Public companies are required to disclose risks that can affect the business and impact the stock. These disclosures are known as “Risk Factors”. Companies disclose these risks in their yearly (Form 10-K), quarterly earnings (Form 10-Q), or “foreign private issuer” reports (Form 20-F). Risk factors show the challenges a company faces. Investors can consider the worst-case scenarios before making an investment. TipRanks’ Risk Analysis categorizes risks based on proprietary classification algorithms and machine learning.
Azure Power Global disclosed 69 risk factors in its most recent earnings report. Azure Power Global reported the most risks in the “Finance & Corporate” category.
Risk Overview Q1, 2021
Risk Distribution
42% Finance & Corporate
19% Legal & Regulatory
17% Production
13% Macro & Political
6% Tech & Innovation
3% Ability to Sell
Finance & Corporate - Financial and accounting risks. Risks related to the execution of corporate activity and strategy
This chart displays the stock's most recent risk distribution according to category. TipRanks has identified 6 major categories: Finance & corporate, legal & regulatory, macro & political, production, tech & innovation, and ability to sell.
Risk Change Over Time
S&P500 Average
Sector Average
Risks removed
Risks added
Risks changed
Azure Power Global Risk Factors
New Risk (0)
Risk Changed (0)
Risk Removed (0)
No changes from previous report
The chart shows the number of risks a company has disclosed. You can compare this to the sector average or S&P 500 average.
The quarters shown in the chart are according to the calendar year (January to December). Businesses set their own financial calendar, known as a fiscal year. For example, Walmart ends their financial year at the end of January to accommodate the holiday season.
Risk Highlights Q1, 2021
Main Risk Category
Finance & Corporate
With 29 Risks
Finance & Corporate
With 29 Risks
Number of Disclosed Risks
69
+1
From last report
S&P 500 Average: 31
69
+1
From last report
S&P 500 Average: 31
Recent Changes
3Risks added
2Risks removed
11Risks changed
Since Mar 2021
3Risks added
2Risks removed
11Risks changed
Since Mar 2021
Number of Risk Changed
11
-18
From last report
S&P 500 Average: 3
11
-18
From last report
S&P 500 Average: 3
See the risk highlights of Azure Power Global in the last period.
Risk Word Cloud
The most common phrases about risk factors from the most recent report. Larger texts indicate more widely used phrases.
Risk Factors Full Breakdown - Total Risks 69
Finance & Corporate
Total Risks: 29/69 (42%)Above Sector Average
Share Price & Shareholder Rights15 | 21.7%
Share Price & Shareholder Rights - Risk 1
Added
We may not be able to sign PPAs in respect of the 4,000 MWs manufacturing linked tender for which letter of award has already been received.
During fiscal year 2020, we won a bid for 2,000 MWs manufacturing linked project with SECI and also elected to exercise a greenshoe option for an additional 2,000 MWs as per auction guidelines. We have received a Letter of Award ("LOA") for the 4,000 MWs projects including for the greenshoe option for 2,000 MWs. We continue to work towards signing PPAs for these 4,000 MWs projects. SECI has informed us that so far there has not been adequate response from the DISCOMs for SECI to be able to sign the PSAs at this stage even though a LOA has been received. SECI has mentioned that they will be unable to sign PPAs until PSAs have been signed, and they have committed to inform us of developments in their efforts with the DISCOMS. Capital costs, interest rates and foreign exchange rates have improved since we won the 4 GWs auction in fiscal year 2020 which have resulted in lower tariffs in other recent SECI auctions. We expect these savings likely will be passed on to the DISCOMs. We expect a tariff markdown from the price achieved in the auction, which will facilitate signing of PSAs. We will continue our discussions with SECI towards signing PPAs in respect of the 4,000 MWs projects and expect the PPAs to be signed in tranches over a period. In case we are unable to sign PPAs in respect of these LOAs, it could have a material adverse effect on our cash flows projections.
Share Price & Shareholder Rights - Risk 2
Changed
Land title in India can be uncertain and we may not be able to identify or correct defects or irregularities in title of the landowner in respect of the land which we own, lease or intend to acquire in connection with the development or acquisition of our power projects. Additionally, certain land on which our power projects are located may be subject to onerous conditions which may adversely affect its use.
