tiprankstipranks
Companhia Energetica Minas Gerais (CIG)
:CIG
US Market

Companhia Energetica Minas Gerais (CIG) Risk Analysis

Compare
503 Followers
Public companies are required to disclose risks that can affect the business and impact the stock. These disclosures are known as “Risk Factors”. Companies disclose these risks in their yearly (Form 10-K), quarterly earnings (Form 10-Q), or “foreign private issuer” reports (Form 20-F). Risk factors show the challenges a company faces. Investors can consider the worst-case scenarios before making an investment. TipRanks’ Risk Analysis categorizes risks based on proprietary classification algorithms and machine learning.

Companhia Energetica Minas Gerais disclosed 60 risk factors in its most recent earnings report. Companhia Energetica Minas Gerais reported the most risks in the “Finance & Corporate” category.

Risk Overview Q4, 2022

Risk Distribution
60Risks
30% Finance & Corporate
25% Legal & Regulatory
22% Production
17% Macro & Political
3% Tech & Innovation
3% Ability to Sell
Finance & Corporate - Financial and accounting risks. Risks related to the execution of corporate activity and strategy
This chart displays the stock's most recent risk distribution according to category. TipRanks has identified 6 major categories: Finance & corporate, legal & regulatory, macro & political, production, tech & innovation, and ability to sell.

Risk Change Over Time

2022
Q4
S&P500 Average
Sector Average
Risks removed
Risks added
Risks changed
Companhia Energetica Minas Gerais Risk Factors
New Risk (0)
Risk Changed (0)
Risk Removed (0)
No changes from previous report
The chart shows the number of risks a company has disclosed. You can compare this to the sector average or S&P 500 average.

The quarters shown in the chart are according to the calendar year (January to December). Businesses set their own financial calendar, known as a fiscal year. For example, Walmart ends their financial year at the end of January to accommodate the holiday season.

Risk Highlights Q4, 2022

Main Risk Category
Finance & Corporate
With 18 Risks
Finance & Corporate
With 18 Risks
Number of Disclosed Risks
60
-10
From last report
S&P 500 Average: 31
60
-10
From last report
S&P 500 Average: 31
Recent Changes
3Risks added
13Risks removed
8Risks changed
Since Dec 2022
3Risks added
13Risks removed
8Risks changed
Since Dec 2022
Number of Risk Changed
8
-9
From last report
S&P 500 Average: 2
8
-9
From last report
S&P 500 Average: 2
See the risk highlights of Companhia Energetica Minas Gerais in the last period.

Risk Word Cloud

The most common phrases about risk factors from the most recent report. Larger texts indicate more widely used phrases.

