, in a timely manner, or at all, the commencement of engineering construction may be delayed. In such circumstances, we may not be able to complete our engineering construction on time according to the land use contract so that we may need to pay for the liquidated damages and our land may be taken back by the government. Our business, results of operations and financial condition may be materially and adversely affected.
Construction Acceptance Certificate
According to the Development Regulations and the Regulation on the Quality Management of Construction Projects promulgated by State Council on January 30, 2000, as amended on October 7, 2017, and the Provisions on Acceptance Examination Upon Completion of Buildings and Municipal Infrastructure promulgated by MOHURD in December 2013, after the completion of construction of a project, the property must undergo inspection and receive relevant approvals from local authorities including planning bureaus, fire safety authorities and environmental protection authorities. Thereafter, the property development enterprise shall apply for a certificate of completion at the property development authority under the people's government at the county level or above. Once the examination has been completed, a Construction Acceptance Certificate will be issued. A real estate development project may only be delivered after passing the inspection and acceptance examination. Failure to obtain Construction Acceptance Certificate may affect our ability to delivery commodity houses, if we chose to sell residences as our business model. If we fail to deliver commodity houses on time according to the contract, purchasers may demand us to take the responsibility of breach of contract.
Property Ownership Certificate
Under the Measures for Administration of Sale of Commodity Properties, developers must submit the documents relating to the application for Property Ownership Certificates to the local real estate administration authorities within 60 days after the delivery of property to customers. The developers are required to assist customers in applying for amendments in the procedures for land use rights and registration procedures for property ownership.
In accordance with the Measures for Administration of Pre-sale of Commodity Properties promulgated by ministry of construction on November 15, 2004 and amended on august 15, 2001 and July 20, 2004, the purchasers must apply for the individual Property Ownership Certificates to the local real estate administration authorities within 90 days after the delivery of pre-sale property to purchasers. The developers are required to assist and provide the purchasers with necessary verifying documents. Where the purchasers fail to obtain the individual Property Ownership Certificates within 90 days thereafter due to the developer's fault, unless otherwise provided between the developers and the purchasers, the developers will be liable for the breach of contract.
Pursuant to Interpretations on Certain Issues Concerning the Application of Law in Trying Cases Involving Disputes over Contracts on Purchase and Sale of Commodity Premises by Supreme People's Court passed on March 24, 2003 and enforced on June 1, 2003, property developers are required to deliver to purchasers then relevant individual Property Ownership Certificates within 90 days after delivery of a presold property or 90 days after execution of sale agreement of a ready-built property or, within a time frame set out in the relevant sale agreement, unless the agreement provides otherwise. Property developers, including us, generally elect to specify a deadline for the delivery of the individual Property Ownership Certificates in the sale agreements to allow sufficient time for the application and approval processes.
Under current regulations, we are required to submit the requisite governmental approvals in connection with our property developments, including Land Use Permit, Land Use Rights Certificates, Construction Planning Permits, Construction Permits, Construction Acceptance Certificates, to the local bureau of land resources and housing administration for the relevant properties and apply for the general Property Ownership Certificate in respect of these properties. According to Administrative Measures for the Sale of Commodity Houses issued by the MOHURD on April 4, 2001, we are required to submit related documents to the bureau for purchaser's application of individual Property Ownership Certificate subdivided from the general Property Ownership Certificate within 60 days after the delivery of property. We are required to assist property purchasers to go through related land use right alteration and house ownership registration procedures. Nevertheless, delays by the various administrative authorities in reviewing the application and granting approval and certain other factors may affect timely delivery of the general and individual Real Property Certificates. Therefore, we may not be able to deliver individual Real Property Certificates to purchasers on time as a result of delays in the administrative approval processes or for any other reason beyond its control, which may result in it having to pay default payments and, in the case of a prolonged delay, the purchaser terminating the sales agreement. If we become liable to a significant number of purchasers for late delivery of the individual Real Property Certificates, our business, financial condition and results of operations may be adversely affected.
Regulation on Transfer of Property Interest
According to Urban Real Estate Administration Law promulgated by the National People's Congress on July 5, 1994, as amended on August 30, 2007 and on August 27, 2009, transfer of real estate means moving the ownership of a real estate from the original owner to another person through sale, donation or other lawful means. When transferring a building, the ownership of the building and the Land Use Rights to the site on which the building is situated are transferred together.
Where the Land Use Rights were originally obtained by assignment, the real property may only be transferred on the condition that: (a) the assignment price has been paid in full for the assignment of the land use rights as provided by the contract for the assignment of the land and a land use rights certificate has been obtained; (b) development has been carried out according to the contract for the assignment of the land and, in the case of a project in which buildings are being developed, development representing more than 25% of the total investment has been completed.
The Provisional Industrial Building Transfer Measures and Detailed Implementation Rules on Industrial Building Transfer Measures promulgated by the People's Government of Shenzhen City on January 7, 2013 and December 6, 2013, respectively, provide legally built industrial buildings and public facilities on industrial land obtained legally by administrative allocation or through purchasing within administrative jurisdiction of the Shenzhen city may be wholly transferred in units of the parcel of land, unless otherwise stipulated by the laws, regulations, the present rules, the approval documents and the land use right granting contract. Industrial buildings can be divided and transferred as long as agreed upon the approval documents on land use or land use right granting contract.
The industrial buildings built through urban renewal projects may be subdivided and transferred. As industrial facilities in urban renewal projects, offices, dormitories for the single, and small business services facilities may be divided and transferred, but its floor area shall not exceed 30% of the total floor area of the project. The rebuild industrial buildings formed through urban renewal projects may also sold through a pre-sale process prior to the completion of the construction.
The transferee of such industrial buildings must be enterprises registered in accordance with the law. If the approval documents of land use, contracts of granting land use right or the municipal government regulations confines the assignee for purchasing the industrial buildings, the transferee must comply with the confining conditions and pass the qualification examination conducted by industry departments of district government.
Industrial buildings must be transferred and mortgaged after the registration of real property rights and the acquisition of real property rights certificates. In accordance with the provisions of these regulations, the industrial buildings that may be divided and transferred shall be registered with the real property right and be issued the corresponding certificates by the basic units of one room on certain level of each building.
In the transfer of industrial buildings, the transferor shall submit a certain proportion of the value-added income to the government, which shall be brought into the special management of a state-owned land income fund established by the government. The specific collection of regulations shall be separately formulated by the municipal land administration department. Value added income refers to the balance between the transaction price of the industrial building and the registered price plus relevant taxes paid by the transferor in the case of the industrial building. When the transfer of industrial buildings has been made in accordance with the provisions of these measures, and the land price has been paid, then this part of the price should also be deducted.
Our Nam Tai Inno City project is a city renewal project and thus the property of Nam Tai Inno City project can be subdivided and transferred in part under the regulations. However, we are limited to selling our units in Nam Tai Inno City to enterprises, as opposed to individuals, as the buildings are still considered as industrial buildings. Our Nam Tai Inno Park project is neither a city renewal project nor stipulated in the land use contract for subdivision and partial transfer of less than the whole complex. So unless we re-execute land use rights contract for further rights that would allow us to subdivide and transfer in parts, we are not permitted to sell the subdivided units in Nam Tai Inno Park. As re-execution of the land use rights contract with rights of further subdivision will require us to pay additional land premium, our current plan is to conduct commercial leases or long-term leases for the remainder of the land use rights period with respect to the properties in our Nam Tai Inno Park.