There is no central title registry for real property in India and the documentation of land records in India has not been fully computerized. Property records in India are generally maintained at the state and district level and in local languages and are updated manually through physical records. Therefore, property records may not be available online for inspection or updated in a timely manner, may be illegible, untraceable, incomplete or inaccurate in certain respects, or may have been kept in poor condition, which may impede title investigations or our ability to rely on such property records. In addition, there may be a discrepancy between the duration of the principal lease under different orders issued by state governments in respect of a particular parcel of revenue land. Furthermore, title to land in India is often fragmented, and in many cases, land may have multiple owners. Title may also suffer from irregularities, such as non-execution or non-registration of conveyance deeds and inadequate stamping and may be subjected to encumbrances of which we are unaware. Any defects in, or irregularities of, title may result in a loss of development or operating rights over the land, which may prejudice the success of our power projects and require us to write off substantial expenditures in respect of our power projects.
A portion of land leased from the government of Rajasthan for our projects in Nagaur, Rajasthan, is presently disputed by third parties claiming mining rights through the Mining Department of the State of Rajasthan. We had filed a petition with the High Court of Rajasthan to disallow the renewal of such mining lease and the High Court of Rajasthan had issued an injunction over the alleged claims on this land for mining. Further, the lease for our Andhra Pradesh 3 project is pending completion of formalities for development of the land. Currently, we are also facing multiple land related civil disputes in our Assam project, although procurement of land under the same has been made entirely as per the set procedures of law by registered title deeds in our favor and there is no restraining order from any court on completion of the project.
In addition, in March 2021, a civil suit was filed against us in relation to certain land parcels admeasuring around 8 acres of undivided land parcel of 47 acres (the entire land of 47 acres is referred to as "Suit land") out of around 3,300 acres of land for our SECI 600MW solar project in Rajasthan (the "Rajasthan 600MW Project"). We have partially commissioned the project and are in the final stages of commissioning the remaining MWs. An Indian district court had issued a temporary restraining order in the civil suit requiring that status quo be maintained on the entire Suit Land. In the appeal filed by us against the said order, the high court has permitted us to undertake work on the land and has set aside the finding of the district court prohibiting undertaking work on the entire Suit Land, however, has asked us to maintain status quo only on 7.80 acres of land. If this order is further contested and we are unsuccessful in any subsequent appeal, it may adversely affect our business and results of operations. Further, in June 2021, a report was filed with a local police department making allegations against certain members of our management for trespass on the Suit Land. The said members of the management had taken appropriate legal actions to contest this report before the High Court. The High Court has disposed of the matter by taking on record the statement of the public prosecutor that a case closure report has been filed.
In addition, improperly executed, unregistered or insufficiently stamped conveyance instruments in a property's chain of title, unregistered encumbrances in favor of third parties, rights of adverse possessors, ownership claims of family members of prior owners or third parties, or other defects that a purchaser may not be aware of can affect title to a property. As a result, potential disputes or claims over title to the land on which our power projects are or will be constructed may arise. However, an adverse decision from a court or the absence of an agreement with such third parties may result in additional costs and delays in the construction and operating phases of any solar projects situated on such land. Also, such disputes, whether resolved in our favor or not, may divert management's attention, incur extra-legal cost, harm our reputation or otherwise disrupt our business. For instance, we have filed civil suits in UP and Gujarat seeking directions from the court to the counterparty to execute Sale Deeds in our favor.
Further, some properties used for our solar projects are subject to other third-party rights such as right of passage and rights to place cables and other equipment on the properties, which may result in certain interferences with our use of the properties. Our rights to the properties used for our solar projects may be challenged by property owners and other third parties for various other reasons as well. Any such challenge, if successful, could impair the development or operations of our solar projects on such properties.
In the case of land acquired from private parties, which may be agricultural land, the transfer of such land from agricultural to non-agricultural and the use of such land for non-agricultural purposes may require an order from the concerned state or revenue authority allowing such transfer or use. For instance, for our Gujarat 2 projects, we are awaiting approval for use of land for industrial/non-agricultural purposes. Similarly, for revenue land, we obtain a lease from the relevant government authority with some restrictions with it.