Risk Factors Full Breakdown - Total Risks 60

Finance & Corporate
Total Risks: 18/60 (30%)Above Sector Average
Share Price & Shareholder Rights11 | 18.3%
Share Price & Shareholder Rights - Risk 1
We are controlled by the government of the State of Minas Gerais, which might have interests that are different from the interests of our other investors, or even of the Company.
As our controlling shareholder, the government of the State of Minas Gerais exercises substantial influence on the strategic orientation of our business. Currently it holds 51% of the common shares of CEMIG and as majority shareholder has full powers to decide on business relating to the Company's objects as stated in the by-laws, and to adopt whatever decisions it deems to be necessary for the defense of its interests and development. The government of the State of Minas Gerais can elect the majority of our senior management and has the authority to approve, among other subjects, matters that require a qualified quorum of shareholders. The latter include transactions with related parties, shareholding reorganizations and the date and payment of dividends. The government of the State of Minas Gerais, as our controlling shareholder, has the capacity to direct us to engage in activities and to make investments that promote the controlling shareholder's economic or social objectives, and these might not be strictly aligned with the Company's strategy or the strategies of our other shareholders, adversely affecting the direction of our business.
Share Price & Shareholder Rights - Risk 2
Our processes of governance, risk management, compliance and internal controls might fail to avoid regulatory penalties, damages to our reputation, or other adverse effects on our business, results of operations or financial condition.
Our Company is subject to various different regulatory structures, of which the following are examples: (a) laws and regulations of the Brazilian energy sector, such as Law 10,848/04 (on trading in energy) and regulations by ANEEL; (b) the laws and regulations that apply to listed companies with securities traded in the Brazilian capital markets, such as Law 6,404/76 (the ‘Corporate Law') and regulations of the CVM; (c) laws and regulations that apply to Brazilian companies with majority state-owned shareholdings, such as Law 13,303/2016 (the ‘State Companies Law'); (d) laws and regulations that apply to Brazilian companies that have securities registered with the SEC, such as the Sarbanes-Oxley Act of 2002, the Foreign Corrupt Practices Act (FCPA) and regulations of the SEC; and (e) laws and regulations regarding privacy and data protection, such as Law 13,709/2018 (the ‘General Data Protection Law, LGPD'), among others. Furthermore, Brazil has rigorous legislation relating to maintaining competition, combat of improbity and preventing corrupt practices. For instance, Law 12,846/13 (the ‘Anticorruption Law') established objective liabilities for Brazilian companies that commit acts against Brazilian or foreign public administration, including acts relating to public bidding processes and administrative contracts, and established tough penalties for those companies that are punished. The Company has a high number of administrative contracts with high values and a large number of suppliers and customers, which increases its exposure to risks of fraud and administrative impropriety. Our Company has structures and policies for the prevention and combat of fraud and corruption, audit and internal controls, and has adopted the recommendations for Best Corporate Governance Practices recommended by the Brazilian Corporate Governance Institute (Instituto Brasileiro de Governança Corporativa, or ‘IBGC') and the framework of the Committee of Sponsoring Organizations of the Treadway Commission (‘COSO'). Furthermore, due to the majority interest held by the State Government in our shareholding structure, we are required to contract the greater part of our works, services, advertising,purchases, disposals and rentals, through competitive bidding processes and administrative contracts, which are ruled by the Tenders Law, State Companies Law and other complementary legislation. However, despite the Company having processes of governance, risk management and compliance, we might be unable to avoid future violations of the laws and regulations to which we are subject (regarding labor, tax, environment, energy, among others), or violations of our internal control mechanisms, our Code of Ethics and Code of Professional Conduct, or the occurrence of fraudulent or dishonest behavior by employees, or individuals or legal entities that are contracted, or other agents that may represent the company in dealings with third parties, especially with the Public Authorities.
Share Price & Shareholder Rights - Risk 3
Changed
An investor of our common shares or preferred shares and common or preferred ADSs might be unable to exercise preemptive rights and tag-along rights with respect to our shares.
U.S. investors of common shares or preferred shares and common or preferred ADSs may not be able to exercise the preemptive rights and tag-along rights relating to our shares unless a registration statement under the U.S. Securities Act of 1933, as amended, or the Securities Act, is effective with respect to those rights or an exemption from the registration requirements of the Securities Act is available. We are not obligated to file a registration statement with respect to our shares relating to these rights, and we cannot assure that we will file any such registration statement. Unless we file a registration statement or an exemption from registration is available, an ADR investor may receive only the net proceeds from the sale of their preemptive rights and tag-along rights or, if these rights cannot be sold, they will lapse and the ADR investor will receive only the net proceeds from the sale of their preemptive rights and tag-along rights or, if these rights cannot be sold, they will lapse and the ADR holder will receive no value for them.
Share Price & Shareholder Rights - Risk 4
Changed
Future equity issuances may dilute the holdings of current holders of our shares or ADSs and could materially affect the market price for those securities.
We may in the future decide to offer additional equity to raise capital or for other purposes. Any such future equity offering could reduce the proportionate ownership and voting interests of holders of our shares and ADSs, as well as our earnings and net equity value per share or ADS. Any offering of shares and ADSs by us or our main shareholders, or a perception that any such offering is imminent, could have an adverse effect on the market price of these securities.
Share Price & Shareholder Rights - Risk 5
Foreign shareholders may be unable to enforce judgments given in non-Brazilian courts against the Company, or against members of its Board of Directors or Executive Board.
All our directors and officers reside in Brazil. Our assets, as well as the assets of these individuals, are located mostly in Brazil. As a result, it may not be possible for foreign shareholders to effect service of process on them within the United States or other jurisdictions outside Brazil, or to attach their assets, or to enforce against them, or against the Company in United States courts, or in the courts of other jurisdictions outside Brazil, judgments that are predicated upon the civil liability provisions of the securities laws of the United States or the respective laws of such other jurisdictions. In order to have a judgment rendered outside of Brazil enforced in Brazil, the party seeking enforcement would need to be recognized in the courts of Brazil (to the extent that Brazilian courts may have jurisdiction) and such courts would enforce such judgment without any retrial or reexamination of the merits of the original action only if such judgment had been previously ratified by the Superior Court of Justice (Superior Tribunal de Justição, or ‘STJ'), in accordance with Articles 216-A to 216- X of the Internal Regulations of the STJ (RISTJ), introduced by Regulatory Amendments No. 18/2014 and No. 24/2016. Notwithstanding the foregoing, no assurance can be given that ratification will be obtained.
Share Price & Shareholder Rights - Risk 6
Exchange of preferred ADSs or common ADSs for underlying shares may have adverse consequences.
The Brazilian custodian for the preferred shares and common shares must obtain an electronic certificate of foreign capital registration from the Central Bank to remit U.S. dollars from Brazil to other countries for payments of dividends, or any other cash distributions, or to remit the proceeds of a sale of shares. If the investor decides to exchange his preferred ADSs or common ADSs for the underlying shares, the investor will be able to continue to rely, for five business days from the date of the exchange, on the depositary bank's electronic certificate of registration in order to receive any proceeds distributed in connection with the shares. After that period, the investor may not be able to obtain and remit U.S. dollars abroad upon sale of our common/preferred shares, or distributions relating to our common/preferred shares, unless he or she obtains his or her own certificate of registration or registers the investment under CMN Resolution 4,373/2014, dated September 29, 2014, which entitles registered foreign investors (‘Resolution 4,373/2014') to buy and sell on a Brazilian stock exchange. If the investor does not obtain a certificate of registration or register under Resolution 4,373/2014, the investor will generally be subject to less favorable tax treatment on gains with respect to our common shares. If the ADR investors attempt to obtain their own certificate of registration, they may incur expenses or suffer delays in the application process, which could delay their ability to receive dividends or distributions relating to our common shares or the return of their capital in a timely manner. The custodian's certificate of registration or any foreign capital registration obtained by an investor may be affected by future legislative changes, and additional restrictions applicable to the investor, the disposition of the underlying common/preferred shares or the repatriation of the proceeds of disposition may be imposed in the future. If the investors decide to exchange their preferred or common shares back into preferred ADSs or common ADSs, respectively, once they have registered their investment in preferred shares or common shares, they may deposit their preferred or common shares with the custodian and rely on the depositary bank's registration certificate, subject to certain conditions. We cannot guarantee that the depositary bank's certificate of registry or any certificate of foreign capital registration obtained by an investor may not be affected by future legislative or other regulatory changes, nor that additional Brazilian restrictions applicable to the investor, or to the sale of the underlying preferred shares, or to repatriation of the proceeds from the sale, will not be imposed in the future.
Share Price & Shareholder Rights - Risk 7
Judgments of Brazilian courts with respect to our shares will be payable only in Reais.
If proceedings are brought in the courts of Brazil seeking to enforce our obligations in respect of our shares, we will not be required to discharge any such obligations in a currency other than Reais. Under Brazilian exchange control limitations, an obligation in Brazil to pay amounts denominated in a currency other than Reais may only be satisfied in Brazilian currency at the exchange rate, as determined by the Central Bank, in effect on the date the judgment is obtained, and any such amounts are then adjusted to reflect exchange rate variations through the effective payment date. The then prevailing exchange rate may not afford non-Brazilian investors full compensation for any claim arising out of, or related to, our obligations under our shares.
Share Price & Shareholder Rights - Risk 8
Sales of a substantial number of shares, or the perception that such sales might take place, could adversely affect the prevailing market price of our shares, or of the preferred or common ADSs.
As a consequence of the issuance of new shares, sales of shares by existing share investors, or the perception that such a sale might occur, the market price of our shares and, by extension, of the preferred and/or common ADSs, may decrease significantly.
Share Price & Shareholder Rights - Risk 9
The preferred shares and preferred ADSs generally do not have voting rights, and the common ADSs can only be voted by proxy by providing voting instructions to the depositary.
Under the Brazilian Corporate Law and our by-laws, holders of our preferred shares, and, consequently, holders of our ADSs representing preferred shares, are not entitled to vote at our shareholders' meetings, except in very specific circumstances. Holders of our preferred ADSs may also encounter difficulties in the exercise of certain rights, including the limited voting rights. Holders of the ADSs for our common shares do not have automatic entitlement to vote in our General Meetings of Shareholders, other than by power of attorney, by sending a voting instruction to the depositary. Where there is not enough time to send the form with voting instructions to the depository, or in the event of omission to send the voting instruction, the holders of ADSs for CEMIG's preferred and common shares may be unable to vote by means of instructions to the depository.
Share Price & Shareholder Rights - Risk 10
The relative volatility and illiquidity of the Brazilian securities market may adversely affect our shareholders.
Investing in Latin American securities, such as the preferred shares, common shares, preferred ADSs or common ADSs, involves a higher degree of risk than investing in securities of issuers from countries with more stable political and economic environments and such investments are generally considered speculative in nature. These investments are subject to certain economic and political risks, including, as examples, the following: - Changes to the regulatory, tax, economic and political environment that may affect the ability of investors to receive payment, in whole or in part, related to their investments; and - Restrictions on foreign investment and on repatriation of capital invested. The Brazilian securities market is substantially smaller, less liquid, more concentrated and more volatile than the major securities markets in the United States. This might substantially limit an investor's ability to sell the shares underlying his preferred or common ADSs for the desired price and within the desired period. In 2022, the São Paulo Stock Exchange (Brasil, Bolsa, Balcão S.A, or ‘B3'), the only stock exchange in Brazil on which our shares are traded, had an annual market capitalization of R$6.3 trillion, and average daily trading volume of R$25.2 billion.
Share Price & Shareholder Rights - Risk 11
Holders of the preferred and common ADSs, and holders of our shares, may have different shareholders' rights than holders of shares in U.S. companies.
Our corporate governance, disclosure requirements and accounting practices are governed by our by-laws, by the Level 1 Differentiated Corporate Governance Practices Regulations (‘Regulamento de Práticas Diferenciadas de Governança Corporativa Nível 1') of the B3 (the main Brazilian stock exchange) by the Brazilian Corporate Law (Federal Law 6,404/76) and by the rules issued by the CVM. These regulations may differ from the legal principles that would apply if our Company were incorporated in a jurisdiction in the United States, such as Delaware or New York, or in other jurisdictions outside Brazil. In addition, the rights of an ADS holder, which are derived from the rights of holders of our common or preferred shares to have his interests protected in relation to decisions by our board of directors or our controlling shareholder, may be different under the Brazilian Corporate Law from the rules of other jurisdictions. Rules against insider trading and self-dealing and other rules for the preservation of shareholder interests may also be different in Brazil if compared to the United States rules, potentially establishing a disadvantage for holders of the preferred shares, common shares, or preferred or common ADSs.
Accounting & Financial Operations2 | 3.3%
Accounting & Financial Operations - Risk 1
Our ability to distribute dividends is subject to limitations.
Whether or not an investor receives dividends depends on whether our financial condition permits us to distribute dividends under Brazilian law, restrictive covenant clauses in contracts related to our loans and financings and whether our shareholders, on the recommendation of our Board of Directors, acting in its discretion, determine suspension, due to our financial circumstances, of the distribution of dividends in excess of the amount of mandatory distribution required under our by-laws in the case of the preferred shares. Because we are a holding company with no revenue-producing operations other than those of our operating subsidiaries, we can only distribute dividends to shareholders if the Company receives dividends or other cash distributions from our operating subsidiaries. The dividends that our subsidiaries can distribute depend on our subsidiaries generating sufficient profits in any given fiscal year and on restrictive covenant clauses in contracts for loans and financings of these subsidiaries as well as on any restriction imposed by the grantor, all of which place limits upon our subsidiaries' payments of dividends to the Company. Similarly, we have a limitation on the payment of dividends which cannot exceed the mandatory minimum of 50% of the net income for the business year, as contained in our by-laws, due to restrictive covenant clauses in the contracts for loans and financings of the subsidiaries in which we are guarantors. Dividends are calculated and paid in accordance with applicable Brazilian corporate law and the provisions of the by-laws of each of our regulated subsidiaries.
Accounting & Financial Operations - Risk 2
ANEEL through concessions contracts establish the Permitted Annual Revenue (Receita Anual Permitida or ‘RAP') of our transmission companies; if any adjustments result in a reduction of the RAP, this could have a material adverse effect on our results of operations and financial condition.
ANEEL defines the RAP that we receive through our transmission companies, on behalf of the Federal Government. The concession contracts provide for two mechanisms for the adjustment of revenues: (a) the annual tariff adjustments; and (b) the Periodic Tariff Review (Revisão Tarifária Periódica, or ‘RTP'). The annual tariff adjustment of our transmission revenues takes place annually in June and is effective in July of the same year. The annual tariff adjustments take into account the permitted revenues of the projects that have come into operation, and the revenue from the previous period is adjusted by the inflation index (IPCA for Contract No. 006/1997 and IGP-M for Contract No. 079/2000). The periodic tariff review takes place every five years. During the periodic tariff review, the investments made by a concession holder in the period and the operating costs of the concession are analyzed by ANEEL. The grantor takes into account only investments that it deems to be prudent, and operating costs that it assesses as having been efficient, using a benchmarking methodology. Thus, the tariff review mechanism is subject to some extent to the discretionary power of ANEEL, since it may omit investments that have been made, and could recognize revenues for operating costs lower than those actually incurred. This could result in a material adverse effect on our business, results of operations and financial condition. An Extraordinary Tariff Review takes place whenever there is any unforeseen development that significantly alters the economic/ financial equilibrium of the concession. Thus, although our concession agreements specify that the economic and financial balance of the contract shall be preserved, we cannot guarantee that ANEEL will set tariffs that adequately compensate us in relation to the investments made or in relation to the operating costs incurred because of the concession. This may have a material adverse effect on our business, financial condition and results of operations.
Debt & Financing2 | 3.3%
Debt & Financing - Risk 1
We have a considerable amount of debt, and we are exposed to limitations on our liquidity – a factor that might make it more difficult for us to obtain financing for investments that are planned and might negatively affect our financial condition and our results of operations.