Under the current PRC regulations, there are certain restrictions placed on individuals purchasing residential units in a residential building. On October 4, 2016, the people's government of Shenzhen city promulgated the Measures Concerning Tightening Up Stable and Healthy Development of Real Estate Market, which provides, among other things, that each family with a Shenzhen registered residence may purchase no more than two residential units in a residential building within the Shenzhen city and the amount of the mortgage loan permitted also varies according to the specific circumstances. However, since our two projects are industrial buildings and the purchasers of units in our two projects are required to be enterprises as described above, the aforementioned restrictions do not apply, and our target enterprise purchasers may purchase any number of units.
Nevertheless, as each successive owner of units in an industrial building must be enterprises, not individuals, this may affect the transferability of both our commercial and residential units. Furthermore, other restrictions placed on enterprises to obtain loans generally may also impose further financial pressure on any potential enterprise purchasers, as it may adversely affect their willingness to purchase our units or ability to source funding.
Regulations on Leases
The Measures for Administration of Lease of Commodity Housing promulgated by the MOHURD on December 1, 2010 and implemented on February 1, 2011, requires parties to a leasehold arrangement of a property shall register the leasing agreement with property administrative authorities within 30 days after entering into such leasing agreement under local government at the municipal or county level where the property is situated. In addition, enterprise may be imposed a fine of RMB1,000 to RMB10,000 and individuals of RMB1,000 or less if they do not register leasing agreement within time limit required by competent authorities.
Regulations on Establishment of a Real Estate Development Enterprise
Pursuant to the Law of the PRC on Administration of Urban Real Estate, or Urban Real Estate Administration Law, promulgated by the Standing Committee of the National People's Congress on July 5, 1994 and amended on August 30, 2007 and on August 27, 2009, a Real Estate Development Enterprise is defined as "an enterprise that engages in the development and sale of real estate for the purposes of making profits."
Under the Regulations on Administration of Development and Operation of Urban Real Estate, or Development Regulation, promulgated by the State Council on July 20, 1998 and amended on January 8, 2011, a real estate development enterprise must satisfy the following requirements:
- has a registered capital of not less than RMB1 million; and - has four or more full time professional real estate/construction technicians and two or more full time accounting officers, each of whom must hold the relevant qualifications
To establish a Real Estate Development Enterprise, the developer is required to apply for registration with the department of administration of industry and commerce. The developer must also report its establishment to the real estate administration authority in the location of the registration authority within 30 days upon receipt of its business license.
Our PRC subsidiaries may apply for the qualification as a Real Estate Development Enterprise in due course, which would allow such subsidiaries to conduct pre-sale of the constructed real estate units, if they choose to. To do so, besides meeting the requirements above, we will also need to comply with other laws and administrative regulations on foreign-invested enterprise (please see Regulations on Foreign-Invested Real Estate Enterprise for further details).
Regulations on Foreign-Invested Real Estate Enterprise
Under Catalogue of Guidance on Industries for Foreign Investment (Revised in 2017), real estate development falls within the category of industries in which foreign investment is permitted and certain of our PRC subsidiaries may apply for the Real Estate Development Enterprise qualification in due course.
Opinions on Regulating Foreign Investment Access and Management of Real Estate Market jointly issued by MOHURD, MOFCOM, NDRC, PBOC, SAIC, and SAFE on July 11, 2006, as amended on August 19, 2015, stipulates that for Real Estate Enterprises established by foreign investment, their registered capital should be more than 50% of the total investment if the total investment is equal to or over US$10 million. Their registered capital should be no less than 50% of the total investment if the total investment is US$3 – US$10 million. Their registered capital should be no less than 70% of the total investment if the total investment is less than US$3 million. The current registered capital of our project subsidiary, Nam Tai Investment, is US$170 million, which we believe would allow it to meet the required registered capital under the regulation.
On May 23, 2007, MOFCOM and SAFE promulgated Notice on Further Strengthening and Regulating the Approval and Supervision on Direct Foreign Investment on Real Estate, as amended on October 28, 2015, which provides:
- to apply to establish a Real Estate Development Enterprise, one must obtain the Land Use Rights or ownership of the building first, or must sign assignment or purchase contracts with local land authorities or developer and owner of the building; only upon meeting the above requirements will the authorities approve the application; and - after properly established, if a foreign-invested enterprise intends to broaden its business scope for land development and operation, or to operate or develop new real estate business, one must apply relevant approval according to laws and regulations on foreign investment.
Qualification of a Real Estate Developer
Under the Rules on the Administration of Qualifications of Real Estate Developers promulgated on March 29, 2000 by MOHURD and effective on the same day (amended on May 4, 2015) a developer must apply for registration of its qualifications. An enterprise may not engage in the pre-sales of real estate units without a qualification classification certificate for real estate development.
In accordance with the above rules, developers are classified into four classes: class I, class II, class III and class IV. A developer that passes the qualification examination will be issued a qualification certificate of the relevant class by the relevant construction authority.
Under the Development Regulations, real estate administration authorities examine all applications for the registration of the qualifications of a developer when it reports its establishment, by considering its assets, professional personnel and business results. A developer may only undertake real estate development projects in compliance with the approved qualification registration.
After a newly established developer reports its establishment to the real estate administration authority, the latter will issue a provisional qualification certificate to the eligible developer within 30 days of its qualification of the above report. The provisional qualification certificate will be effective for one year from its date of issue and may be extended for not more than two additional years with the approval of the real estate development authority. The developer must apply for the qualification classification by the real estate administration authority within one month before expiry of the provisional qualification certificate.
Regulations on Pre-sale of Units
According to Urban Real Estate Administration Law promulgated by the National People's Congress on July 5, 1994, as amended on August 30, 2007 and on August 27, 2009, a commodity building may be sold before completion if: (a) the assignment price has been paid in full for the grant of the land use rights involved and a Land Use Rights Certificate has been obtained; (b) Construction Planning Permit and Construction Permit have been obtained; (c) the funds invested in the development of the commodity buildings put to pre-sale represent 25% or more of the total investment in the project and the progress of works and the completion and delivery dates have been ascertained; and (d) the pre-sale has been registered and a Pre-sale Permit has been obtained. The pre-sale seller shall, in accordance with the relevant state provisions, report the pre-sale contracts for record-filing to real estate administration and land administration departments of the people's government above the county level. The pre-sale proceeds of commodity buildings must be used to develop the relevant project so pre-sold.
According to the Development Regulations and the Measures for Administration of Pre-sale of Commodity Buildings promulgated by Ministry of Construction on November 15, 1994 and as amended on August 15, 2001 and July 20, 2004, the term "pre-sale of commodity houses" refers to the act that the real estate development enterprises sell the houses under construction to purchasers and the purchasers pay the earnest money or the prices of houses. The pre-sale of commodity houses shall be subject to the licensing system. Where a real estate development enterprise intends to sell commodity houses in advance, it shall apply to the real estate administrative department for pre-sale approval so as to obtain the Pre-Sale Permit. Real estate development enterprise must register contracts of pre-sale of commercial housing with the competent real estate authority and the relevant land administration of the people's government at the city or county level within 30 days after the date of execution of the contract and the purchasers shall go through the procedure of change in registration of land use right and registration of individual property ownership within 90 days after delivery of a presold property to obtain the individual property ownership certificates in respect of the properties purchased by the purchasers.