Additionally, the power projects that we may develop or acquire in the future may be located on land that may be subject to onerous conditions under the lease agreements through which we acquire rights to use such land and rights of way. Furthermore, the government may exercise its rights of eminent domain, or compulsory acquisition in respect of land on which our projects are or will be located. Any of this may adversely affect our business, results of operations and cash flows in the future.
Share Price & Shareholder Rights - Risk 3
If a United States person is treated as owning at least 10% of our equity shares, the holder may be required to include amounts in its U.S. taxable income even if our Company does not make distributions to its shareholders.
If a United States person is treated as owning (directly, indirectly, or constructively) at least 10% of the value or voting power of our Company's equity shares, that person may be required to include certain amounts in its U.S. taxable income even if our Company make no distributions to our Company's shareholders. A United States person that is treated as owning (directly, indirectly, or constructively) at least 10% of the value or voting power of our Company's equity shares will be treated as a "United States shareholder" with respect to each "controlled foreign corporation" in our Group. As a result of tax legislation enacted in 2017, it is not certain under what circumstances our non-U.S. subsidiaries will be treated as controlled foreign corporations. However, because our Group includes U.S. subsidiaries, our non-U.S. subsidiaries could be treated as controlled foreign corporations with respect to any United States shareholders (regardless of whether or not our Company are treated as a controlled foreign corporation). A United States shareholder of a controlled foreign corporation in our Group would be required to report annually and include in its U.S. taxable income its pro rata share of "Subpart F income", "global intangible low-taxed income," and investments in United States property, if any, related to that controlled foreign corporation, regardless of whether our Company make any distributions. Failure to comply with these reporting obligations may subject a United States shareholder to significant monetary penalties and may prevent the statute of limitations with respect to such shareholder's U.S. federal income tax return for the year for which reporting was due from starting. An individual that is a United States shareholder with respect to a controlled foreign corporation generally would not be allowed certain tax deductions or foreign tax credits that would be allowed to a United States shareholder that is a U.S. corporation. Because our Company does not maintain U.S. tax books and records, our Company does not expect to be able to furnish to any United States shareholders the information that may be necessary to comply with the shareholder's reporting and taxpaying obligations under these rules. A U.S. investor should consult its advisors regarding the potential application of these rules to an investment in our Company's equity shares, including the possibility that the investor may be treated as a "United States shareholder" as a result of direct, indirect or constructive ownership of our Company's equity shares.
Share Price & Shareholder Rights - Risk 4
Future issuances of any equity securities may cause a dilution in your shareholding, decrease the trading price of our equity shares, and restrictions agreed to as part of debt financing arrangements may place restrictions on our operations.
Any issuance of equity securities after our initial offering could dilute the interests of our shareholders and could substantially decrease the trading price of our equity shares. our Company may issue equity or equity-linked securities in the future for a number of reasons, including to finance our operations and business strategy (including in connection with acquisitions and other transactions), to adjust our ratio of debt to equity, to satisfy our obligations upon the exercise of then-outstanding options or other equity-linked securities, if any, or for other reasons. Issuance of such additional securities may significantly dilute the equity interests of investors, since initial offering who will not have pre-emptive rights with respect to such an issuance, subordinate the rights of holders of equity shares if preferred shares are issued with rights senior to those afforded to our Company's equity shares, or harm prevailing market prices for our Company's equity shares.
Share Price & Shareholder Rights - Risk 5
If securities or industry analysts do not publish or cease publishing research or reports about us, our business or our market, or if they change their recommendations regarding our equity shares adversely, our stock price and trading volume could decline.
The trading market for our equity shares is influenced by the research and reports that industry or securities analysts publish about us, our business, our market or our competitors. If any of the analysts who cover us or may cover us in the future change their recommendation regarding our stock adversely, or provide more favorable relative recommendations about our competitors, our stock price would likely decline. If any analyst who covers us or may cover us in the future were to cease coverage of our company or fail to regularly publish reports on us, we could lose visibility in the financial markets, which in turn could cause our stock price or trading volume to decline.