In order to finance the capital expenditures needed to meet our long-term growth objectives, we have incurred a substantial amount of debt. As of December 31, 2022, our total loans and debentures (including interest) were R$10,580 million; a decrease of 6.91% compared to the R$11,364 million reported as of December 31, 2021 and, which 2021 amount represented a decrease of 24.35% compared to R$15,020 million reported as of December 31, 2020. As of December 31, 2022, 52.48% of our existing loans and debentures - totaling R$5,552 million, have maturities in the next two years. To meet our growth objectives, maintain our ability to fund our operations and comply with scheduled debt maturities, we will need to raise debt capital from a range of funding sources. To service its debt after meeting the capital expenditure targets, the Company has relied upon a combination of cash flows provided by its operations, sale of assets, drawdowns under its available credit facilities, its cash and short-term financial investments balance and the incurrence of additional indebtedness. Any further lowering of its credit ratings may have adverse consequences on the Company's ability to obtain financing or may affect its cost of financing, also making it more difficult or costly to refinance maturing obligations. If, for any reason, the Company were to face difficulties in accessing debt financing, this could hamper its ability to make capital expenditures in the amounts needed to maintain its current level of investments or its long-term targets and could impair its ability to timely meet its principal and interest payment obligations with its creditors. A reduction in the Company's capital expenditure program or the sale of assets could significantly and adversely affect its results of operations.
Debt & Financing - Risk 2
A reduction in our credit risk rating or in Brazil's sovereign credit ratings could adversely affect the availability of new financing and increase our cost of capital.
The credit risk rating agencies Standard and Poor's, Moody's and Fitch Ratings attribute a rating to the Company and its debt securities on a Brazilian basis, and also a rating for the Company on a global basis. Ratings reflect, among other factors, the outlook for the Brazilian energy sector, the hydrological conditions of Brazil, the political and economic conditions, country risk, and the rating and outlook for the Company controlling shareholder, the State of Minas Gerais. In the event of a downgrade due to any external factors, our operational performance or high levels of debt, our cost of capital could increase and our ability to comply with existing financial covenants in the instruments that regulate our debt could be adversely affected. Further, our operating or financial results and the availability of future financing could be adversely affected. In addition, probable reductions in Brazilian sovereign ratings could adversely affect the perception of risk in relation to securities of Brazilian issuers, and, as a result, increase the cost of any future issues of debt securities. Any reductions in our ratings or Brazil's sovereign ratings could adversely affect our operating and financial results, and our access to future financing.
Corporate Activity and Growth3 | 5.0%
Corporate Activity and Growth - Risk 1
Changed
The operating and financial results of our subsidiaries, jointly controlled entities and affiliates, non controlling or from any companies which we may acquire in the future, may negatively affect our strategies, operating results and financial condition.
We own equity in and do business through various subsidiaries and investees, including companies with assets in the energy generation and transmission sectors, energy and natural gas distribution sectors and other related business. The future development of our subsidiaries, jointly controlled entities and affiliates, such as Transmissora Aliança de Energia Elétrica S.A. (‘Taesa') and Aliança Geração de Energia S.A. (‘Aliança'), Guanhães Energia S.A. and Norte Energia S.A. (‘NESA') could have a significant impact on our business and operating results. The Company's ability to meet its financial obligations is correlated, in part, to the cash flow and the profits of its subsidiaries and investees, and the distribution to the Company by such companies of profits in the form of dividends or other advances or payments. If these companies' abilities to generate profits and cash flows are reduced, this may cause a reduction of dividends and interest on capital paid to the Company, which could have a material adverse effect on our results of operations and financial position. In addition, the investees may not achieve the results expected when they were acquired. The process of integration for any acquired business could subject the Company to certain risks, such as, for example, the following: (i) unexpected expenses; (ii) inability to integrate the activities of the companies acquired with a view to obtaining the expected economies of scale and efficiency gains; (iii) possible delays related to integration of the operations of companies; (iv) exposure to potential contingencies; (v) legal claims made against the acquired business that were unknown at the time of its acquisition; (vi)environmental licensing and liabilities, (vii) hydrological risk, (viii) power system operation and control, and (ix) general claims. The Company might be unsuccessful in dealing with these or other risks, or problems related to any other operation of a future acquisition and be negatively affected by the companies acquired or which may be acquired in the future. Furthermore, some of our subsidiaries and investees might, in the future, enter into agreements with creditors that could restrict dividend payments or other transfers of funds to the Company. These subsidiaries are separate legal entities. Any rights that we may have in relation to the receipt of assets or other payments in the event of liquidation or reorganization of any subsidiary, could be structurally subordinated to the demands of the creditors of such subsidiary (including tax authorities, commercial creditors and lenders to those subsidiaries). Any deterioration in the operating results or financial conditions of these subsidiaries, and any sanctions or penalties imposed on them, could have a material adverse effect on the Company's business results of operations or financial condition.
Corporate Activity and Growth - Risk 2
Our strategy for maximizing value for CEMIG's shareholders depends on external factors that could impede its successful implementation.
CEMIG's strategy to maximize shareholder value in the Company is based on three pillars: - Divestments: non-strategic or low synergy assets, and opportunistic offerings;- Expansion: mainly through investments in our distribution and transmission concessions, greenfield projects in renewable sources and with the renewing of power generation concessions; and - Management: synergy improvement, capital structure and distribution policy and governance enhancing. All of these pillars may be affected by external factors that are beyond the control of the Company, in particular any divestment transactions which must take into consideration particular risks associated with each relevant business, such as performance (technical, operational, commercial and financial), market risks, sectorial risks and national and international macroeconomic risks (e.g., market volatility). Furthermore, any closing of divestment transactions will depend on the favorable development of negotiations with potential investors regarding the conditions of the possible transactions. The Company cannot provide any assurances that factors outside of its control will not hinder the implementation of its strategies to maximize shareholder value.
Corporate Activity and Growth - Risk 3
We may be unable to implement our long-term strategic plans within the desired timeframe, or without incurring unforeseen costs, which could have adverse consequences for our business, results of operations and financial condition.
Our ability to meet our strategic objectives depends, largely, on successful, cost-effective and timely implementation of our Long-term Strategy and our Multi-year Business Plan. The following are some of the factors that could negatively affect the implementation of our strategic plans: - Inability to generate cash flow, or obtain the future financing, necessary for implementation of the particular projects or strategic objectives;- Inability to obtain necessary governmental licenses and approvals;- Unexpected engineering and environmental problems;- Unexpected delays in the processes of eminent domain and establishment of servitude rights;- Unavailability of the necessary workforce or equipment;- Labor strikes;- Delays in delivery of equipment by suppliers;- Delays resulting from failures of suppliers or third parties to comply with their contractual obligations;- Delays or stoppages caused by climate factors, or environmental restrictions;- Changes in the environmental legislation creating new obligations and causing additional costs for projects;- Legal instability caused by political issues; and - Substantial changes in economic, regulatory, hydrological or other conditions. The occurrence of the above factors, separately or taken together, could lead to a significant increase in costs, and might delay or impede the implementation of initiatives, and consequently compromise the execution of our strategic plans and negatively affect our operating and financial results. Furthermore, as we are a mixed-capital company controlled by the State of Minas Gerais, we are subject to changes to our board of directors and executive officers because of changes in the Executive Branch of the State government from time to time, as a result of elections and political instability. These types of changes may adversely affect the continuity of the Company's strategy.
Legal & Regulatory
Total Risks: 15/60 (25%)Above Sector Average
Regulation6 | 10.0%
Regulation - Risk 1
The rules for energy trading and market conditions may affect the sale prices of energy.
Under applicable laws, our generation companies are not allowed to sell energy directly to distributors. Thus, the power generated by our companies is sold in the Regulated Market (Ambiente de Contratação Regulado, or ‘ACR') – also referred to as the ‘Pool' – through public auctions held by ANEEL, or through the Free Market (Ambiente de Contratação Livre, or ‘ACL') through bilateral negotiations with customers and traders. The applicable legislation allows distributors that sign contracts for existing energy supply (‘energia existente') with generation companies in the Regulated Market to reduce the quantity of energy contracted by up to 4%, per year, in relation to the amount of the original contract, for the entire period of the contract. This exposes our generation companies to the risk of not selling the de-contracted supply at adequate prices. We conduct trading activities through power purchase and sale agreements, mainly in the Free Market, through our generation and trading companies. Contracts in the Free Market may be entered into with other generating entities, energy traders, or mainly, with ‘free customers.' Free customers are customers with a demand of 1.0 MW or more: they are allowed to choose their energy supplier. this limit will be reduced to 0.5 MW in 2023 and by 2024 all consumers connected to high voltage lines (Ordinance 50, published by the Ministry of Mines and Energy in September 2022). Some contracts have flexibility in the amount sold, allowing the customer to consume a higher or lower amount (5% on average) from our generating companies than the original amount contracted, which might cause an adverse impact on our business, operating results and/or financial condition. Other contracts do not allow for this kind of flexibility in the purchase of energy, but increased competition in the Free Market could influence the occurrence of this type of arrangement in purchase contracts. In addition to the free customers referred to above, there is a category of customers referred to as ‘Special Customers', which are those with contracted demand between 0.5 MW and 1.0 MW. Special Customers are eligible to participate in the Free Market provided they buy energy from incentive-bearing alternative sources, such as Small Hydroelectric plants, biomass plants or wind farms. As envisaged by the Ordinance 50/2022, by 2024 there will be no demand restriction for free customers connected to high voltage lines and in light of that there will be no more separation of free and special consumers. The Company has conducted sales transactions for this category of energy from specific energy resources in particular companies of the CEMIG Group and, since 2009, the volume of these sales has gradually increased. The Company has formed a portfolio of purchase contracts, which now occupies an important space in the Brazilian energy market for incentive-bearing alternative power sources. Contracts for the sale of energy to these customers have specific flexibilities to serve their needs, and these flexibilities of greater or lesser consumption are linked to the historic behavior of these loads. Higher or lower levels of consumption by these customers may cause purchase or sale exposures to spot prices, which can have an adverse impact on our business, operating results and/or financial condition. Market variations, such as variations of prices for signature of new contracts, and of volumes consumed by our customers in accordance with flexibilities previously contracted, can lead to spot market positions, which can potentially have a negative financial impact on our results. The MRE aims to reduce the exposure of generators of hydroelectric power, such as our generation companies, to the uncertainties of hydrology. It functions as a pool of hydroelectric Generation Companies, in which the generation of all the plants participating in the MRE is shared in such a way as to meet the demand of the pool. When the totality of the plants generates less than the amount demanded, the mechanism reduces the assured offtake levels of the plants, causing a negative exposure to the short-term (‘spot') market and, therefore, the need to purchase power supply at the spot price. Correspondingly, when the total generation of the plants is higher than the volume demanded, the mechanism increases the guaranteed offtake level of the plants, leading to a positive exposure, permitting the liquidation of power at the Differences Settlement Price (Preço de Liquidação de Diferenças, or ‘PLD'). In years of poor rainfall, the reduction factor, which applies to the assured energy levels, can reduce the levels of the hydroelectric plants by 20% or more. Low liquidity or volatility in future prices, due to market conditions and/or perceptions, could negatively affect our results of operations. Further, if we are unable to sell all the power that we have available (our own generation capacity plus contracts under which we have bought supply of power) in the regulated public auctions or in the Free Market, the unsold capacity will be sold in the CCEE at the PLD, which tends to be very volatile. If this occurs in periods of low spot prices, our revenues and results of operations could be adversely affected. The PLD's value is calculated through the results of the optimization models of the operation of the national grid used by the ONS and by the CCEE. The PLD is currently published weekly by the CCEE for three load levels (light, medium and heavy). The models depend on entry data revised by the ONS at each period of four months, monthly, and weekly. In this system, there is the possibility that errors occur during the input of data into the model, which can lead to an unexpected change in the PLD. Alteration of these models, and errors in data input, constitute risks for the trading business, because they cause uncertainty in the market, reducing liquidity, and financial losses due to the unexpected change of price. To mitigate the risk of change of the models during the current year, the National Energy Policy Council (‘CNPE') published a note in 2016 which established that changes in the mathematical models used in the sector will need to be approved by the CPAMP (‘Comissão Permanente para Análise de Metodologias', or Standing Committee for Methodologies Analysis and Energy Industry Computer Programs) by July 31 of each year in order to be in force in the subsequent year. In 2020, the frequency of changes in the PLD were increased to hourly. Having an hourly PLD improves the PLD's adherence to the real operation of the system, which will then better capture the hourly changes in the intermittent sources (solar and wind). This better alignment of price with operation tends to reduce the System and Service Charges (‘ESS'), and to remunerate the thermoelectric generation plants more efficiently when they are activated. On the other hand, the quality of the entry data when input on an hourly basis, especially for solar and wind sources, introduces one more element of uncertainty to the pricing of the market.
Regulation - Risk 2
Changed
We are subject to extensive and governmental legislation and regulation which may be subject to change, and any changes to such legislation and regulation could have a material adverse effect on our business, results of operations and financial condition.
Our operations are highly regulated and supervised by the Brazilian Federal Government, through the MME, ANEEL, the National System Operator (Operador Nacional do Sistema, or ‘ONS'), and other regulatory authorities. These authorities have a substantial degree of influence on our business. MME, ANEEL and ONS have discretionary authority to implement and change policies, interpretations and rules applicable to different aspects of our business, particularly operations, maintenance, health and safety, consideration to be received and inspection. Any significant regulatory measure implemented by such authorities may result in a significant burden on our activities, which may have a material adverse effect on our business, results of operations and financial condition. The Brazilian Federal Government has been implementing policies that have a far-reaching impact on the Brazilian energy sector. As part of the restructuring, Law 10,848, of March 15, 2004 introduced a new regulatory regime for the Brazilian energy industry. This regulatory structure has undergone several changes in recent years, the most recent being the changes added by PA 579 (which was converted into Law 12,783/2013), which governs the extension of some concessions governed by Law 9,074/1995. Under this law, such concessions can, from September 12, 2012, be extended only once, for up to 30 years, at the option of the concession authority. Draft law PL 414/2021 (formerly PLS 232/2016) is being discussed in the Chamber of Deputies. This bill proposes amendments to important legislation in the electricity sector, aiming to improve the regulatory and commercial model of the electricity sector with a view to expanding the free market, among other measures. In addition, we cannot guarantee that measures taken in the future by the Brazilian Federal Government, in relation to development of the Brazilian energy system, will not have a negative effect on our activities. Further, we are unable to predict to what extent such measures might affect us. If we are required to conduct our business and operations in a way that is substantially different from that specified in our business plan, our business, results of operations or financial position may be negatively affected.
Regulation - Risk 3
Our subsidiaries might suffer intervention by Brazilian public authorities to ensure adequate levels of service or be sanctioned by ANEEL for non-compliance with their concession agreements, or the authorizations granted to them, which could result in fines, other penalties and/or, depending on the severity of the non-compliance, legal termination of concession agreements or revocation of authorizations.