While our current plan for Phase I of Nam Tai Inno City does not involve pre-sale, we may pre-sale certain units in Phase II of Nam Tai Inno City. We may do so after we have obtained the Real Estate Development Enterprise qualification certificate and satisfy the above pre-sale conditions. If we fail to obtain the certificate in a timely manner, or at all, we would not be permitted to pre-sell our units, which may result in a delay in our profit making. Our business, results of operations and financial condition may be materially and adversely affected.
Measures on Property Price
According to Measures on Pre-sale Price Filing of Commodity Buildings of Shenzhen City promulgated by Market and Quality Supervision Commission of Shenzhen Municipality on June 25, 2011, as amended in May 2017, pre-sale price filing of Commodity Buildings refers to real estate enterprises' liability to inform competent department the sale price of the commodity buildings when a real estate enterprise intends to pre-sell a unit or the price adjustment is beyond the certain range of the recent filing price. A real estate enterprise should file the pre-sale price to the sub bureau of Quality Supervision Commission Shenzhen Municipality.
The government sets the ceiling price of commodity buildings. The pre-sale price of a certain property may not exceed the ceiling price. If a Real Estate Development Enterprise doesn't file pre-sale price to competent department or fails to file in a timely manner, then the enterprise would not be able to obtain the pre-sale permit to pre-sell commodity buildings.
Major Taxes Applicable to Property Developers
Land Appreciation Tax
Under the PRC Interim Regulation on Land Appreciation Tax of 1994 and its implementation rules of 1995, as amended in 2011, Land Appreciation Tax ("LAT") applies to both domestic and foreign investors in real properties in mainland China, irrespective of whether they are corporate entities or individuals. The tax is payable by a taxpayer on the appreciation value derived from the transfer of land use rights, buildings or other facilities on such land, after deducting the "deductible items" that include the following:
- payments made to acquire land use rights;- costs and charges incurred in connection with the land development;- construction costs and charges in the case of newly constructed buildings and facilities;- assessed value in the case of old buildings and facilities;- taxes paid or payable in connection with the transfer of the land use rights, buildings or other facilities on such land; and - other items allowed by the Ministry of Finance.
The tax rate is progressive and ranges from 30% to 60% of the appreciation value as compared to the "deductible items" as follows:
Appreciation value LAT rate Portion not exceeding 50% of deductible items 30% Portion over 50% but not more than 100% of deductible items 40% Portion over 100% but not more than 200% of deductible items 50% Portion over 200% of deductible items 60%
After the enactment of the LAT regulations and the implementation rules in 1994 and 1995, respectively, due to the long period of time typically required for real estate developments and their transfers, many jurisdictions, while implementing these regulations and rules, did not require real estate development enterprises to declare and pay the LAT as they did other taxes. Therefore, in order to assist the local tax authorities in the collection of LAT, the Ministry of Finance, State Administration of Taxation, Ministry of Construction and State Land Administration Bureau separately and jointly issued several notices to reiterate that, after the assignments are signed, the taxpayers should declare the tax to the local tax authorities where the real estate is located, and pay the LAT in accordance with the amount as calculated by the tax authority and within the time period as required. For those who fail to acquire proof as regards the tax paid or the tax exemption from the tax authorities, the real estate administration authority will not process the relevant title change procedures, and will not issue the property ownership certificates.
We will be subject to LAT if we choose to sell, instead of lease, our units.
Tax
The PRC Interim Regulation on Business Tax of 1994, as amended in December 2008, provided that business tax for PRC enterprises would be officially abolished by November 2017. The Detailed Implementation Rules of the Interim Regulation of the PRC on Business Tax issued and implemented by Ministry of Finance on December 25, 1993, and as amended on December 15, 2008 and October 28, 2011, although not officially abolished, are now deemed as no longer in effect.
Pursuant to the Circular on Comprehensively Promoting the Pilot Program of Replacing Business Tax with Value Added Tax which was promulgated by the Ministry of Finance and the State Administration of Taxation on March 23, 2016 and became effective on May 1, 2016, and further revised by The Notice on the Policy of Replacing Business Tax with Value Added Tax in Construction Services, which was implemented on July 1, 2017, the government will levy Valued Added Tax in lieu of business tax on a trial basis within the territory of the PRC, and any taxable activities of taxpayers shall be subject to a tax rate of 6% except for the taxpayer providing transportation, postal, telecom, construction, real estate leasing service, selling real estate, transferring land use right, leasing services of tangible personal property, and any cross-border taxable activity conducted by an entity or individual within the territory.
To provide services related to transportation, postal, telecom, construction, real estate leasing service, selling real estate and transferring land use right, the tax rate is 11%. To provide leasing services of tangible personal property, the tax rate is 17%. For any cross-border taxable activity conducted by an entity or individual within the territory, the tax rate is zero.
For the general taxpayers of real estate developers who sell the real estate projects (excluding the old real estate projects to which the simple tax calculation method is applicable) developed by them, the sales amount shall be the balance of the total price and other charges gained after the deduction of the land price paid to the government departments at the time of acceptance of the transferred land.
Pursuant to the Interim Measures on the Management of Value Added Tax of Self-developed Real Estate Project by the Sale of Real Estate Developers issued on March 31, 2016 and implemented on May 1, 2016 by State Administration of Taxation, in the event that a real estate developer recognized as an ordinary taxpayer sells a self-developed real estate project, the general tax calculation method shall be adopted, and the obtained total consideration and other charges after the deduction of the corresponding land price of the real estate project sold for the current period shall be the sales amount.
Corporate income tax
In 2007, the PRC government adopted the PRC Corporate Income Tax Law and the related implementation rules, which became effective on January 1, 2008 and was amended on February 24, 2017. Under the PRC Corporate Income Tax Law, a unified income tax rate of 25% is applied to all PRC enterprises, including foreign-invested enterprises. In addition, according to the Enterprise Income Tax Laws, dividends from PRC subsidiaries to their foreign corporate shareholders are subject to a withholding tax at a rate of 10% unless any lower treaty rate is applicable.
Urban Land Use Tax and Buildings Tax
Pursuant to the PRC Interim Regulations on Land Use Tax in respect of Urban Land promulgated by the State Council in September 1988, amended on December 31, 2006, January 8, 2011 and in December 2013, the land use tax in respect of urban land is levied according to the area of relevant land. The annual tax on urban land was between RMB0.6 and RMB30 per square meter.
Property Tax.
Under the PRC Interim Regulations on Property Tax promulgated by the State Council in September 1986, and amended on January 8, 2011, property tax applicable to domestic enterprises is 1.2% if it is calculated on the basis of the residual value of a building and 12% if it is calculated on the basis of the rental. On January 27, 2011, the governments of Shanghai and Chongqing respectively issued measures for implementing pilot individual property tax schemes which became effective on January 28, 2011.
According to the Notice on Issues Relating to Assessment of Buildings Tax against Foreign-invested Enterprises and Foreign Individuals issued by the Ministry of Finance and SAT in January 2009, the foreign-invested enterprises, foreign enterprises and foreign individuals are to be levied the same as domestic enterprise.
Stamp Duty
Under the PRC Interim Regulations on Stamp Duty promulgated by the State Council in August 1988, and amended on January 8, 2011, for property transfer instruments, including those in respect of property ownership transfers, the duty rate is 0.05% of the amount stated therein; for permits and certificates relating to rights, including property ownership certificates and land use rights certificates, stamp duty is levied on an item-by-item basis of RMB5 per item.