Share Price & Shareholder Rights - Risk 6
For as long as our Company is an "emerging growth company," our Company will not be required to comply with certain reporting requirements that apply to other public companies.
Our Company is an "emerging growth company," as defined in the JOBS Act, enacted on April 5, 2012. For as long as our Company continues to be an emerging growth company, our Company may choose to take advantage of certain exemptions from reporting requirements applicable to other public companies that are not emerging growth companies. These include: (1) not being required to comply with the auditor attestation requirements of Section 404 of the Sarbanes-Oxley Act, (2) not being required to comply with any new requirements adopted by the Public Company Accounting Oversight Board, or the PCAOB, requiring mandatory audit firm rotation or a supplement to the auditor's report in which the auditor would be required to provide additional information about the audit and the financial statements of the issuer, (3) not being required to comply with any new audit rules adopted by the PCAOB after April 5, 2012 unless the SEC determines otherwise, and (4) not being required to provide certain disclosure regarding executive compensation required of larger public companies. Our Company could be an emerging growth company for up to five years from the end of fiscal year 2017, although, if the market value of our common equity shares that is held by non-affiliates (referred as "Public Float") exceeds US$ 700.0 million as of any September 30 before the end of that five-year period, our Company would cease to be an emerging growth company as of the following April 1, 2021. During the previous year, our Company has early adopted certain new accounting pronouncements that were applicable for public companies and irrevocably elected to follow the public company accounting requirements. This will result in adoption of Financial Accounting Standards Board ("FASB")'s Accounting Standard Updates ("ASU"), as it would be applicable for other public companies. We cannot predict if investors will find our equity shares less attractive if we choose to rely on these exemptions. If some investors find our equity shares less attractive as a result of any choices to reduce future disclosure, there may be a less active trading market for our equity shares and our share price may be more volatile. Further, as a result of these scaled regulatory requirements, our disclosure may be more limited than that of other public companies and you may not have the same protections afforded to shareholders of such companies. The Company completes its fifth anniversary from the first sale of common equity shares during the fiscal year ended March 31, 2022 and the exemptions available for the Emerging Growth Company will no longer be available effective March 31, 2022. From that date, the Company will be required to comply with all reporting requirements as applicable to other public companies including the requirement to comply with the auditor attestation requirements of Section 404 of the Sarbanes-Oxley Act.
Share Price & Shareholder Rights - Risk 7
If our Company ceases to qualify as a foreign private issuer, our Company would be required to comply fully with the reporting requirements of the Exchange Act applicable to U.S. domestic issuers, and our Company could incur additional legal, accounting and other expenses that our Company would not incur as a foreign private issuer.
As a foreign private issuer, our Company is exempt from a number of rules and regulations under the Securities Exchange Act of 1934, or the Exchange Act, applicable to U.S. domestic issuers, including the furnishing and content of proxy statements, compliance with the reporting and short-swing profit recovery provisions contained in Section 16 of the Exchange Act applicable to executive officers, directors and principal shareholders. Our Company is not required under the Exchange Act to file periodic reports and financial statements with the SEC as frequently or as promptly as U.S. domestic issuers, and we are not required to disclose in our periodic reports all of the information that U.S. domestic issuers are required to disclose. If our Company does not qualify as a foreign private issuer, our Company will be required to comply fully with the reporting requirements of the Exchange Act applicable to U.S.
domestic issuers, and our Company will incur significant additional legal, accounting and other expenses that our Company would not incur as a foreign private issuer.
Share Price & Shareholder Rights - Risk 8
As a foreign private issuer, our Company is permitted to, and it will, follow certain home country corporate governance practices in lieu of certain requirements applicable to U.S. issuers. This may afford less protection to holders of our Company's equity shares.