We conduct our generation, transmission and distribution activities pursuant to concession agreements entered into with the Brazilian Federal Government, through ANEEL, and pursuant to authorizations granted to companies of the CEMIG Group, as the case may be. ANEEL may impose penalties or revoke a concession or authorization if we fail to comply with any provision of the concession agreements or authorizations, including those relating to compliance with the established quality standards. Depending on the severity of the non-compliance, these penalties could include: - Fines for breach of contract of up to 2.0% of the concession holder's revenues in the financial year immediately prior to the date of the breach;- Injunctions related to the construction of new facilities and equipment;- Temporary suspension from participating in bidding processes for new concessions for a period of up to two years;- Intervention by ANEEL in the management of the concession holder that is in breach;- Revocation of the concession; and - Execution of the guarantees related to the concession. Furthermore, the Brazilian Federal Government can revoke any of our concessions or authorizations before the expiration of the concession term, in the event of bankruptcy or dissolution, or by legal termination, if determined to be in the public interest. It can also intervene in concessions to ensure adequate provision of the services, full compliance with the relevant provisions of agreements, authorizations, regulations and applicable law; and where it has concerns about the operations of the facilities of the Company. Delays in the implementation and construction of new energy infrastructure can trigger the imposition of regulatory penalties by ANEEL, which, under ANEEL's Normative Resolution 846 of June 11, 2019, can vary from warnings to the termination of concessions or withdrawal of authorizations. Any compensation we may receive upon rescission of the concession agreement or revocation of an authorization may not be sufficient to compensate us for the full value of certain investments. If we are responsible for the rescission of any concession agreement, the effective amount of compensation could be lower, due to fines or other penalties. The imposition of fines or penalties or the early termination or revocation by ANEEL of any of our concession agreements or authorizations, or any failure to receive sufficient compensation for investments we have made, may have a material adverse effect on our business, financial condition and results of operations, and on our ability to meet our payment obligations. Rules under the Fifth Amendment to the distribution concession contract came into effect in 2016. They contain new targets for service quality, and requirements related to CEMIG Distribuição S.A. (or Cemig D)'s economic and financial sustainability. These targets must be complied with over the 30 years of the concession. Compliance with these targets is assessed annually, and non-compliance could result in an obligation for CEMIG to inject capital into CEMIG D or a limitation on distribution of dividends or the payment of interest on equity by CEMIG D to CEMIG. According to ANEEL regulations, in case of failure to comply with global annual targets for collective continuity indicators for two consecutive years, or three times in five years, or at any time in the last five years of the agreement term, distribution of dividends or payment of interest on equity may be limited until compliance is resumed. Also, our Gasmig S.A. (or Gasmig)'s Concession contract establishes that in the event of non-compliance with any provision of the Concession Contract, including delays or non-compliance with targets specified in it, the State of Minas Gerais may impose penalties on Gasmig. Depending on the severity of the non-compliance, the applicable penalties include warnings and intervention. Gasmig cannot guarantee that it will not be penalized for non-compliance with its concession contract, nor that its concession contract will not be revoked in the future. The indemnity to which this subsidiary is entitled in the event of revocation of its concession may be insufficient for recovery of the full value of certain assets. Consequently, imposition of sanctions on Gasmig or revocation of its concession could result in a material adverse effect on the financial condition and results of operations of Gasmig, and of the Company.
Regulation - Risk 4
We are not certain whether new concessions or authorizations, as applicable, will be obtained, nor that our present concessions or authorizations will be extended on terms similar to those currently in effect, nor that any compensation we receive in the event of non-extension will be sufficient to cover the full value of our investment.
We operate most of our power generation, transmission and distribution activities, and related services under concession agreements entered into with the Brazilian Federal Government or pursuant to authorizations granted to companies of the CEMIG Group. The Brazilian Constitution determines that all concessions related to public services must be granted through a bidding process. In 1995, in an effort to implement these constitutional provisions, the Brazilian Federal Government adopted certain laws and regulations, which are collectively known as the ‘Concessions Law,' which governs bidding procedures in the electric power industry. On September 11, 2012, the Brazilian Federal Government issued Provisional Act 579 (‘PA 579'), later converted into Law 12,783 of January 11, 2013 (‘Law 12,783/13'), which governs the extensions of concessions granted prior to Law 9,074/95. Law 12,783/13 determines that, as of September 12, 2012, concessions prior to Law 9,074/95 can be extended once, for up to 30 years, provided that the concession operators accept and meet certain conditions described in such Law. With respect to generation activities, the Company chose not to accept the mechanism offered to extend the generation concessions that would expire in the period from 2013 to 2017. These concessions are: Três Marias, Salto Grande, Itutinga, Volta Grande, Camargos, Peti, Piau, Gafanhoto, Tronqueiras, Joasal, Martins, Cajuru, Paciência, Marmelos, Dona Rita, Sumidouro, Poquim and Anil. Following publication of the tender documents for Generation Auction 12/2015, on October 7, 2015 (‘Auction 12/2015'), which was held under the revised regulatory structure for renewal of concessions of existing power plants as set forth in Law 13,203 of December 8, 2015 (‘Law 13,203/15'), the Company's Board of Directors authorized CEMIG Geração e Transmissão S.A. (CEMIG GT) to bid at an auction, held on November 25, 2015, in which CEMIG GT was successful. In the auction, CEMIG GT won the concessions for the 18-hydroelectric plants comprising ‘Lot D', for 30 years: Três Marias, Salto Grande, Itutinga, Camargos, Cajuru, Gafanhoto, Martins, Marmelos, Joasal, Paciência, Piau, Coronel Domiciano, Tronqueiras, Peti, Dona Rita, Sinceridade, Neblina and Ervália. The total installed capacity of these plants is 699.5 MW, and their offtake guarantee is 420.2 MW average. On September 9, 2020, Law 14,052 was issued, changing Law 13,203/2015 and establishing new conditions for renegotiation of hydrological risk in relation to the portion of costs incurred due to the Generation Scaling Factor (‘GSF') (Fator de ajuste da energia), borne by the holders of hydroelectric plants participating in the Energy Reallocation Mechanism (‘MRE') since 2012, when there was a serious crisis in water sources. The compensation to the holders of hydroelectric were granted through the extension of the concession period for generation plants and were recognized as an intangible asset in exchange for a compensation of electricity costs. This renegotiation represents important progress for the electricity sector, reducing levels of litigation – and for CEMIG, in that it enables extension of the periods of its generation concessions. The periods of extension approved by ANEEL through normative resolutions 2,919/2021 and 2,932/2021 are shown in the table below: Power plant Capacity (MW) Concession extension (days) New Term of Concession Emborcação 1,192 672 05/26/2027 Nova Ponte 510 750 08/12/2027 Irapé 399 934 09/19/2037 Três Marias 396 2,555 01/03/2053 Salto Grande 102 2,555 01/03/2053 Sá Carvalho 78 635 08/28/2026 Rosal 55 1,314 12/13/2035 Others (1) 353 - -(1)Includes 20 power plants, of which 3 are owned by CEMIG GT, 1 is owned by CEMIG PCH, 3 are owned by Horizontes and the others belong to CEMIG affiliates. The average concession extension in days varies between 252 and 2,555 days. Considering the degree of discretion granted to the Brazilian Federal Government in relation to new concession contracts or new authorizations, as applicable, and renewal of existing concessions and authorizations, and due to Law 12,783/13 and amendments, for renewals of generation, transmission and distribution concession agreements, we cannot guarantee that: (i) new concessions and authorizations will be obtained; (ii) our existing concessions and authorizations will be extended on terms similar to those currently in effect; nor (iii) the compensation received in the event of non-extension of a concession or authorization will be in an amount sufficient to cover the full value of our investment. Our inability to obtain new or extended concessions or authorizations could have a material adverse effect on our business, results of operations and financial condition. For more information about the renewal of our concessions and authorizations, see "Item 8. Financial Information – Legal and Administrative Proceedings".
Regulation - Risk 5
We are subject to restrictions on our ability to make capital investments and to incur indebtedness, which could adversely affect our business, results of operations and financial condition.
Our ability to carry out our capital expenditure program is dependent upon several factors, including our ability to charge adequate rates for our services, access to the domestic and international capital markets, and a variety of operational and other factors. Further, our plans to expand our generation and transmission capacity are subject to compliance with competitive bidding processes. These bidding processes are governed by Law 13,303/2016 (the ‘State Companies Law'). In relation to loans from third parties: (i) as a state-controlled company, we are subject to rules and limits relating to the level of credit applicable to the public sector, including rules established by the National Monetary Council (Conselho Monetário Nacional, or ‘CMN'), and by the Brazilian Central Bank; and (ii) we are subject to the rules and limits established by ANEEL that regulate indebtedness for companies in the energy sector. Also, although we may access both the international and local capital markets, we, as a state-controlled company, can only be financed with funds extended by local commercial banks if such debt is guaranteed by receivables, as well as with funds extended by Brazilian federal banks in transactions with the purpose of refinancing financial obligations contracted with entities of the Brazilian financial system. Furthermore, we are subject to certain contractual conditions under our existing debt instruments, and we may enter into new loans that contain restrictive covenants or similar clauses that could restrict our operational flexibility. These restrictions might also affect our ability to obtain new loans that are necessary for financing our activities and our growth strategy, and for meeting our future financial obligations when they become due, and this could adversely affect our ability to comply with our financial obligations. We have financing contracts and other debt obligations containing restrictive covenants, including Brazilian local market debentures and Eurobonds on international market. We have R$9.6 billion of outstanding debt with financial covenant restrictions, and any breach could have severe negative consequences to us. See ‘– The Company has a considerable amount of debt, and it is exposed to limitations on its liquidity – a factor that might make it more difficult for the Company to obtain financing for investments that are planned and might negatively affect its financial condition and its results of operation.' If, for example, we breach a financial covenant under the CEMIG GT's 9.25% Senior Notes due 2024 (the ‘Eurobonds'), we would be subject to an interest increase or acceleration of certain debt as a result of cross-default provisions under certain of our outstanding debt agreements. Similarly, if the Company violates a covenant under our debenture issuance, the debenture holders may accelerate the maturity of the debt in a meeting organized by the Fiduciary Agent (‘Trustee'), unless 75% of the debenture holders decide not to do so. Any acceleration of our outstanding debt could have a material adverse effect on our financial condition and may trigger cross-default clauses in other financial instruments. In the event of a default and acceleration, our assets and cash flow might be insufficient to repay amounts due, or to comply with the servicing of such debt. In the past, we have, on certain occasions, failed to comply with certain financial covenants that had conditions that were more restrictive than those currently in place. Although we were able to obtain waivers from our creditors in relation to past non-compliance, we cannot guarantee that we will be successful in obtaining any particular waiver in the future.
Regulation - Risk 6
Changed
CEMIG D's economic and financial sustainability is directly related to the effectiveness of the actions to control energy losses, and the regulatory limits established for it. If CEMIG D fails in successfully controlling energy loss, its business, operations, profit and financial condition could be substantially and adversely affected.
The energy losses of a distribution company comprise two types of losses: technical losses and non-technical (commercial) losses. Technical losses are inherent to the process of transporting and the transformation of electric power and occur in the cables and equipment of the energy system. Non-technical losses comprise energy that is supplied and not invoiced, which may be the result of illegal connections (theft), fraud, metering errors or failures in internal processes. CEMIG's Total Losses Index as of December 31, 2022, using a 12-month window, was 11.11%. This percentage is in relation to the total energy injected into the distribution system (the total volume of losses was 6,172 GWh). Of that percentage, 8.77% comprised technical losses, and 2.34% comprised non-technical losses. This result was 1.3 percentage points lower than the result for December 2021 (11.27%), and below the regulatory target set by ANEEL for 2022 (11.23%). From a regulatory point of view, ANEEL has been increasingly rigorous in establishing target caps for distribution losses. The target caps for non-technical losses are set based on a benchmarking model that compares using an index, which measures the social-economic complexity of each concession area and how efficient the distributors are in combating non-technical energy losses. For the targets of technical losses, ANEEL uses metering and power flow software. In light of this complex scenario involving regulatory uncertainties, even with the implementation of a strategy to reduce technical and commercial losses, CEMIG cannot guarantee that the target caps for losses established by ANEEL will be met in the short term, and this could affect the Company's financial condition and operating results, since the portion of a distribution company's power losses that exceeds the regulatory cap cannot be passed through to customers as an expense in the form of an increase in tariffs.
Litigation & Legal Liabilities4 | 6.7%
Litigation & Legal Liabilities - Risk 1
Added
A member of our board of directors is party to judicial proceedings.
A member of our board of directors is a defendant in several tax evasion proceedings, all in the pre-trial proceeding stage. For more information, see "Item 6. Significant Civil and Criminal Proceedings Involving Key Management Member". We cannot assure you that judicial and administrative proceedings, or the commencement of new judicial and administrative proceedings against any members of our management or board of directors, will not impose limitations or restraints on the performance of the members of our management and board of directors that are a party to these proceedings. In addition, we cannot assure you that these limitations will not adversely affect us and our reputation.
Litigation & Legal Liabilities - Risk 2
The anticorruption investigations currently in progress in Brazil, which have had large-scale public exposure, and any allegations against, or anticorruption investigations of, CEMIG, may have adverse effects on the perception of Brazil, as well as on our business, financial conditions and results of operations.
Certain anti-corruption investigations could have adverse effects on CEMIG or other companies of the CEMIG Group. Investors' perception of Brazil has been adversely affected by investigations of public corruption in large Brazilian companies, and by political events, which may represent potential risks to the social and economic outlooks for Brazil. Among the Brazilian companies involved in these investigations are state-controlled companies in the oil and gas, electricity and infrastructure sectors, and private companies in the construction and equipment supplier sectors, which are being submitted to investigations due to accusations of corruption by the Brazilian Securities Commission (‘CVM'), the Federal Police, the Brazilian Public Attorneys, the Federal Audit Board, the U.S. Securities and Exchange Commission (‘SEC') and the U.S. Department of Justice (‘DOJ'), among others. In the energy industry, Eletrobras has set up an independent internal investigation into possible non-compliance with law and/or regulations indicated by media reports that alleged illegal acts related to service providers of Norte Energia S.A. (‘NESA') and of Madeira Energia S.A. (‘MESA') for the construction of Belo Monte and Santo Antônio hydroelectric plants, respectively and some other special purposes entities, in which Eletrobras holds a minority stake. There have been no direct findings against NESA or MESA nor against any of their managers or employees, and the supposed illegal acts are in fact alleged to have taken place before NESA was formed. The internal investigation, however, estimated the economic and financial impact of these alleged illegal acts, related to NESA's service providers at R$183 million, and this was considered by Eletrobras and by NESA in accounting analyses and conclusions for the year ended December 31, 2015. This total supposedly represents amounts estimated in excess for acquisition of machines, equipment, services, capitalized charges and administrative expenses, since the alleged improper payments were not made by NESA, but by contractors and suppliers of the Belo Monte hydroelectric plant; and this impedes identification of the amount and precise periods of the payments. CEMIG holds, through CEMIG GT, an 11.69% indirect minority stake in NESA, through the jointly controlled entities Aliança Norte Energia Participações S.A. and Amazônia Energia S.A. and the estimated amount of losses was recorded in CEMIG's consolidated financial statements as of and for the year ended December 31, 2015. The independent internal investigation of MESA, concluded in February 2019, in the absence of any future developments such as any leniency agreements by third parties that may come to be signed or collaboration undertakings that may be signed by third parties with the Brazilian authorities, found no objective evidence enabling it to be affirmed that there were any supposed undue payments by MESA that should be considered for possible accounting write-off, pass-through or increase of costs to compensate undue advantages and/or linking of MESA with the acts of its suppliers, in the terms of the witness accusations and/or cooperation statements that have been made public. In addition to the cases above, there are investigations being conducted by the Public Attorneys' Office of the State of Minas Gerais (‘MPMG') and by the Civil Police of the State of Minas Gerais (‘PCMG'), which aim to investigate possible irregularities in the investments made by CEMIG in Guanhães Energia S.A. and in MESA (Santo Antônio Energia S.A. or ‘SAESA'). Additionally, on April 11, 2019 agents of the Brazilian Federal Police were in the Company's head office in Belo Horizonte to execute a search and seizure warrant issued by a São Paulo Federal Court in connection with the ‘Operation E o Vento Levou', as described above. These proceedings are being investigated by reviewing of documents requested by the respective authorities, and by hearing of witnesses. At present, it is not possible to determine what the results of the MPMG and PCMG's investigations will be. Considering these investigations, we contracted a third-party investigator to analyze the internal procedures related to these investments, as well as the Company internal proceedings related to the acquisition of Light's interest in Enlighted. The independent investigation was subject to oversight of an independent investigation committee whose creation was approved by our Board of Directors. The independent investigation was completed in May 2020 and identified no objective evidence substantiating illegal acts made by Company in the Company's investments that were the subjects of the investigation. Therefore, there has been no impact on our consolidated financial statements. By the end of 2020, CEMIG initiated internal investigations into allegations that are the subjects of inquiries conducted by the MPMG, regarding certain alleged irregularities in public bidding and purchasing processes. The investigations are being conducted by a new Investigation Committee with support from third-party investigator and external law firm. On November 24, 2021 the independent internal investigation that begun in 2020 was concluded, and its final report has been delivered and was approved by the Investigation Committee. However, the Company awaits completion of the investigations by the Public Attorneys' Office of Minas Gerais State (‘MPMG') and by other Brazilian and international authorities that are still ongoing. The Executive Board determined the establishment of a disciplinary administrative process (‘Processo Administrativo Disciplinar', or ‘PAD') to verify the veracity of the allegations and to pursue the preventive removal of all managers from the Supply and Logistics area, which aims to ensure impartiality and exemption in the investigations. CEMIG is and has been fully cooperating with any and all investigation and inspection by competent authorities, whether in the United States or Brazil. In July 2019, pursuant to the DOJ's Corporate Enforcement Policy, the Company disclosed the above-described investigation to the DOJ and the SEC and has been cooperating with those agencies. In December 2022, the SEC concluded its investigation with no further enforcement action. In February 2023, the DOJ closed its inquiry on possible violations of the FCPA. We cannot guarantee that CEMIG or companies of the CEMIG Group will not in the future become target of legal actions based on these or future investigations, whether in the United States or Brazil. Any future anti-corruption actions, which might find failures of conduct by the management of the Company or by third parties, might result in significant fines or penalties or significant negative postings in the accounts, or intangible damage, such as damage to reputation, and/or other significant, unforeseen, adverse effects.