Municipal Maintenance Tax
Under the PRC Interim Regulations on Municipal Maintenance Tax promulgated by the State Council in 1985, and amended on January 8, 2011, any taxpayer, whether an individual or otherwise, of product tax, value-added tax or business tax is required to pay municipal maintenance tax calculated on the basis of product tax, value-added tax and business tax. The tax rate is 7% for a taxpayer whose domicile is in an urban area, 5% for a taxpayer whose domicile is in a county or a town, and 1% for a taxpayer whose domicile is not in any urban area or county or town.
According to the Circular Concerning Unification of Municipal Maintenance Tax and Education Surcharge for Foreign Investment and Domestic Enterprises and Individuals issued by State Council on October 18, 2010, the municipal maintenance tax is applicable to foreign invested enterprises, foreign enterprises and foreign individuals from December 1, 2010.
Education Surcharge
Under the Interim Provisions on Imposition of Education Surcharge promulgated by the State Council in April 1986 and amended on June 7, 1990, August 20, 2005 and January 8, 2011, any taxpayer, whether an individual or otherwise, of value-added tax, business tax or consumption tax is liable for an education surcharge, unless such taxpayer is required to pay a rural area education surcharge as provided by the Notice of the State Council on Raising Funds for Schools in Rural Areas. The Education Surcharge rate is 3% calculated on the basis of consumption tax, value-added tax and business tax. According to the Circular Concerning Unification of Municipal Maintenance Tax and Education Surcharge for Foreign Investment and Domestic Enterprises and Individuals issued by State Council on October 18, 2010, the education surcharge is applicable to foreign invested enterprises, foreign enterprises and foreign individuals from December 1, 2010.
Regulations on Property Management
The Property Management Rules, amended by the State Council on August 26, 2007 and effective as of October 1, 2007, as amended on February 6, 2016, provide that property owners have the right to appoint and dismiss property service enterprises. The rules also establish a regulatory system for property service enterprises, which encompasses the following regulations:
- the Measures for the Administration of Qualifications of Property Service Enterprises amended by the MOHURD and effective as of November 26, 2007, provide that property service enterprises must apply to the local branch of the MOHURD and undertake a qualification examination to obtain a Property Service Qualification Certificate. A property service enterprise must pass the Property Service Qualification, or PSQ examination, in order to engage in property management. Property service enterprises are classified as Class I, II or III. Different classes of service enterprises have different establishment requirements and may manage different types of premises.
- The Provisional Measures on the Administration of Initial Property Management Bid-inviting and Bidding, promulgated on June 26, 2003 by the MOHURD, provide that prior to the selection of the Property Owners' Committee, or the POC, the property developer must select a property service enterprise to provide property management services.
- the NDRC and the MOHURD jointly promulgated the Rules on Property Management Service Fees on November 13, 2003, which provide that property management fees shall be determined by mutual consent between the POC and the property service enterprise, and set forth in writing in the property management service contract.
Regulations on Construction Safety
Under relevant laws and regulations such as the Laws for Safe Production in the PRC promulgated by the Standing Committee of the National People's Congress in November 2002 and as amended on August 31, 2014, the property development enterprise should apply to the supervisory department on safety for the registration of supervision for work safety in construction before the commencement of construction. Constructions without such registration will not be granted a construction works commencement permit by the supervisory body. Contractors for the construction should establish the objectives and measures for work safety and improve the working environment and conditions of workers in a planned and systematic way. A work safety protection scheme should also be set up to carry out the work safety job responsibility system. At the same time, contractors should adopt corresponding site work safety protective measures according to the work protection requirements in different construction stages and such measures shall comply with the labor safety and hygiene standards of the State.
Under the Construction Law of the People's Republic of China, the construction contractor assumes responsibility for the safety of the construction site. The main contractor will take overall responsibility for the site, and the subcontractors are required to comply with the protective measures adopted by the main contractor.
Regulations on Environmental Protection in Construction Projects
Under the Regulations on the Administration of Environmental Protection in Construction Project, or Environmental Regulations, promulgated by the State Council on November 29, 1998 and effective as of the same date, as amended on July 16, 2017, each construction project is subject to an environmental impact assessment by the relevant authorities.
According to the Environmental Regulations, a developer is required to submit an environmental impact report, or an environmental impact report form, or an environmental impact registration form (as the case may be) to the relevant environmental protection administration for approval during the project's feasibility analysis stage. In the meantime, if any ancillary environmental protection facilities are necessary in the construction project, such facilities are required to be designed, constructed and used in conjunction with the main project. After completion of the project, the developers are required to apply to the relevant environmental protection administrations for final acceptance examination in respect of any ancillary environmental protection facilities. Construction projects are approved for use after passing the said acceptance examination.
The Environmental Impact Assessment Law, promulgated by the National People's Congress on October 28, 2002 and effective as of September 1, 2003, as amended on July 2, 2016, provides that if the environmental impact assessment documents of a construction project have not been examined by the relevant environmental protection administrations or are not approved after examination, the authority in charge of examination and approval of the project may not approve construction on the project, and the construction work unit may not commence work.
On July 6, 2006, the State Environmental Protection Administration issued its Circular on Strengthening the Environmental Protection Examination and Approval and Strictly Controlling New Construction Project, which provides for stringent examination and approval procedures for various real estate development projects. It also stipulates that no approvals may be issued for new residential projects or extensions in industry development zones, areas impacted by industrial enterprises or areas where such development poses potential harm to residents' health
Pursuant to the requirements of relevant laws and regulations such as the Appraisal Measures for the Impact on the Environment of the PRC implemented by the Standing Committee of the National People's Congress in September 2003 and amended on July 2, 2016, and the Regulations Governing Environmental Protection of Construction Projects amended by the State Council in July, 2017, property development enterprises and construction enterprises must carry out an appraisal of the impact the construction project will have on the environment. The relevant project shall not commence until approval is obtained from the supervisory body for environmental protection. While the project is in progress, the developer should also comply with the appraisal documents relating to the impact on the environment and implement the environmental protection measures set out in the opinion of the supervisory body for environmental protection. Such measures must be incorporated into the design, construction and operation of the general construction. Upon completion of the project, the developer should apply to the supervisory body for environmental protection for the inspection and acceptance of the completed environmental protection facilities. Only those projects that have been inspected and accepted may go into operation or be available for use.
Insurance
There is no mandatory provision under the PRC laws, regulations and government rules which require a property developer to take out insurance policies for its real estate developments. According to the common practice of the property industry in China, construction companies are usually required to submit insurance proposals in the course of tendering and bidding for construction projects. Construction companies must pay for the insurance premium at their own costs and take out insurance to cover their liabilities, such as third party's liability risk, employer's liability risk, risk of non-performance of contract in the course of construction and other kinds of risks associated with the construction and installation works throughout the construction period. The insurance coverage for all these risks will cease immediately after the completion and acceptance upon inspection of construction.
Litigation & Legal Liabilities3 | 6.4%
Litigation & Legal Liabilities - Risk 1
It may be difficult to serve us with legal process or enforce judgments against our management or us.
We are a British Virgin Islands holding corporation with subsidiaries in Hong Kong and China. Substantially, all of our assets are located in the PRC. In addition, most of our directors and executive officers reside within the PRC or Hong Kong, and substantially all of the assets of these persons are located within the PRC or Hong Kong. It may not be possible to affect service of process within the United States or elsewhere outside the PRC or Hong Kong upon our directors, or executive officers, including effecting service of process with respect to matters arising under United States federal securities laws or applicable state securities laws. The PRC does not have treaties providing for the reciprocal recognition and enforcement of judgments of courts with the United States and many other countries. As a result, recognition and enforcement in the PRC of judgments of a court in the United States or many other jurisdictions in relation to any matter, including securities laws, may be difficult or impossible. An original action may be brought against our assets and our subsidiaries, our directors and executive officers in the PRC only if the actions are not required to be arbitrated by PRC law and only if the facts alleged in the complaint give rise to a cause of action under PRC law. In connection with any such original action, a PRC court may award civil liability, including monetary damages.