As a foreign private issuer listed on the New York Stock Exchange, or NYSE, our Company permitted to follow certain home country corporate governance practices in lieu of certain NYSE requirements. A foreign private issuer must disclose in its annual reports filed with the SEC, each NYSE requirement with which it does not comply followed by a description of its applicable home country practice. As a company incorporated in Mauritius and which is listed on the NYSE, our Company may follow its home country practice with respect to the composition of its Board of Directors and executive sessions and composition of our compensation committee and our nominating and corporate governance committee. Unlike the requirements of the NYSE, the corporate governance practice and requirements in Mauritius do not require our Company to have the majority of its Board of Directors be independent or to hold regular executive sessions where only independent directors shall be present. In addition, Mauritius law does not require our compensation committee or our nominating and corporate governance committee to be comprised of only independent directors. Such Mauritian home country practices may afford less protection to holders of our Company's equity shares than would be available to the shareholders of a U.S. corporation.
Share Price & Shareholder Rights - Risk 9
You may have difficulty enforcing judgments against our Company, our Company's directors and management.
Our Company is incorporated under the laws of Mauritius. Further, we conduct substantially all of our operations in India through our key operating subsidiaries in India. The majority of our Company's directors and officers reside outside the United States, and a majority of our assets and some or all of the assets of such persons are located outside the United States. As a result, it may be difficult or impossible to effect service of process within the United States upon our Company or those persons, or to recover against our Company or them on judgments of United States courts, including judgments predicated upon the civil liability provisions of the United States federal securities laws. An award of punitive damages under a United States court judgment based upon United States federal securities laws is likely to be construed by Mauritian and Indian courts to be penal in nature and therefore unenforceable in both Mauritius and India. Further, no claim may be brought in Mauritius or India against our Company or our Company's directors and officers in the first instance for violation of United States federal securities laws because these laws have no extraterritorial application under Mauritian or Indian law and do not have force of law in Mauritius or India. However, a Mauritian or Indian court may impose civil liability, including the possibility of monetary damages, on our Company or our Company's directors and officers if the facts alleged in a complaint constitute or give rise to a cause of action under Mauritian or Indian law. Moreover, it is unlikely that a court in Mauritius or India would award damages on the same basis as a foreign court if an action were brought in Mauritius or India or that a Mauritian or Indian court would enforce foreign judgments if it viewed the amount of damages as excessive or inconsistent with Mauritius or Indian practice or public policy.
The courts of Mauritius or India would not automatically enforce judgments of United States courts obtained in actions against our Company or our Company's directors and officers, predicated upon the civil liability provisions of the United States federal securities laws, or entertain actions brought in Mauritius or India against our Company or such persons predicated solely upon United States federal securities laws. Further, there is no treaty in effect between the United States and Mauritius providing for the enforcement of judgments of United States courts in civil and commercial matters and the United States has not been declared by the Indian government to be a reciprocating territory for the purposes of enforcement of foreign judgments, and there are grounds upon which Mauritian or Indian courts may decline to enforce the judgments of United States courts. Some remedies available under the laws of United States jurisdictions, including remedies available under the United States federal securities laws, may not be allowed in Mauritian or Indian courts if contrary to public policy in Mauritius or India. Because judgments of United States courts are not automatically enforceable in Mauritius or India, it may be difficult for you to recover against us or our Company's directors and officers based upon such judgments. In India, prior approval of the Reserve Bank of India is required in order to repatriate any amount recovered pursuant to such judgments.
Share Price & Shareholder Rights - Risk 10
Sales of a substantial number of our Company's equity shares in the public market, including by our Company's existing shareholders, could cause our Company's share price to fall.
Sales of a substantial number of our equity shares in the public market, or the perception that the sales might occur, could depress the market price of our Company's equity shares and could impair our ability to raise capital through the issuance of additional equity securities of our Company. We are unable to predict the effect that these sales and others may have on the prevailing market price of our Company's equity shares.
In addition, certain of our Company's shareholders can require us to register shares owned by them for public sale in the United States. Our Company also has filed a registration statement to register our Company's equity shares reserved for future issuance under our Company's equity compensation plans. Subject to the satisfaction of applicable exercise periods and applicable volume and restrictions that apply to affiliates, our Company's equity shares issued upon exercise of outstanding options will become available for immediate resale in the public market upon issuance.
Future sales of our Company's equity shares may make it more difficult for us to sell equity securities in the future at a time and at a price that we deem appropriate. These sales also could cause the market price of our Company's equity shares to decline and make it more difficult for you to sell our Company's equity shares.