Litigation & Legal Liabilities - Risk 3
We have strict liability for any damages caused to third parties resulting from inadequate provision of energy services.
Under Brazilian law, we are strictly liable for direct and indirect damages resulting from the inefficient rendering of energy generation, transmission, distribution and related services. In addition, when damages are caused to final customers as a result of outages or disturbances in the generation, transmission and distribution system, whenever these outages or disturbances are not attributed to an identifiable member of the ONS or to the ONS itself, the liability for such damages is shared among generation, distribution and transmission companies. Until a party with final responsibility has been identified, the liability for such damages will be shared in the proportion of 35.7% to the distribution agents, 28.6% to the transmission agents and 35.7% to the generation agents. The number of votes establishes these proportions that each of these types of energy concession holders receives in the general meetings of the ONS, and as such, are subject to change in the future. Consequently, our business, results of operations and financial condition might be adversely affected in the event we are held liable for any such damages.
Litigation & Legal Liabilities - Risk 4
We may incur losses and reputational damage in connection with pending litigation.
We are party to several legal and administrative proceedings relating to civil, administrative, environmental, tax, regulatory, labor and other claims. These claims involve a wide range of issues and seek indemnities and restitution in money and by specific performance. Several individual disputes account for a significant part of the total amount of claims against the Company. See "Item 8. Financial Information – Legal and Administrative Proceedings". Our consolidated financial statements include provisions for risks in a total amount of R$2,029 million, as of December 31, 2022, for actions in which the probability of loss have been assessed as ‘probable'. One or more unfavorable decisions against us in any legal or administrative proceeding may have a material adverse effect on us. In addition to making provisions and the costs associated with legal fees, we may be required by the court to provide collateral for the proceedings, which may adversely affect our financial condition. In the event that our provisions for legal actions are insufficient, payments for actions in excess of the amounts provisioned could adversely affect our results of operations and financial condition. In addition, a member of our board of directors is involved as a defendant in criminal proceedings that are currently pending, which may distract our management and negatively affect us and our reputation. See "Item 6. Significant Civil and Criminal Proceedings Involving Key Management Members".
Taxation & Government Incentives2 | 3.3%
Taxation & Government Incentives - Risk 1
Changes in Brazilian tax law or conflicts regarding its interpretation may adversely affect us.
The Brazilian Federal, state and municipal governments regularly implement changes in tax policies that affect us. These changes include the creation and alteration of taxes and charges, permanent or temporary, related to specific purposes of the government. Some of these governmental measures can increase our tax burden, which could affect our profitability, and consequently our financial condition. We cannot guarantee that we will be able to maintain our cash flow and profitability after an increase in taxes and charges that apply to us, and this might result in a material adverse effect on the Company.
Taxation & Government Incentives - Risk 2
The Brazilian Government may assert that the ADS taxation for Non- Resident Holders shall be payable in Brazil.
Pursuant to Section 26 of Law 10,833, published on December 29, 2003, the sale of property located in Brazil involving non-resident investors is subject to Brazilian income tax as of February 1, 2004. Currently, the Company understands that ADSs do not qualify as property located in Brazil and, thus, should not be subject to the Brazilian withholding tax; nevertheless, the Brazilian Tax Authorities may try to assert Brazilian tax jurisdiction in such condition, incurring on the payment of tax income in Brazil for the Non-Resident Holders.
Environmental / Social3 | 5.0%
Environmental / Social - Risk 1
The multiple uses of water and the various interests related to this natural resource might give rise to conflicts of interest between CEMIG and the society, which might cause losses to our business, results of operations or financial condition.
At present, considering projects and companies that are jointly controlled, CEMIG has 60 hydroelectric power plants, with 5,368 MW and representing 97% of our installed capacity. Water is the main raw material for CEMIG's production of energy and is a resource that is sensitive to climate change and vulnerable to the consequences of exploration of other natural resources, significantly impacted by human actions and subject to a regulatory environment. CEMIG's operation of reservoirs for generation of hydroelectric power essentially requires consideration of the multiple uses of water by other users in a river basin; and this in turn, leads to the need to take into account a range of constraints - environmental, safety, irrigation, human consumption, waterways and bridges, among others. In periods of severe drought, like those of 2013 until 2021, monitoring and forecasting the levels of reservoirs and the constant dialogue with the public authorities, civil society and users were essential for ensuring the generation of energy, and the other uses of this resource. Finally, CEMIG uses a Risk Management System to analyze scenarios and determine the degree of financial exposure to risks, considering the probability of occurrence and its effect. In the scenarios relating to potential conflicts with other users, CEMIG evaluates both the effects arising from prolonged droughts, which can lead to an increase of competition between the energy sector and other users, and the effects of flood events occurring due to excessive rain. While CEMIG engages with other essential users and takes steps to analyze community input and studies on issues relating to the impact of water use, competing interests relating to water use could, subject to certain minimum limits previously established by law, affect its availability to us for use in the operations of certain of our projects, which could adversely affect our business results of operations and financial condition.
Environmental / Social - Risk 2
Environmental regulations require us to perform environmental impact studies on future projects and obtain regulatory permits.
For reasons of obligations imposed by Brazilian environmental law, we must conduct environmental impact studies and obtain regulatory and environmental permits and licenses for our current and future projects. We cannot assure that these environmental impact studies will be approved by environmental agencies, that environmental licenses will be issued, that public opposition will not result in delays or modifications to any proposed project, or that laws or regulations will not change or be interpreted in a manner that could materially adversely affect our operations or plans for the projects in which we have an investment. We believe that concern for environmental protection is also an increasing trend in our industry. Although we consider environmental protection when developing our business strategy, changes in environmental regulations, or changes in the policy of enforcement of existing environmental regulations, could have a material adverse effect on our results of operations and our financial condition by delaying the implementation of energy projects, increasing the costs of expansion. Furthermore, the implementation of investments in the transmission sector has suffered delays due to the difficulty in obtaining the necessary regulatory and environmental permits and approvals. This has led to delays in investments in generation due to the lack of transmission lines to provide for the outflow of the energy generated. If we experience any of these or other unforeseen risks, we may not be able to generate, transmit and distribute energy in amounts consistent with our projections, which may have a material adverse effect on our financial condition and results of operations.
Environmental / Social - Risk 3
Requirements and restrictions imposed by environmental agencies might require the Company to incur additional costs.
Our operations relating to generation, distribution and transmission of energy and distribution of natural gas are subject to various Federal, state and municipal laws and regulations, and to numerous requirements relating to the protection of health and the environment. Delays by the environmental authorities, or the refusal of license requests by them, or any inability on our part to meet the requirements set by these bodies during the environmental licensing process, may result in additional costs, or even, depending on the circumstances, prohibit or restrict the construction or maintenance of these projects. Any non-compliance with environmental laws and regulations, such as construction and operation of a potentially polluting facility without a valid license or authorization, could give rise to the obligation to remedy any damages that are caused (third party liability) and result in criminal and administrative sanctions. Under Brazilian legislation, criminal penalties, such as imprisonment and restriction of rights, may be applied to individuals (including managers of legal entities), and penalties such as fines, restriction of rights or community service may be applied to companies. With respect to administrative sanctions, depending on the circumstances, the environmental authorities may: (i) impose warnings, or fines, ranging from R$50,000 to R$50 million; (ii) require partial or total suspension of activities; (iii) suspend or restrict tax benefits; (iv) cancel or suspend lines of credit from governmental financial institutions; or (v) prohibit us from contracting with governmental agencies, companies or authorities. Any of these actions could adversely affect our business, results of operations and financial condition. We are also subject to Brazilian legislation that requires payment of compensation if our activities have polluting effects. According to Federal Law 9,985/2000, Federal Decree 6,848/2009, and Minas Gerais State Decree 45,175/2009, up to 0.5% of the total amount invested in the implementation of a project that causes significant environmental impact should be used to pay for offsetting, based on the project's specific level of pollution and environmental impact. State Decree 45,175/2009 (‘Decree 45,175') also indicated that the compensation rate will be applied retroactively to projects implemented prior to promulgation of the present legislation. Among the provisions of law that can lead to operating investments and expenses, one is compliance with the Stockholm Convention on Persistent Organic Pollutants, to which Brazil is a signatory. This relates to the international commitment to eliminate the use of Polychlorinated Biphenyls (‘PCB') above 50 mg/kg by 2025, and the complete elimination by 2028, through Decree 5,472, of June 20, 2005. Currently there were two new legislations related to the theme: Law 14250/2021 and Interministerial Ordinance MMA/ MME 107/2022. Cemig need to adjust its practice and need to complete its inventory by PCB, according to these legislations. Further efforts may be required if there are new changes in the legislation. If we are unable to meet the technical requirements established by the environmental agencies during the process of licensing, this might prejudice the installation and operation of our projects, or make carrying out of our activities more difficult, which could negatively affect our business, financial, condition and results of operations. Finally, the adoption or implementation of new safety, health and environmental laws, new interpretations of existing laws, increased rigidity in the application of the environmental laws, or other developments in the future might require us to make additional capital expenditures or incur additional operating expenses in order to maintain our current operations. They might also restrain our production activities or demand that we take other action that could have an adverse effect on our business, results of operations or financial condition.
Production
Total Risks: 13/60 (22%)Below Sector Average
Manufacturing4 | 6.7%
Manufacturing - Risk 1
Brazil's supply of energy is heavily dependent on hydroelectric plants, which in turn depends on climatic conditions to produce energy. Adverse hydrological conditions that result in lower generation of hydroelectric power could adversely affect our business, results of operations and financial condition.
Hydroelectric generation is predominant in Brazil. The advantages of hydroelectric power have also been widely publicized due to it being a renewable resource and avoids substantial expenditures on fuels in thermal generation plants. At the same time, the main risk related to the use of this resource arises from the variability of the flows to the plants. There are substantial seasonal variations in monthly and annual flows, which depend fundamentally on the volume of rain that falls in each season. Adverse hydrological conditions in the Brazilian southeast region caused drought and water scarcity in the states of São Paulo, Minas Gerais and Rio de Janeiro in the past. These conditions might become worse during the dry period, which occurs from April through September. This could cause rationing of water consumption and/or energy, which could have a material adverse effect on the Company's business and results of operations. To deal with this difficulty, the Brazilian system has a complementary component of thermoelectric generation plants, and a growing portfolio of wind farms and Photovoltaic solar farms. It also has accumulation reservoirs, the purpose of which is to secure water from the rainy to the dry period and from one year to the next. However, these mechanisms are not able to absorb all the adverse consequences of a prolonged hydrological shortage, like the one that we have seen in the recent past. The National Energy System Operator (Operador Nacional do Sistema, or ‘ONS') coordinates the operation of the Brazilian energy system. Its primary function is to achieve optimal operation of the resources available, minimizing operating costs, and the risks of energy shortage. In periods when the hydrological condition is adverse, a decision by the ONS might, for example, reduce generation by hydroelectric plants and increase thermal generation, which results in higher costs for the hydroelectric generating agents, as happened in 2014. In the distributors, this increase in costs generates an increase in the purchase price of energy that is not always passed through to the customer at the same moment, generating mismatches in cash flows, with an adverse effect on the business and financial condition of those distributors. In addition, in extreme cases of scarcity of energy due to adverse hydrological conditions, the system might undergo rationing, which could result principally in reduction of cash flow. The MRE aims to mitigate the impact of the variability of generation of the hydroelectric plants. This mechanism shares the generation of all the hydroelectric plants in the system in such a way as to supplement the shortage of generation of one plant with excess generation by another. However, this mechanism is not able to eliminate the risk of the generation players, because when there is an extremely unfavorable hydrological condition, to the extent that all the plants in aggregate are unable to reach the sum of their Physical Guarantee levels of energy output, this mechanism makes an adjustment to the Physical Guarantee of each plant through the Physical Guarantee Adjustment Factor (Fator de Ajuste da Garantia Física, or ‘GSF'), resulting in the generating companies being exposed to the short-term (‘spot') market. The company transferred to captive customers the hydrological risk related to Queimado and Irapé power plants (Regulated Market Contracts), in exchange for payment of a ‘risk premium', while also receiving indemnity for the losses suffered in 2015. In the free market, we do not have the same process, since even with the payment of the premium, generation companies would have had to continue assuming the hydrological risk at moments of critical hydrology. Thus, no plant that sells energy in the free market signed up for any renegotiation of hydrological risk. Those operators that did not subscribe to the renegotiation continued to have injunctions preventing charging of the hydrological risk in full. These injunctions are causing a deficit of R$1.124 billion in the short-term market as of December 2022. This position increases the level of default calculated by the CCEE, thus reducing the amounts received by creditor agents in the short-term market. To avoid this effect, some creditor agents filed for further injunctions to acquire the right to priority in receipt. This effect leads to uncertainty in the market, reduction of liquidity, increase of default, and reduction in amounts received in the short-term market, representing a risk for the Company. Any substantial seasonal variation in the monthly flows and in the total of flows over the year could limit hydroelectric generation, making it necessary to use alternative generation systems, which could have a significant adverse effect on the Company's costs, including court fees and expenses relating to the subject. Law 14,052/2020 and Resolution 895/2020 proposed the reimbursement of agents holding the concession of hydraulic plants in the MRE of the effects: (i) generation in disregard of the merit order which means dispatching energy to the grid in disregard of the ascending price ranking for energy generation, (ii) anticipation of delivery of firm energy to the system of relevant power plants, and (iii) restriction to the supply of energy to the grid due to delay in the transmission system. These effects were calculated retroactively from 2012 to 2020, updated and remunerated at the ANEEL rate of 9.63%. The amount has been paid through extension of the plants' concession. With this new agreement, injunctions are expected to be withdrawn and market deficits to be settled. In this way, the liquidity of the market in the short term and the default in the CCEE should return to their historical values.
Manufacturing - Risk 2
Delayed completion of construction projects or late capitalization of new investments in our generation, transmission and distribution companies could adversely affect our business, operating results and financial condition.
We are constantly engaged in the construction and expansion of our plants, transmission lines, distribution networks and substations, and regularly consider other potential expansion projects. The Company's ability to complete projects within deadlines and on budget, without adverse economic effects, is subject to various risks. For instance, we may encounter the following: - Complications in the planning and execution stages of expansion of the electrical system projects and other new investments may occur, such as strikes, lagging suppliers of materials and services, delays in tender processes, embargos on work, unexpected geological and climate conditions, political and environmental uncertainties, financial instability of our partners, contractors and subcontractors;- Regulatory or legal challenges that delay the start-up of operations of new assets;- New assets might operate below planned capacity, or cost related to their operation or installation may be higher than planned;- Difficulty in obtaining adequate working capital to fund expansion projects;- The unintentional shutdown of transmission assets during execution of the expansion projects can reduce the revenue of the Transmission business;- ONS's (‘Operador Nacional do Sistema', Brazil's ISO) refusal to authorize the execution of work on the transmission grid, due to power system restrictions; and - Environmental demands and claims by local communities during construction of power generation plants, transmission lines, distribution lines, distribution networks and substations. If faced with any of these or similar issues related to the new investments or to the expansion of our generation, transmission or distribution capacity, the Company might incur increased costs or lower profitability than originally expected for the projects.
Manufacturing - Risk 3
Dams are part of the critical and essential infrastructure in the Brazilian energy sector. Dam failures can cause serious damage to affected communities and to the Company.