No treaty exists between Hong Kong or the British Virgin Islands and the United States providing for the reciprocal enforcement of foreign judgments. However, the courts of Hong Kong and the British Virgin Islands are generally prepared to accept a foreign judgment as evidence of a debt due. An action may then be commenced in Hong Kong or the British Virgin Islands for recovery of this debt. A Hong Kong or British Virgin Islands court will only accept a foreign judgment as evidence of a debt due if:
- the judgment is for a liquidated amount in a civil matter;- the judgment is final and conclusive;- the judgment is not, directly or indirectly, for the payment of foreign taxes, penalties, fines or charges of a like nature (in this regard, a Hong Kong court is unlikely to accept a judgment for an amount obtained by doubling, trebling or otherwise multiplying a sum assessed as compensation for the loss or damage sustained by the person in whose favor the judgment was given);- the judgment was not obtained by actual or constructive fraud or duress;- the foreign court has taken jurisdiction on grounds that are recognized by the common law rules as to conflict of laws in Hong Kong or the British Virgin Islands;- the proceedings in which the judgment was obtained were not contrary to natural justice (i.e. the concept of fair adjudication);- the proceedings in which the judgment was obtained, the judgment itself and the enforcement of the judgment are not contrary to the public policy of Hong Kong or the British Virgin Islands;- the person against whom the judgment is given is subject to the jurisdiction of a foreign court; and - the judgment is not on a claim for contribution in respect of damages awarded by a judgment, which fall under Section 7 of the Protection of Trading Interests Ordinance, Chapter 7 of the Laws of Hong Kong.
Enforcement of a foreign judgment in the PRC, Hong Kong or the British Virgin Islands may also be limited or affected by applicable bankruptcy, insolvency, liquidation, arrangement and moratorium, or similar laws relating to or affecting creditors' rights generally, and will be subject to a statutory limitation of time within which proceedings may be brought.
Litigation & Legal Liabilities - Risk 2
Added
Failure to comply with the United States Foreign Corrupt Practices Act could subject us to penalties and other adverse consequences.
As an NYSE listed company, we are subject to the United States Foreign Corrupt Practices Act, which generally prohibits United States companies from engaging in bribery or other prohibited payments to foreign officials for the purpose of obtaining or retaining business. Foreign companies, including some that may compete with us, may not be subject to these prohibitions. Corruption, extortion, bribery, pay-offs, theft and other fraudulent practices occur from time-to-time in the PRC. We can make no assurance, however, that our employees or other agents will not engage in such conduct for which we may be held responsible. If our employees or other agents are found to have engaged in such practices, we could suffer severe penalties and other consequences that may have a material adverse effect on our business, financial condition and results of operations.
Litigation & Legal Liabilities - Risk 3
Added
We face litigation risks and regulatory disputes in the course of our business.
In the ordinary course of our business, claims and disputes involving project owners, customers, labor subcontractors, suppliers, business partners and regulatory authorities may be brought against us and by us in connection with our contracts or business. Claims may be brought against us for alleged defective or incomplete work, liabilities for defective products, related personal injuries and death, damage to or destruction of property, breaches of warranty and late completion of the project, as well as claims relating to taxes, among others. Such claims can involve actual damages and liquidated damages. If found to be liable, we would have to incur a charge against earnings to the extent a reserve had not been established for the matter in our accounts, or to the extent the claims were not sufficiently covered by our insurance. Claims between us and our labor subcontractors and vendors may include claims similar to those described above. We may also engage in disputes with regulatory authorities on tax-related matters in connection with our business and operations. Both claims brought against us and by us, if not resolved through negotiation, are often subject to lengthy and expensive litigation or arbitration proceedings such that the amounts ultimately realized from claims by us could differ from the balances included in our consolidated financial statements. Such claims could therefore have an adverse impact on our business, financial condition and results of operations.
Taxation & Government Incentives3 | 6.4%
Taxation & Government Incentives - Risk 1
Added
We face uncertainty from the Circular on Strengthening the Administration of Enterprise Income Tax on Non-resident Enterprises' Share Transfer ("Circular 698") released in December 2009 by China's State Administration of Taxation (SAT), effective as of January 1, 2008.
Where a foreign investor indirectly transfers equity interests in a PRC resident enterprise by selling the shares in an offshore holding company, and the latter is located in a country or jurisdiction where the effective tax burden is less than 12.5% or where the offshore income of its residents is not taxable, the foreign investor is required to provide the tax authority in charge of that PRC resident enterprise with the relevant information within 30 days of any such transfer.
Where a foreign investor indirectly transfers equity interests in a PRC resident enterprise through the abuse of form of organization and there are no reasonable commercial purposes such that the corporate income tax liability is avoided, the tax authority has the power to re-assess the nature of the equity transfer in accordance with the "substance-over-form" principle and deny the existence of the offshore holding company that is used for tax planning purposes. "Income derived from equity transfers" as mentioned in Circular 698 refers to income derived by non-resident enterprises from direct or indirect transfers of equity interest in the PRC resident enterprises, excluding share in the PRC resident enterprises that are bought and sold openly on the stock exchange.
While the term "indirectly transfer" is not defined, we understand that the relevant PRC tax authorities have jurisdiction regarding requests for information over a wide range of foreign entities having no direct contact with the PRC. The relevant authority has not yet promulgated any formal provisions or formally declared or stated how to calculate the effective tax in the relevant country or jurisdiction, and the process of the disclosure to the tax authority in charge of that PRC resident enterprise. Meanwhile, there are no formal declarations with regard to how to decide "abuse of form of organization" and "reasonable commercial purpose," which can be utilized by us to determine if our company complies with the Circular 698.
Taxation & Government Incentives - Risk 2
Changed
We believe we were a passive foreign investment company for 2017 and we may be a passive foreign investment company for 2018, which could result in adverse U.S. federal income tax consequences for U.S. investors.
The determination of whether we are a passive foreign investment company, or PFIC, in any taxable year is made on an annual basis after the close of that year and depends on the composition of our income and the nature and value of our assets, including goodwill. Specifically, we will be classified as a PFIC if, after applying relevant look-through rules with respect to the income and assets of subsidiaries, either (i) 75% or more of our gross income for such taxable year is passive income (the "PFIC income test"), or (ii) 50% or more of the value of our assets (based on an average of the quarterly values of the assets during such year) are passive assets, which generally means that they either produce passive income or are held for the production of passive income (the "PFIC asset test").
Although not free from doubt, we believe we were a PFIC for U.S. federal income tax purposes for 2017. The PFIC asset test requires a determination of the fair market value of each asset and a determination of whether such asset produces or is held for the production of passive income and involves complex legal issues. We have not made a determination of the fair market value of our assets for 2017 and do not plan to do so for 2018, and we cannot anticipate our market capitalization for 2018. Accordingly, we may be treated as a PFIC for 2017 under the PFIC asset test, or under the PFIC income test, or both. Our characterization as a PFIC during any year could result in adverse U.S. federal income tax consequences for U.S. investors. For example, if we were a PFIC in 2017 or in any other taxable year, U.S. investors who owned our common shares during such year generally would be subject to increased U.S. tax liabilities and reporting requirements.