There is an intrinsic risk of dam failure, due to factors that may be internal or external to the structure (such as, for example, failure of a dam upstream from the site). The scale, and nature, of the risk are not entirely predictable. Thus, we are subject to the risk of a dam failure that could have repercussions far greater than the loss of hydroelectric generation capabilities. The failure of a dam could result in economic, social, regulatory, and environmental damage and potential loss of human life in the communities downstream from dams, which could have a material adverse effect on the Company's image, business, results of operations and financial condition.
Manufacturing - Risk 4
We might be held responsible for impacts on our own workforce, on the population and the environment, due to accidents related to our generation, transmission and distribution systems and facilities.
Our operations, especially those related to transmission and distribution lines, present risks that may lead to accidents, such as electrocutions, explosions and fires. These accidents may be caused by natural occurrences, human errors, technical failures and other factors. As a significant part of our operations is conducted in urban areas, the population is a factor to be constantly considered. Any incident that occurs at our facilities or in human occupied areas, whether regularly or irregularly, can result in serious damages such as loss of life, environmental and material damage, loss of production and liability in civil, criminal and environmental lawsuits. These events may also result in reputational damage, financial damages, penalties for the Company and its officers and directors, and difficulties in obtaining or maintaining concession contracts and operating licenses.
Employment / Personnel3 | 5.0%
Employment / Personnel - Risk 1
We may be exposed to behaviors that are incompatible with our standards of ethics and compliance, and we might be unable to prevent, detect or remedy them in time, which might cause material adverse effects on our business, results of operations, financial condition and reputation.
Our businesses, including our relationships with third parties, are guided by ethical principles and rules of conduct that we have established. We have a range of internal rules that aim to orient our managers, employees and contractors, and to reinforce our ethical principles and rules of professional conduct. Due to the wide distribution and outsourcing of the production chains of our suppliers, we are unable to control all possible irregularities of these third parties. This means that we cannot guarantee that the financial, technical, commercial and legal evaluations that we use in our selection processes will be sufficient prevent our suppliers from having problems related to employment law, or sustainability, or in the outsourcing of the production chain with inadequate safety conditions. We also cannot guarantee that these suppliers, or third parties related to them, will not involve themselves in irregular practices. If a significant number of our suppliers involve themselves in irregular practices, we might be adversely affected. Furthermore, we are subject to the risks that our employees, contractors or any person who may do business with us might become involved in activities of fraud, corruption or bribery, circumventing our internal controls and procedures, misappropriating or using our assets for private benefit to the detriment of the Company's interests. This risk is exacerbated by the fact that there are some affiliates, such as special-purpose companies and joint ventures, in which we do not have control. Our internal controls systems to identify, monitor and mitigate risks may not be effective in all circumstances, especially in relation to companies that are not under our control. In the case of companies, we have acquired, our internal controls systems might be incapable of identifying fraud, corruption or bribery that took place prior to the acquisition. Any failing in our capacity to prevent or detect non-compliance with the applicable rules of governance or of regulatory obligation could cause harm to our reputation, limit our capacity to obtain financing, or otherwise cause material adverse effects on our, business, results of operations, financial condition and reputation.
Employment / Personnel - Risk 2
Potential shortages of skilled personnel in operational areas could adversely affect our business and results of operations.
It is possible that we will experience shortages of qualified key personnel. In recent years, we have been carrying out voluntary severance incentive programs open to all our employees. Such programs may reduce our employees' headcount by more than our ability to hire new ones to fill key positions. Our success depends on our ability to continue to successfully train our personnel so they can assume key positions in the organization. We cannot assure you that we will be able to properly train, qualify or retain key staff, or do so without costs or delays. Nor can we assure you that we will be able to hire new qualified personnel, in particular in operational areas, should the need arise. Any such failure could adversely affect our results of operations and our business.
Employment / Personnel - Risk 3
Strikes, work stoppages or labor unrest by our employees or by the employees of our suppliers or contractors could adversely affect our results of operations and our business.
All of our employees are represented by labor unions. Disagreements on issues involving divestments or changes in our business strategy, reductions in our personnel, as well as potential employee contributions, could lead to labor unrest. We cannot ensure that strikes affecting our production levels will not occur in the future. Strikes, work stoppages or other forms of labor unrest at any of our major suppliers, contractors or their facilities could impair our ability to operate our business, complete major projects and adversely affect our ability to achieve our long-term objectives.
Supply Chain1 | 1.7%
Supply Chain - Risk 1
Disruptions in the operation of, or deterioration of the quality of, our services, or those of our subsidiaries, could adversely affect our business, operating results and financial condition.
The operation of a complex system that interconnects numerous power generation plants with large transmission lines and distribution networks involves various risks, operational difficulties and unexpected interruptions, caused by accidents, equipment failure, underperformance or disasters (such as explosions, fires, climate events, floods, landslides, sabotage, terrorism, vandalism and other similar events). In the event of any such occurrence, the insurance coverage for operational risks may be insufficient to fully repay the asset damage or service interruption costs incurred. In addition, National Grid Operator decisions, Regulatory Agency acts, and Environmental Authority demands could adversely affect our business. The Company's income is highly dependent on equipment availability, service quality and regulatory compliance of the assets and facilities it builds, operates and maintains. Failure to comply may lead to business and operating losses. For example, the distribution business may be penalized in the tariff revision process with a higher "X-factor", would reducing its expected annual revenue requirement; the transmission business may have its annual permitted revenue reduced due to any asset unavailability; and the generation business may have its earnings affected if a power plant does not meet minimum availability levels, because in the event that hydro generation does not fully meet previously contracted energy levels, the equivalent shortfall has to be acquired at the spot price, which is highly volatile. Penalties and financial compensation are applicable depending on the scope, severity and duration of the service or equipment unavailability. Thus, disruptions in power plants, transmission and distribution facilities, substations or networks, may have a material adverse effect on our business, financial condition and operating results.
Costs5 | 8.3%
Costs - Risk 1
Added
Increases in energy generated by MMGD in Cemig D's concession area could cause an imbalance in its cash flows and financial results.
The tariffs of the distribution companies in Brazil carry numerous benefits aimed at specific sectors, subsidies that have been increasing the charges passed on to final consumers. In the case of subsidies to renewable generation (through what we call ‘TUSD/TUST Discounts'), the approval of Law 14,300/2022 defined a deadline for granting those benefits, thereby limiting such benefits. Furthermore, the state of Minas Gerais (Cemig D's concession area) has two other factors that stimulate the implementation of projects characterized as distributed generation (‘MMGD'): (i) a high ICMS (state taxes that directly impact consumers' final power tariffs) rate and (ii) large area with great insolation that benefits photovoltaic electricity generation. These points have led to an exponential growth in the implementation of photovoltaic plants in Cemig D's concession area. With the expansion of MMGD connections in Cemig D's concession area, regulated customer consumption will be partially supplied by this distributed generation, rather than the energy supply contracts purchased by the Company. This has created an excess of energy above the regulatory limit (5%). However, there are regulatory mechanisms that allow distributors to exchange energy, enabling Cemig D to reduce its energy purchases in years where the excess is above the permitted limit when possible. Additionally, Federal Law 14,300/22 guarantees that the costs associated with this excess will be passed on to tariffs in the following year. Despite these mechanisms, energy purchases must be invoiced and the surplus is valued at the short-term price, typically lower than acquisition costs. This difference can create a cash flow mismatch, since the pass-through to tariffs only occurs in the next tariff cycle. In addition, the customers in question are using a billing method called "net metering" (‘NEM'). This means that if a customer's energy generation exceeds their on-site needs and is exported back to the grid, they will receive a bill credit. This credit will be applied to their monthly bill at the same retail rate that they would have paid for energy consumption according to their normal rate structure. While this benefits the customer by reducing their costs, it could cause a cash flow concern for the Company as it is effectively subsidizing the excess energy generated by the customer.
Costs - Risk 2
A substantial portion of the Company's assets is tied to the provision of public services and would not be available for attachment as collateral for the enforcement of any court decision.
A substantial portion of the Company's assets is tied to the provision of public services. These assets cannot be attached as collateral for the enforcement of any court decision because the assets revert to the concession-granting authority to ensure continuity in the provision of public services, according to applicable legislation and our concession agreements. Although the Brazilian Federal Government would be obligated to compensate us for early termination of our concessions, we cannot assure you that the amount ultimately paid by the Brazilian Federal Government would be equal to the market value of the reverted assets. These restrictions on liquidation may lower significantly the amounts available to holders of the notes in the event of our liquidation and may adversely affect our ability to obtain adequate financing.
Costs - Risk 3
We operate without insurance policies against catastrophes and third-party liability.
Except for use of aircraft, fire and certain operational risks, we do not have third-party liability that covers accidents and we do not seek proposals for this type of insurance. CEMIG has not sought a proposal for, and has not contracted, insurance coverage against disasters, such as earthquakes or floods, that might affect our facilities. Any events of this type could generate unexpected additional costs, resulting in adverse effects on our business, results of operations and financial condition.
Costs - Risk 4
The insurance contracted by us might be insufficient to reimburse costs of damage.
Our business is normally subject to a range of risks, including industrial accidents, labor disputes, unexpected geological conditions, changes in the regulatory environment, environmental and climatic risks, and other natural phenomena. In addition, we and our subsidiaries might be found responsible for losses and damages caused to third parties as a result of failures to provide generation, transmission and/or distribution service. We only maintain insurance for fire, risks involving our aircraft, and operational risks, as well as those types of insurance coverage that are required by law, such as transport insurance of goods belonging to legal entities. We cannot guarantee that the insurance contracted by us will be sufficient to cover in full or at all any liabilities that may arise in the course of our business nor that these insurance policies will continue to be available in the future. The occurrence of claims in excess of the amount insured, or which are not covered by our insurance policies, might generate significant and unexpected additional costs, which could have an adverse effect on our business, results of operations and/or financial condition. Further, we cannot guarantee that we will be able to maintain our insurance coverage at favorable or acceptable commercial prices in the future.
Costs - Risk 5
Increases in energy purchase prices could cause an imbalance in CEMIG D's cash flows.
The expense for purchase of power from the distributors is currently strongly linked to the Differences Settlement Price (Preço de Liquidação de Diferenças, or ‘PLD') (Availability Contracts, Physical Guarantee quotas, and Itaipu Hydroelectric Plant quotas) and to MRE's adjustment factor (Physical Guarantee quotas, Itaipu quotas and Hydrological Risk of the plants that have been renegotiated). Therefore, an adverse period in terms of rainfall may result in high spot prices and lower hydro generation that may affect the cash flow. The ‘Flag Account' (Conta Centralizadora de Recursos de Bandeiras Tarifárias – CCRBT or ‘Conta Bandeira') was created to stabilize this issue. This account manages the additional funds that are collected from captive customers of distribution concession. This additional payment is defined monthly based on the assessment made by the ISO based on the supply condition of the system. Based on this analysis, ANEEL defines in which flag baseline (green, yellow, red 1 and red 2) the tariffs will be adjusted. Raises in the tariffs are indicated from the yellow flag baseline, indicating that the costs to purchase energy raised. The methodology of the Tariff Flag system is reviewed every year; however, under the present methodology, when very adverse conditions occur the system may not respond sufficiently, resulting in negative effects on distributors' cash position. This factor could have an adverse effect on our business, operating results and financial condition. By the end of 2021, the hydrological conditions started to get better and in the beginning of 2022 that was reflected in lower energy costs. The ‘Flag Account' deficit reached a record low by the end of 2021, but the increased amount of surcharge had a very positive effect and by April 2022 the deficit ended. Due to the positive period in terms of rainfall in 2022, there was no need for an additional surcharge during 2022.
Macro & Political
Total Risks: 10/60 (17%)Above Sector Average
Economy & Political Environment5 | 8.3%
Economy & Political Environment - Risk 1
Political and economic instability in Brazil could have effects on the economy and affect us.
Historically, the Brazilian political environment has influenced, and continues to influence, the performance of the country's economy. Political crises has affected and continue to affect investor confidence and that of the general public, which resulted in economic deceleration and heightened volatility in the securities issued by Brazilian companies. The President of Brazil has power to determine the governmental policies and actions related to the Brazilian economy and, consequently, to affect the operations and financial performance of companies, including ours. General elections were held in October 2022, and Luiz Inácio Lula da Silva was elected as President and Geraldo Alckim as Vice President, in addition to elections in the National Congress. In addition, on the same date elections for State Governors and Vice Governors, as well as State Legislative Assemblies, including those of Minas Gerais, were held. The results of these elections, and the policies eventually implemented by both the Federal Government and State governments, could have a material impact on our business. Furthermore, Brazilian markets have experienced a high level of volatility due to the uncertainties arising from ongoing anticorruption and other investigations being carried out by the Brazilian Federal Prosecutors, and their impact on the economy and on the Brazilian political environment. Such events could cause the trading value of our shares, preferred and common, of our preferred and common ADSs, and our other securities to be reduced, and could negatively affect our access to the international financial markets. Furthermore, any political instability resulting from such events, including upcoming political elections at the federal and state levels, if it affects the Brazilian economy, could cause us to re-evaluate our strategy.
Economy & Political Environment - Risk 2
The Brazilian Federal Government has exercised, and continues to exercise, significant influence on the Brazilian economy. Political and economic conditions can have a direct impact on our business, financial condition, results of operations and prospects.
The Brazilian Federal Government frequently intervenes in the country's economy and occasionally makes significant changes in monetary, fiscal and regulatory policy. Our business, results of operations and financial condition may be adversely affected by changes in government policies, as well as other factors including, without limitation: - Fluctuations in the exchange rate;- Regulatory policy for the energy sector;- Inflation;- Changes in interest rates;- Fiscal policy;- Other political, diplomatic, social and economic developments which may affect Brazil or the international markets;- Liquidity of the domestic markets for capital and loans;- Development of the energy sector;- Controls on foreign exchange and restrictions on remittances out of the country; and/or - Limits on international trade. Uncertainty on whether the Brazilian Federal Government will make changes in policy or regulation that affect these or other factors in the future might contribute to the economic uncertainty in Brazil and to greater volatility of the Brazilian securities-markets and the markets for securities issued outside Brazil by companies. Measures by the Brazilian Federal Government to maintain economic stability, and speculation on any future acts of the Brazilian Federal Government, might generate uncertainties in the Brazilian economy, and increase the volatility of the domestic capital markets, adversely affecting our business, results of operations and financial condition. If the political and economic conditions deteriorate, we may also face increased costs. These uncertainties may adversely affect our business, results of operations and financial condition.
Economy & Political Environment - Risk 3
Inflation and certain government measures aimed to control it might contribute significantly to economic uncertainty in Brazil and could have a material adverse effect on our business, results of operations, financial condition and the market price of our shares.
Brazil has historically experienced extremely high rates of inflation. Inflation, and some of the Federal Government's measures taken in an attempt to curb inflation, have had significant negative effects on the Brazilian economy. Since the introduction of the Real in 1994, Brazil's inflation rate has been substantially lower than in previous periods. Brazilian annual inflation as measured by the IPCA index in the years 2020, 2021 and 2022 was, respectively, 4.52%, 10.06% and 5.79%. In 2021, the inflation rate was impacted partially due to global supply chain residuals from the 2020 pandemic effects. No assurance can be given that inflation will remain at these levels. Future measures taken by the Federal Government, including increases in interest rates, intervention in the foreign exchange market or actions intended to adjust the value of the Real, might cause an increase in the rate of inflation, and consequently, have an adverse economic impact on our business, results of operations and financial condition. If Brazil experiences high inflation rates in the future, we might be unable to adjust the rates we charge our customers to offset the effects of inflation on our cost structure. A significant increase in interest rates or inflation would have an adverse effect on our finance expenses and financial results as a whole. At the same time, a significant reduction in the CDI rate (interest rate for interbank deposit), or in inflation, could negatively affect the revenue generated by our financial investments, but also have the positive effect of revaluing adjustments to the balances of our concession financial assets. Substantially, all our cash operating expenses are denominated in Reais and tend to increase with Brazilian inflation. Inflationary pressures might also hinder our ability to access foreign financial markets or might lead to further government intervention in the economy, including the introduction of government policies that could harm our business, results of operations and financial condition or adversely affect the market value of our shares and as a result, of our preferred ADSs, common ADSs and other securities.