Given the complexity of the issues regarding our classification as a PFIC, U.S. investors are urged to consult their own tax advisors for guidance as to our PFIC status. For further discussion of the adverse U.S. federal income tax consequences arising from the classification as a PFIC see "Taxation-United States Federal Income Tax Consequences" beginning on page 65 of this Report.
Taxation & Government Incentives - Risk 3
Changes to PRC tax laws and heightened efforts by the PRC tax authorities to increase revenues have subjected us to greater taxes.
Under PRC law before 2008, we were afforded a number of tax concessions by, and tax refunds from, PRC tax authorities on a substantial portion of our operations in China by reinvesting all or part of the profits attributable to our PRC manufacturing operations. However, on March 16, 2007, the PRC government enacted a unified enterprise income tax law or EIT, which became effective on January 1, 2008. Prior to the EIT, as a foreign invested enterprise, or "FIE", located in Shenzhen, China, our PRC subsidiaries enjoyed a national income tax rate of 15% and were exempted from the 3% local income tax. The preferential tax treatment given to our subsidiaries in the PRC as a result of reinvesting their profits earned in previous years in the PRC also expired on January 1, 2008. Under the EIT, most domestic enterprises and FIEs are subject to a single PRC enterprise income tax rate of 25% from 2012 onwards. For information on the EIT rates as announced by the PRC's State Council for the transition period until year 2013, please see the table in ITEM 5. Operating and Financial Review and Prospects on page 40 of this Report.
We base our tax position upon the anticipated nature and conduct of our business and upon our understanding of the tax laws of the various administrative regions and countries in which we have assets or conduct activities; however, our tax position is subject to review and possible challenge by taxing authorities and to possible changes in law, which may have retroactive effect. According to Circular of the State Administration of Taxation on Issues Related to the End of Various Preferential Tax Policies for Foreign and Foreign-Invested Enterprises (STA [2008] No. 23) published by the State Administration of Taxation of the PRC) on February 27, 2008, a FIE may be required to pay back the taxes previously exempted as a result of the preferential tax treatment enjoyed in accordance with the Income Tax Law of People's Republic of China for Foreign Investment Enterprises and Foreign Enterprise, if such FIE no longer meets the conditions for preferential tax treatment after 2008 due to a change in its nature of business or if the term of its business operation is determined to be less than ten years since its inception. As we have ceased our production operations at all of our manufacturing facilities and are switching our core business to property development and management, our tax position may be subject to review by relevant tax authorities, and we cannot determine in advance whether, or the extent to which, such tax policy may require us to pay taxes or make payments in lieu of taxes.
Environmental / Social1 | 2.1%
Environmental / Social - Risk 1
Added
We are subject to potential environmental liability.
We are subject to a variety of laws and regulations concerning the protection of health and the environment. The particular environmental laws and regulations that apply to any given development site vary significantly according to the site's location and environmental condition, the present and former uses of the site and the nature of the adjoining properties. Environmental laws and conditions may result in delays, may cause us to incur substantial compliance and other costs and can prohibit or severely restrict project development activity in environmentally-sensitive regions or areas. Although we have received environmental assessments by the local PRC environmental to proceed with our projects, it is possible that these reviews did not reveal all environmental liabilities.
We also cannot assure you that the PRC government will not change the existing laws and regulations or impose additional or stricter laws or regulations, the compliance of which may cause us to incur significant capital expenditure.
Production
Total Risks: 7/47 (15%)Above Sector Average
Manufacturing3 | 6.4%
Manufacturing - Risk 1
Added
The property development business is subject to claims under statutory quality warranties.
Under PRC law, all property developers in the PRC must provide certain quality warranties for the properties they construct or sell. We will be required to provide these warranties to our tenants and customers. Generally, we receive quality warranties from our third-party contractors with respect to our property projects. If a significant number of claims were brought against us under our warranties and if we were unable to obtain reimbursement for such claims from third-party contractors in a timely manner or at all, or if the money retained by us to cover our payment obligations under the quality warranties was not sufficient, we could incur significant expenses to resolve such claims or face delays in remedying the related defects, which could in turn harm our reputation, and materially adversely affect our business, financial condition and results of operations.
Manufacturing - Risk 2
Added
Injury or damages to third parties may arise from construction accidents.
Risk related to injuries or damages to third parties arising from construction accidents is inherent in our business. As a policy, we require and uphold high construction safety standards within our project construction teams, in line with those set by reputable industry organizations in China. We also hold ourselves to the highest applicable safety standards and ensure all of our personnel, and require all of our subcontractors' personnel to, comply with such safety standards through consistent training, supervision and monitoring. Notwithstanding the foregoing, third parties may claim for damages from us in the event of accidents during construction, resulting in higher costs of construction. We cannot assure you that such injuries or damages to third parties and subsequent claim for damages would not occur. Although we require our subcontractors to comply with our safety and health policies in our contracts, we cannot assure you that our subcontractors will adhere to these safety provisions at all times. We may also be subject to claims from customers or other third parties, resulting from the subsequent use of facilities and products we have constructed. If we fail to adequately protect ourselves or third parties against these potential liabilities, we could incur substantial costs, which could have an adverse effect on our business, financial condition and results of operations. Furthermore, any harm caused to third parties due to our operations could damage our reputation and relationship with regulators and other customers, which may hinder our chances to win tenders for new projects.
Manufacturing - Risk 3
We may be unable to complete our property developments on time or at all.
The progress and costs for a development project can be adversely affected by many factors, including, without limitation:
- delays in obtaining necessary licenses, certificates, permits or approvals from government agencies or authorities;- shortage of materials, equipment, contractors and skilled labor or increased labor or raw material costs;- failure by our third-party contractors to comply with our designs, specifications or standards;- onsite labor disputes or work accidents; and - natural catastrophes or adverse weather conditions, including strong winds, storms, floods, and earthquakes.
Any construction delays, or failure to complete a project according to our planned specifications or budget, may delay our property leasing timetable, which could adversely affect our revenues, cash flows and our reputation. We may also be penalized if we fail to complete our projects on time as agreed with the local planning activities.
Employment / Personnel1 | 2.1%
Employment / Personnel - Risk 1
Added
We rely on the support of our key management members and Kaisa.
We have begun certain strategic cooperation with Kaisa, including hiring a number of engineers and real estate professionals from Kaisa to join the Company as officers and employees, as well as appointed one of Kaisa's founders, Mr. Ying Chi Kwok, as an Executive Director and Chief Executive Officer of our Company together with other Kaisa affiliates Ms. Yu Zhang as our Chief Financial Officer and Ms. Xiaoxia (Shirley) Yin as our Project Director. We also expect to continue to consult with Kaisa from time to time, leveraging Kaisa's knowledge and experience in the areas of construction and real estate development. We depend on the services provided by these key management members that have pre-existing affiliation with Kaisa. Competition for management talent is intense in the property development sector in the PRC. In particular, we are highly dependent on Mr. Kwok Ying Chi, our Executive Director and Chief Executive Officer. We do not maintain key employee insurance. In the event that we lose the services of any key management member, we may be unable to identify and recruit suitable successors, from Kaisa or elsewhere, in a timely manner or at all, which will adversely affect our business and operations. If we cannot attract and retain suitable human resources, especially at the management level, our business and ability to complete our projects on time and within budget may be adversely affected.
Supply Chain1 | 2.1%
Supply Chain - Risk 1
Added
We rely on third-party contractors.