Economy & Political Environment - Risk 4
Added
The continuing impact of the ongoing military conflict between Russia and Ukraine, or any widening of the conflict, may have a material adverse effect on the global economy, certain material and commodity prices and potentially on our business.
Global markets are currently operating in a period of economic uncertainty, volatility and disruption as the military conflict between Russia and Ukraine continues. Such military conflict and the effect of the resulting economic sanctions imposed on Russia and certain Russian citizens and enterprises, as well as the potential Russian response to such sanctions or any further sanctions, could have a negative effect on the global economy and are highly uncertain and difficult to predict. As a result, many entities outside the region may be adversely affected by rising prices of commodities such as oil, gas and wheat, or by a potential slowdown in the global economy. The occurrence of large-scale business disruptions potentially gives rise to liquidity issues for certain entities and there may also be consequential impacts on the credit quality of some suppliers. As of the date of this annual report, while we are not directly involved in the region and, therefore, our exposure to Russia and Ukraine is limited, considering the uncertainties surrounding the impact of the conflict on global economy, we are unable to estimate the extent of any potential effects of the conflict or any escalation of the conflict on our business, results of operation or financial condition.
Economy & Political Environment - Risk 5
Changes in economic and market conditions in other countries, especially Latin American and emerging market countries, may adversely affect our business, results of operations and financial condition, as well as the market price of our shares, preferred ADSs and common ADSs.
The market value of the securities of Brazilian companies is affected to varying degrees by economic and market conditions in other countries, including other Latin American countries and emerging market countries. Although the economic conditions of such countries may differ significantly from the economic conditions of Brazil, the reactions of investors to events in those countries may have an adverse effect on the market value of the securities of Brazilian issuers. Crisis in other emerging market countries might reduce investors' interest in the securities of Brazilian issuers, including our Company. In the future, this could make it more difficult for us to access the capital markets and finance our operations on acceptable terms or at all. Due to the characteristics of the Brazilian power industry (which requires significant investments in operating assets) and due to our financing needs, if access to the capital and credit markets is limited, we could face difficulties in completing our investment plans and the refinancing our obligations, and this could adversely affect our business, results of operations and financial condition.
Natural and Human Disruptions2 | 3.3%
Natural and Human Disruptions - Risk 1
Climate change can have significant impacts on our distribution, generation and transmission activities.
The effects of climate change, the increase in the frequency and intensity of extreme climate events and regulatory changes can directly affect our distribution, generation and transmission activities, which can lead to financial impacts, loss of competitiveness, risk of disinvestment and reputational damage. Given that virtually all of Cemig's generation site is composed of hydroelectric power plants, changes in rainfall totals and rainfall dispersion impact certain business activities. Extreme events can also impact distribution and transmission activities, mainly related to asset availability. On the other hand, high water flow is also a potential risk, since the Company is required to open floodgates to ensure dam safety, thus flooding the downstream area. Moreover, with increased severity and frequency of extreme climate events, such as cyclones and floods, heavy rainfall may occur in a short period accompanied by windstorms and lightning. These events may damage power transportation and distribution facilities, making the resource unavailable to customers. Furthermore, Cemig may be required to adjust to possible regulatory changes defined by the government to achieve the goals to which it has committed through the National Policy on Climate Change, which defines commitments to reduce emissions by 2030, and through emerging regulations that include carbon pricing mechanisms. The actions include a regulation applicable to the consumption of fossil fuels. The carbon price applied in the fuel sector would imply an increase in fossil fuel prices or fossil source-based thermal plants. Cemig's business may also be impacted by new technologies in the medium and long term if it does not build strategic partnerships or is unable to implement technological changes to its services. If we fail to adapt or experience delays in adapting to this new global scenario, our operations and financial results may be adversely affected.
Natural and Human Disruptions - Risk 2
Changed
The outbreak of disease and health epidemics, such as the Covid-19 pandemic, could adversely affect our business, operational results and financial condition.
The COVID-19 pandemic necessitated governments, including in Brazil, to respond at unprecedented levels to protect public health, and to support local economies and livelihoods. The resulting government support measures and restrictions created additional challenges given the rapid pace of change and significant operational demands. Any renewed outbreaks, particularly those resulting from the emergence of new variants of the virus, could result in the tightening of government restrictions. The Company continues to closely monitor any further impacts of the Covid-19 pandemic on the Brazilian macroeconomic environment, especially in relation to its business and the market in which it operates, in order to decide on actions to maintain the sustainability of its operations, mitigate economic and financial effects, and protect the health of its employees. The Company established the Coronavirus Crisis Management Committee (‘Comite Diretor de Gestão da Crise do Coronavírus') in March 2020, to ensure its readiness to make decisions in light of the fast-changing condition. Several measures were taken to protect the Company´s liquidity position in 2020, such as capital expenditure restraints and expense reductions, the payment of only minimum mandatory dividends to shareholders, and deferral of dividends and interest on equity to the end of 2020 and the negotiating of contracts with its customers on the free market. In order to cope with the reduction in collections resulting from the economic crisis, in 2020 measures to support the sector were implemented by the Grantor and regulated by ANEEL, with a view to ensure that companies maintain adequate liquidity and were able to comply with contracts in the electricity sector supply chain. This scenario resulted in the need for internal reassessment by the Company of its Investment Program, revision of the budgets for revenue and expenses, and alteration of the assumptions used in calculating the fair and recoverable value of certain financial and non-financial assets. Among the measures implemented by ANEEL having a greater financial impact on us was the creation of the ‘Covid-account', issued on May 18, 2020, to support the energy distribution sector, which, as the customer interface, is the basis of the energy sector financial flow, aimed either to cover the distribution agents revenue/cash flow deficit or to anticipate sector receivables. The ‘Covid-account' increased CEMIG D's cash flow by R$1.4 billion in 2020 enabling it to meet its financial obligations, in spite of the collection reduction resulting from the economic crisis. For the year ended on December 31, 2022, COVID-19 pandemic did not have a significant negative impact on our business nor results of operations. In accordance with World Health Organization (WHO), on May 5, 2023, more than three years into the pandemic, the WHO Emergency Committee on COVID-19 recommended to the Director-General, who accepted the recommendation, that given the disease was by now well-established and ongoing, it no longer fit the definition of a Public Health Emergency of International Concern (PHEIC). This does not mean the pandemic itself is over, but the global emergency it has caused is, for now. A Review Committee to be established will develop long-term, standing recommendations for countries on how to manage COVID-19 on an ongoing basis.
Capital Markets3 | 5.0%
Capital Markets - Risk 1
The stability of the Brazilian Real is affected by its relationship with the U.S. dollar, inflation and Brazilian Federal Government policy regarding exchange rates. Our business could be adversely affected by any recurrence of volatility affecting our foreign currency-linked receivables and obligations as well as increases in prevailing market interest rates.
The Brazilian currency has experienced high degrees of volatility in the past. The Brazilian Federal Government has implemented several economic plans and has used a wide range of foreign currency control mechanisms, including sudden devaluation, small periodic devaluation during which the occurrence of the changes varied from daily to monthly, floating exchange market systems, exchange controls and parallel exchange market. From time to time, there was a significant degree of fluctuation between the U.S. dollar and the Brazilian Real and other currencies. On December 30, 2022, the exchange rate between the Real and the US dollar was R$5.2860 for US$1.00. There is no guarantee that the Real will not depreciate, or appreciate, in relation to the US dollar, in the future. The instability of the Brazilian Real/U.S. Dollar exchange rate could have a material adverse effect on us. Depreciation of the Real against the United States dollar and other principal foreign countries could create inflationary pressures in Brazil and cause increases in interest rates, which could negatively affect the growth of the Brazilian economy, and consequently, our growth. Depreciation of the Real could cause an increase in financial and operating costs, since we have payment obligations under financing contracts and import contracts indexed to exchange rate variations. In addition, depreciation of the Real could cause inflationary pressure that might result in abrupt increases in the inflation rate, which would increase our operating costs and expenses, which might adversely affect our business, results of operations, or outlook. We generally do not enter into derivative contracts or similar financial instruments or make other arrangements with third parties to hedge against the risk of an increase in interest rates. To the extent that such floating rates rise, we may incur additional expenses. Additionally, as we refinance our existing debt in the coming years, the mix of our indebtedness may change, specifically as it relates to the ratio of fixed to floating interest rates, the ratio of short-term to long-term debt, and the currencies in which our debt is denominated or to which it is indexed. Changes that affect the composition of our debt and cause rises in short or long-term interest rates may increase our debt service payments, which could have an adverse effect on our results of operations and financial condition.
Capital Markets - Risk 2
Instability of the exchange rate could adversely affect the value of remittances of dividends outside Brazil, and the market price of the ADSs.
Many Brazilian and global macroeconomic factors have an influence on the exchange rate. In this context, the Brazilian Federal Government, through the Central Bank, has in the past occasionally intervened for the purpose of controlling unstable variations in exchange rates. We cannot predict whether the Central Bank or the Federal Government will continue to allow the Real to float freely or whether it will intervene through a system involving an exchange rate band, or the use of other measures. This being so, the Real might fluctuate substantially in relation to the United States dollar, and other currencies, in the future. That instability could adversely affect the equivalent in US dollars of the market price of our shares, and as a result the prices of our ADSs, common and preferred, and also outward dividends remittances from Brazil.
Capital Markets - Risk 3
Exchange controls and restrictions on remittances from Brazil might adversely affect holders of preferred and common ADSs.
Investors in our preferred and common ADSs may be adversely affected by the imposition of restrictions on the remittance to foreign investors of the proceeds of their investments in Brazil and the conversion from Reais (R$) into foreign currencies. Restrictions of this type would hinder or prevent the conversion of dividends, distributions or the proceeds from any sale of preferred shares or common shares from Reais (R$) into U.S. dollars (US$). We cannot guarantee that the Federal Government will not take restrictive measures in the future.
Tech & Innovation
Total Risks: 2/60 (3%)Below Sector Average
Cyber Security2 | 3.3%
Cyber Security - Risk 1
Cyberattacks, or violation of the security of our data might lead to an interruption of our operations, or a leak of confidential information either of the Company, or of our customers, third parties or interested parties, might cause financial losses, legal exposure, damage to reputation or other severe negative consequences for the Company.
We manage and store personal and sensitive or confidential data related to our business. Our information technology systems may be vulnerable to a variety of and cybersecurity breaches and incidents. Computer hackers may be able to penetrate our network security and misappropriate or compromise our confidential information or that of third parties, create system disruptions, or cause shutdowns. Computer hackers also may be able to develop and deploy viruses, worms and other malicious software programs that attack our products or otherwise exploit any security vulnerabilities of our products. The costs we may incur to eliminate or address the security problems and security vulnerabilities before or after a cyber-related incident could be significant. Our remediation efforts may not be successful and could result in interruptions, delays or cessation of service, and loss of existing or potential customers that may impede our critical functions. Successful cybersecurity attacks, breaches, employee malfeasance, or human or technological error may result in unauthorized access to, disclosure, modification, improper use, loss or destruction of data or systems, including those belonging to us, our customers or third parties; theft of sensitive, regulated or confidential data including personal information; the loss of access to critical data or systems through ransomware, destructive attacks or other means; transaction errors; business delays; and service or system disruptions. We have observed an increase in cybersecurity attacks worldwide in recent years. In the event of such actions, we, our customers or other third parties could be exposed to risk of loss or improper use of this information, resulting in litigation and potential liability, damage to our brand and reputation, or other harm to our business. In addition, we rely on third-party infrastructure providers whose potential security vulnerabilities could have an impact on our business. The regulatory environment with regards to cybersecurity, privacy and data protection issues is increasingly complex and may have impacts on our business, including increased risk, costs and expanded compliance obligations.
Cyber Security - Risk 2
Failures in the security of our databases containing customer personal data, as well as events related to noncompliance with data privacy and protection legislation may have an adverse effect on our business, results of operations and reputation.
We have databases containing collected personal data from our customers, partners and collaborators. Any improper use of this data, or failures in the correct use of our security protocols may negatively affect the integrity of those databases. Unauthorized access to information concerning our customers, or unauthorized disclosure of sensitive information, may subject us to lawsuits, and as consequence, we might incur financial liabilities, penalties and reputational damage. The Brazil General Data Protection Law (Lei Geral de Proteção de Dados Pessoais, or ‘LGPD'), was signed into law in August 2018 and came into effect on September 18, 2020, with the exception of the administrative sanctions, which came into effect in August 2021. LGPD establishes rules and obligations regarding the collection, processing, storage and use of personal data and impacts all economic sectors including the relationship between customers and suppliers of goods and services, employees and employers and other relationships in which personal data is collected, whether in a digital or physical environment. Violations of the LGPD carry financial risks due to penalties for data breach or improper processing of personal data. The new legislation establishes penalties for non-compliance that include application of fines of up 2% of revenues, limited to R$50 million, for the most serious infringements. An increased number of data protection laws the globe may continue to result in increased compliance costs and risks. The potential costs of compliance with or imposed by new or existing regulations and policies that are applicable to us may affect our business and could have a material adverse effect on our results of operations.
Ability to Sell
Total Risks: 2/60 (3%)Below Sector Average
Demand1 | 1.7%
Demand - Risk 1
Changed
The level of default by our customers could adversely affect our business, operating results and/or financial condition, as well as those of our subsidiaries.
On December 31, 2022, the past-due receivables from our customers were R$1,825 million compared to R$1,249 million in 2021. In 2022, we recorded a provision for expected credit losses in the amount of R$820 million, compared to R$833 million in 2021. The possibility exists that we may be unable to collect all of the amounts receivable from our customers, which are in arrears due to events beyond the control of the Company, such as limiting the performance of the suspension of energy supply by the regulatory body of the sector. If we are unable to collect all or a portion of our past-due receivables or incur losses in excess of our allowance for doubtful accounts, our results of operations and financial condition may be materially adversely affected.
Sales & Marketing1 | 1.7%
Sales & Marketing - Risk 1
Changed
ANEEL has discretion to establish the rates that distributors charge their customers. These rates are determined by ANEEL in such a way as to preserve the economic and financial balance of concession contracts entered into with the federal Union.
Concession agreements and Brazilian law have established a mechanism that permits three types of rate adjustment: (a) the Annual Adjustment; (b) the Periodic Review; and (c) the Extraordinary Review. The purpose of the Annual Adjustment (‘Reajuste Annual') is to compensate for changes in costs that are beyond a company's control, such as the cost of energy for supply to customers, the sector charges that are set by the Federal Government, and charges for use of the transmission and distribution facilities of other companies. Manageable costs, on the other hand, are adjusted by the IPCA inflation index, less a productivity and efficiency factor, known as the X Factor, which considers aspects such as distribution productivity and service quality standards. Every five years, there is a Periodic Tariff Review (Revisão Periódica Tarifária, or ‘RTP'), the purpose of which is to: identify the variations in costs referred to above; provide an adequate return on the assets that the Company has constructed during the period, establish a factor based on economies of scale, which will be taken into account in the subsequent annual tariff adjustments and define the efficient operational costs. An Extraordinary Tariff Review takes place whenever there is any unforeseen development that significantly alters the economic/financial equilibrium of the concession. Thus, although CEMIG D's concession contracts specify preservation of their economic and financial balance, we cannot guarantee that ANEEL will set tariffs that do remunerate us adequately in relation to the investments made or the operating costs incurred due to the concession, and this might have a material adverse effect on our business, financial condition and operating results.
See a full breakdown of risk according to category and subcategory. The list starts with the category with the most risk. Click on subcategories to read relevant extracts from the most recent report.

FAQ

What are “Risk Factors”?
Risk factors are any situations or occurrences that could make investing in a company risky.
    The Securities and Exchange Commission (SEC) requires that publicly traded companies disclose their most significant risk factors. This is so that potential investors can consider any risks before they make an investment.
      They also offer companies protection, as a company can use risk factors as liability protection. This could happen if a company underperforms and investors take legal action as a result.
        It is worth noting that smaller companies, that is those with a public float of under $75 million on the last business day, do not have to include risk factors in their 10-K and 10-Q forms, although some may choose to do so.
          How do companies disclose their risk factors?
          Publicly traded companies initially disclose their risk factors to the SEC through their S-1 filings as part of the IPO process.
            Additionally, companies must provide a complete list of risk factors in their Annual Reports (Form 10-K) or (Form 20-F) for “foreign private issuers”.
              Quarterly Reports also include a section on risk factors (Form 10-Q) where companies are only required to update any changes since the previous report.
                According to the SEC, risk factors should be reported concisely, logically and in “plain English” so investors can understand them.
                  How can I use TipRanks risk factors in my stock research?
                  Use the Risk Factors tab to get data about the risk factors of any company in which you are considering investing.
                    You can easily see the most significant risks a company is facing. Additionally, you can find out which risk factors a company has added, removed or adjusted since its previous disclosure. You can also see how a company’s risk factors compare to others in its sector.
                      Without reading company reports or participating in conference calls, you would most likely not have access to this sort of information, which is usually not included in press releases or other public announcements.
                        A simplified analysis of risk factors is unique to TipRanks.
                          What are all the risk factor categories?
                          TipRanks has identified 6 major categories of risk factors and a number of subcategories for each. You can see how these categories are broken down in the list below.
                          1. Financial & Corporate
                          • Accounting & Financial Operations - risks related to accounting loss, value of intangible assets, financial statements, value of intangible assets, financial reporting, estimates, guidance, company profitability, dividends, fluctuating results.
                          • Share Price & Shareholder Rights – risks related to things that impact share prices and the rights of shareholders, including analyst ratings, major shareholder activity, trade volatility, liquidity of shares, anti-takeover provisions, international listing, dual listing.
                          • Debt & Financing – risks related to debt, funding, financing and interest rates, financial investments.
                          • Corporate Activity and Growth – risks related to restructuring, M&As, joint ventures, execution of corporate strategy, strategic alliances.
                          2. Legal & Regulatory
                          • Litigation and Legal Liabilities – risks related to litigation/ lawsuits against the company.
                          • Regulation – risks related to compliance, GDPR, and new legislation.
                          • Environmental / Social – risks related to environmental regulation and to data privacy.
                          • Taxation & Government Incentives – risks related to taxation and changes in government incentives.
                          3. Production
                          • Costs – risks related to costs of production including commodity prices, future contracts, inventory.
                          • Supply Chain – risks related to the company’s suppliers.
                          • Manufacturing – risks related to the company’s manufacturing process including product quality and product recalls.
                          • Human Capital – risks related to recruitment, training and retention of key employees, employee relationships & unions labor disputes, pension, and post retirement benefits, medical, health and welfare benefits, employee misconduct, employee litigation.
                          4. Technology & Innovation
                          • Innovation / R&D – risks related to innovation and new product development.
                          • Technology – risks related to the company’s reliance on technology.
                          • Cyber Security – risks related to securing the company’s digital assets and from cyber attacks.
                          • Trade Secrets & Patents – risks related to the company’s ability to protect its intellectual property and to infringement claims against the company as well as piracy and unlicensed copying.
                          5. Ability to Sell
                          • Demand – risks related to the demand of the company’s goods and services including seasonality, reliance on key customers.
                          • Competition – risks related to the company’s competition including substitutes.
                          • Sales & Marketing – risks related to sales, marketing, and distribution channels, pricing, and market penetration.
                          • Brand & Reputation – risks related to the company’s brand and reputation.
                          6. Macro & Political
                          • Economy & Political Environment – risks related to changes in economic and political conditions.
                          • Natural and Human Disruptions – risks related to catastrophes, floods, storms, terror, earthquakes, coronavirus pandemic/COVID-19.
                          • International Operations – risks related to the global nature of the company.
                          • Capital Markets – risks related to exchange rates and trade, cryptocurrency.
                          What am I Missing?
                          Make informed decisions based on Top Analysts' activity
                          Know what industry insiders are buying
                          Get actionable alerts from top Wall Street Analysts
                          Find out before anyone else which stock is going to shoot up
                          Get powerful stock screeners & detailed portfolio analysis