Substantially all of our project construction and related work are outsourced to third-party contractors. We are exposed to risks that the performance of our contractors may not meet our level of standards or specifications. Negligence, delay or poor work quality by contractors may result in defects in our buildings or residential units, which could in turn cause us to suffer financial losses, harm our reputation or expose us to third-party claims. If the performance of any third party contractor is not satisfactory or is delayed, we may need to replace such contractor or take other actions to remedy the situation, which could adversely affect the cost and construction progress of our projects. Moreover, the completion of our property developments may be delayed. Although our construction and other contracts contain provisions designed to protect us, we may be unable to successfully enforce these rights and, even if we are able to successfully enforce these rights, the third-party contractors may not have sufficient financial resources to compensate us. Moreover, the contractors may undertake projects from other property developers engage in risky undertakings or encounter financial or other difficulties, such as supply shortages, labor disputes or work accidents, which may cause delays in the completion of our property projects or increases in our costs.
Costs2 | 4.3%
Costs - Risk 1
Added
Damage to or other potential losses involving, our assets and business may not be covered by insurance
We face risks in our transition to the property development and management business. We maintain comprehensive property and liability insurance policies with coverage features and insured limits that we believe are consistent with market practice in the real estate industry in Shenzhen, China. Nonetheless, the scope of insurance coverage that we can obtain, or our ability to obtain such coverage at commercially reasonable rates, may be limited. In addition, our contractors may not be sufficiently insured themselves or have the financial ability to absorb any losses that arise with respect to our projects or pay our claims. Moreover, there are certain types of losses, which are currently uninsurable in China. While we believe that our practice is in line with the general practice in the PRC property development industry, there may be instances when we will have to internalize losses, damages and liabilities because of the lack of insurance coverage, which may in turn adversely affect our financial condition and results of operations. Furthermore, we generally do not maintain any business disruption insurance policies. As such, certain types of losses, generally of an unforeseen or catastrophic nature, such as fires, natural disasters, terrorist acts, the outbreak of infectious disease or any resulting losses causing disruptions to our business operations, may be uninsurable, or the required insurance premiums may be too expensive to justify obtaining insurance. In the event of a substantial loss, the insurance coverage we carry may not cover our damages, or be sufficient to pay the full market value or the replacement cost of our lost investment.
If we suffer any uninsured losses, damages or liabilities in the course of our business operations, we may not have sufficient funds to cover any such losses, damages or liabilities. Accordingly, we could lose some or all of the capital we have invested in a building or piece of land, as well as the anticipated future revenue from that building or piece of land. To the extent that we suffer losses or damages as a result of a risk for which we do not maintain insurance, or which is not covered by our insurance policies, or where the cost of the losses or damages exceeds our insurance coverage, we will have to bear such costs, which could have a material adverse effect on our business, financial results of operations and condition.
Costs - Risk 2
Increases in the price of raw materials or labor costs and the fluctuation of real estate prices in China, generally, and in Shenzhen, particularly, may increase our cost of sales and reduce our revenues and earnings.
We depend on our suppliers to provide us with sufficient quantities of raw materials such as steel, cement, sand, ballast and timber at acceptable prices and in a timely manner. As we are a new comer to the real estate development industry, we do not have long-term relationships with these suppliers and typically engage them only on a per project basis. Our project-specific supply contracts usually last only as long as the life of the individual project and we have not identified any other project for development beyond Nam Tai Inno Park and Nam Tai Inno City. As such, during times of short supply or price hikes, we may have to pay significantly higher prices to obtain sufficient raw materials or locate alternative suppliers. We have not entered into any raw materials hedging contracts. We also need raw materials of acceptable quality to maintain the quality of our work. Any failure to obtain adequate raw materials, or failure to do so on commercially acceptable terms and in a timely manner, could interfere with our operations and adversely affect the results of our operations. Our future revenues and earnings from leasing or selling properties are subject to the fluctuation of the real estate prices in China, particularly in Shenzhen. We may encounter substantial cost increases, cost overruns or delays in connection with the future development of our projects.
Ability to Sell
Total Risks: 3/47 (6%)Below Sector Average
Competition2 | 4.3%
Competition - Risk 1
We may not be able to compete successfully against our current or future competitors.
Some of our current and future competitors have competitive advantages over us, including more well-known brands, new and different business models, lower cost, larger customer bases, more experience in real estate development and greater financial, marketing, technology, human resources, and other expertise and resources. We cannot assure that we will always be able to successfully compete against our current or future competitors. If we are unable to compete successfully with our current or future competitors, our business, financial condition and results of operations could be adversely affected.
Competition - Risk 2
Added
We face competition from developers in close proximity.
As we seek to grow our real estate portfolio by developing more of our own projects, including Nam Tai Inno Park and Nam Tai Inno City, income from these projects will become an increasingly important contributor to our revenue going forward. The success of our sales and leasing strategies for our properties, however, is not assured. An increase in the number of competing properties by developers in close proximity could increase competition for purchasers and tenants, and force us to reduce rent or sale prices or incur additional costs to make our properties more attractive. Moreover, competition among real estate developers may result in an increase in costs or a shortage of raw materials, an oversupply of properties, an inability to sell such properties, or an increase in administrative costs for hiring or retaining qualified personnel, any of which may adversely affect our business, financial condition and results of operations. If we cannot remain competitive against other property developers in the areas in which our properties are situated, our profitability and prospects could be adversely affected.
Demand1 | 2.1%
Demand - Risk 1
Added
Our business is largely affected by the general level of activity and growth in Shenzhen, China.
We mainly operate in the city of Shenzhen, China, and as a result, the continuous growth and development of Shenzhen and the surrounding Pearl River Delta are paramount to our business and future prospects. The infrastructure development of Shenzhen city is implemented in accordance with a city development plan that is subject to change from time to time. We have little or no influence over the development plan of the area. We cannot assure you that the infrastructure development plan will be effectively carried out as contemplated, or that the vision of Shenzhen city as the next technological development center in China will eventually be realized. Completion of the ongoing public transport infrastructure projects expected to benefit the development of Shenzhen city may be substantially delayed, or future planned infrastructure projects may be postponed indefinitely or cancelled. We cannot assure you that the drivers expected to facilitate Shenzhen's development and also underlie our business strategies may eventually materialize, such as the continuous growth of the research and development business that is expected to increase the demand for our space, once operational. Many other factors can also affect the development of Shenzhen, including the state of the national and regional economies in China, changes in government policies leading to changes in market conditions, and political and social developments that may translate into project execution difficulties. In the event that our Nam Tai Inno Park and Nam Tai Inno City projects do not develop as we planned and envisioned, there will be material and adverse effect on our business and prospects.
Macro & Political
Total Risks: 3/47 (6%)Below Sector Average
Economy & Political Environment1 | 2.1%
Economy & Political Environment - Risk 1
A slow-down of economic growth in China may adversely affect our growth and financial performance.
Our business is sensitive to the current China economic downturn. In recent years, the PRC economy has seen a slowdown related to the international financial crisis in 2008, and a slower growth since then. For 2018, China's economic conditions remain uncertain and unpredictable. With the government lowering economic growth targets, there are forecasts predicting a further significant slowdown.
The PRC economy also faces challenges in the short to medium term. Continued turbulence in the international markets and prolonged declines in consumer spending as well as the slowdown of economic growth in China may adversely affect our liquidity and financial condition, and significantly affect the demand for our commercial and residential units. A widespread change in spending habits may also lead to tighter credit markets, drops in business and consumer confidence and dramatic changes in business and consumer behaviors. In response to the perceived uncertainty in China's economic conditions, commercial tenants could delay,reduce or cancel rental of office space, and homebuyers could also defer, reduce or cancel purchases of residential units, and thereby adversely affect our results of operations.
Natural and Human Disruptions1 | 2.1%
Natural and Human Disruptions - Risk 1
Added
Our construction business, financial condition and results of operations may be affected by adverse weather conditions and natural disasters.
Adverse weather conditions, such as typhoons, flooding and heavy or sustained rainfall and natural disasters such as earthquakes, landslides or mudslides, may prevent us from conducting our construction activities or otherwise affect our productivity, preventing us from completing our project development on schedule, delaying our receipt of payment and possibly causing us to incur increased operating expenses. Unusually severe, intense or non-seasonal weather conditions could therefore have an adverse effect on our business, financial condition and results of operations.
Capital Markets1 | 2.1%
Capital Markets - Risk 1
Changes in currency exchange rates involving the RMB had and could continue to significantly affect our financial results.
For 2014 and earlier, our functional currencies were U.S. dollars and Hong Kong dollars. Our financial results were affected by currency fluctuations, resulting in total foreign exchange gains and losses. Effective from April 1, 2015, the Company's subsidiaries in China changed their functional currency from the U.S. dollar to the Renminbi. This change was made due to the progress of our property development projects in China, which caused our subsidiaries' primary operating activities to be transacted in Renminbi and these entities to primarily generate and expend cash in Renminbi.
As the majority of our assets and our primary operating activities are denominated in Renminbi, the translation of Renminbi-denominated assets to U.S. dollar for our reporting purposes can resulted in a foreign exchange loss. We expect to continue to see fluctuations in the reporting of foreign exchange loss/gain in the financial statements due to the movement of Renminbi against the U.S. dollar. The fluctuation of foreign exchange rate will affect the amount for translation the financial statement in function currency to reporting currency and the impact was recorded in other comprehensive income (loss) in the equity.
Tech & Innovation
Total Risks: 1/47 (2%)Below Sector Average
Innovation / R&D1 | 2.1%
Innovation / R&D - Risk 1
Added
Our timely and cost-effective development of projects is dependent on various factors outside of our control.
Our future financial performance may be significantly affected by factors outside of our control that limit our ability to successfully finance and complete current and future projects, including construction and real estate development projects, in a cost-effective manner. We may invest significant resources in a project that might not be commercially viable due to changes in government policies. We might not obtain governmental approvals and permits within the necessary time limits, and projects might not be completed on schedule and within budget. Project development and construction may also be adversely affected by many other factors, including shortages of materials, machinery malfunction, labor disputes involving us or our subcontractors, construction accidents, adverse weather conditions, RMB value depreciation, natural disasters, changes in laws, government policies or priorities and other unforeseen problems or circumstances that we might not have control over. Any of these factors could result in planned projects being delayed or cancelled or current projects being delayed or incurring cost overruns, which may adversely affect our margins. This may also result in sales and resulting profits from a particular development not being recognized in the year originally expected, which could adversely affect our results of operations for that year. Further, our failure to complete the construction of a project in accordance with the planned specifications or on schedule may result in contractual liabilities to purchasers and lower returns. The occurrence of any such events may adversely affect our business, financial condition and results of operations.
See a full breakdown of risk according to category and subcategory. The list starts with the category with the most risk. Click on subcategories to read relevant extracts from the most recent report.
FAQ
What are “Risk Factors”?
Risk factors are any situations or occurrences that could make investing in a company risky.
The Securities and Exchange Commission (SEC) requires that publicly traded companies disclose their most significant risk factors. This is so that potential investors can consider any risks before they make an investment.
They also offer companies protection, as a company can use risk factors as liability protection. This could happen if a company underperforms and investors take legal action as a result.
It is worth noting that smaller companies, that is those with a public float of under $75 million on the last business day, do not have to include risk factors in their 10-K and 10-Q forms, although some may choose to do so.
How do companies disclose their risk factors?
Publicly traded companies initially disclose their risk factors to the SEC through their S-1 filings as part of the IPO process.
Additionally, companies must provide a complete list of risk factors in their Annual Reports (Form 10-K) or (Form 20-F) for “foreign private issuers”.
Quarterly Reports also include a section on risk factors (Form 10-Q) where companies are only required to update any changes since the previous report.
According to the SEC, risk factors should be reported concisely, logically and in “plain English” so investors can understand them.
How can I use TipRanks risk factors in my stock research?
Use the Risk Factors tab to get data about the risk factors of any company in which you are considering investing.
You can easily see the most significant risks a company is facing. Additionally, you can find out which risk factors a company has added, removed or adjusted since its previous disclosure. You can also see how a company’s risk factors compare to others in its sector.
Without reading company reports or participating in conference calls, you would most likely not have access to this sort of information, which is usually not included in press releases or other public announcements.
A simplified analysis of risk factors is unique to TipRanks.
What are all the risk factor categories?
TipRanks has identified 6 major categories of risk factors and a number of subcategories for each. You can see how these categories are broken down in the list below.
1. Financial & Corporate
Accounting & Financial Operations - risks related to accounting loss, value of intangible assets, financial statements, value of intangible assets, financial reporting, estimates, guidance, company profitability, dividends, fluctuating results.
Share Price & Shareholder Rights – risks related to things that impact share prices and the rights of shareholders, including analyst ratings, major shareholder activity, trade volatility, liquidity of shares, anti-takeover provisions, international listing, dual listing.
Debt & Financing – risks related to debt, funding, financing and interest rates, financial investments.
Corporate Activity and Growth – risks related to restructuring, M&As, joint ventures, execution of corporate strategy, strategic alliances.
2. Legal & Regulatory
Litigation and Legal Liabilities – risks related to litigation/ lawsuits against the company.
Regulation – risks related to compliance, GDPR, and new legislation.
Environmental / Social – risks related to environmental regulation and to data privacy.
Taxation & Government Incentives – risks related to taxation and changes in government incentives.
3. Production
Costs – risks related to costs of production including commodity prices, future contracts, inventory.
Supply Chain – risks related to the company’s suppliers.
Manufacturing – risks related to the company’s manufacturing process including product quality and product recalls.
Human Capital – risks related to recruitment, training and retention of key employees, employee relationships & unions labor disputes, pension, and post retirement benefits, medical, health and welfare benefits, employee misconduct, employee litigation.
4. Technology & Innovation
Innovation / R&D – risks related to innovation and new product development.
Technology – risks related to the company’s reliance on technology.
Cyber Security – risks related to securing the company’s digital assets and from cyber attacks.
Trade Secrets & Patents – risks related to the company’s ability to protect its intellectual property and to infringement claims against the company as well as piracy and unlicensed copying.
5. Ability to Sell
Demand – risks related to the demand of the company’s goods and services including seasonality, reliance on key customers.
Competition – risks related to the company’s competition including substitutes.
Sales & Marketing – risks related to sales, marketing, and distribution channels, pricing, and market penetration.
Brand & Reputation – risks related to the company’s brand and reputation.
6. Macro & Political
Economy & Political Environment – risks related to changes in economic and political conditions.
Natural and Human Disruptions – risks related to catastrophes, floods, storms, terror, earthquakes, coronavirus pandemic/COVID-19.
International Operations – risks related to the global nature of the company.
Capital Markets – risks related to exchange rates and trade, cryptocurrency.