Share Price & Shareholder Rights - Risk 11
The market price of our Company's equity shares has been and may continue to be volatile, and you could lose all or part of your investment.
The trading price of our Company's equity shares has been volatile since our Company's initial public offering and is likely to continue to be volatile. Factors that could cause fluctuations in the market price of our Company's equity shares include - trading volume, prices of other securities, market trends, growth of other comparable companies, changes in operating performance, sale of additional shares in the market by us or by other investors, coverage by security analysts, changes in financial estimates, failure to meet analyst or market expectations, press releases by us or our competitors, market speculations, changes in tax and other incentives, regulatory and policy changes, litigations, business acquisitions, changes in accounting standards and economic conditions.
Further, in recent years the stock markets have experienced extreme price and volume fluctuations that have affected and continue to affect the market prices of equity securities of many companies. These fluctuations often have been unrelated or disproportionate to the operating performance of those companies. In addition, the stock prices of many renewable energy companies have experienced wide fluctuations that have often been unrelated to the operating performance of those companies. These broad market and industry fluctuations, as well as general economic, political and market conditions such as recessions, government shutdowns, interest rate changes, or international currency fluctuations, may cause the market price of our Company's equity shares to decline. Furthermore, the COVID-19 crisis has resulted in frequent share market price fluctuations and price volatility in all parts of the world and may also impact the share price of our Company. Any such crisis in future can also significantly impair the share price of our Company.
Share Price & Shareholder Rights - Risk 12
An active or liquid trading market for our Company's equity shares may not be maintained.
Our Company's shares historically had low trading volumes and an active liquid trading market for our Company's equity shares may not be maintained in the long term and we cannot be certain that any trading market for our Company's equity shares will be sustained or that the present price will correspond to the future price at which our Company's equity shares will trade. Loss of liquidity could increase the price volatility of our Company's equity shares.
Any additional issuance of equity shares or other equity-related securities would dilute the positions of existing investors in the equity shares and could adversely affect the market price of our Company's equity shares. We cannot assure you that our Company's equity shares will not decline below their prevailing market price. You may be unable to sell your equity shares at a price that is attractive to you.
Share Price & Shareholder Rights - Risk 13
Anti-takeover provisions in our Company's constitutional documents and under Mauritius law could make an acquisition of us, which may be beneficial to our Company's shareholders, more difficult and may prevent attempts by our Company's shareholders to replace or remove our Company's current management and limit the market price of our Company's equity shares.
Provisions in our Company's Constitution may have the effect of delaying or preventing a change in control or changes in our management. Our Company's Constitution includes the following provisions which may be regarded as defensive measures:
- a staggered Board of Directors; - the ability to issue additional equity shares (including "blank check" preferred stock); - granting directors, the absolute discretion to decline to register a transfer of any shares; - requiring that amendments to our Company's Constitution be approved by a special resolution of the shareholders of our Company; and - limiting the liability of, and providing indemnification to, our Company's directors and officers.
These provisions may restrict or prevent any attempts by our Company's shareholders to replace or remove our Company's current management by making it more difficult for shareholders to replace members of our Company's Board of Directors, which is responsible for appointing the members of our Company's management team. The provisions could also deprive our shareholders of the opportunity to sell their shares at a premium over the prevailing market price by discouraging third parties from seeking to obtain control of our Company in a tender offer or similar transactions.
Share Price & Shareholder Rights - Risk 14
As a shareholder in our Company, you may have greater difficulties in protecting your interests than as a shareholder of a United States corporation.
Our Company is incorporated under the laws of Mauritius. The laws generally applicable to United States corporations and their shareholders may provide shareholders of United States corporations with rights and protection for which there may be no corresponding or similar provisions under the Companies Act 2001 of Mauritius, as amended, or the Mauritius Companies Act. As such, being shareholder of our Company's equity shares, you may or may not be accorded the same level of shareholder rights and protection that a shareholder of a United States corporation may be accorded under the laws generally applicable to United States corporations and their shareholders. Taken together with the provisions of our Company's constitution, which our Company adopted with effect upon completion of its public offering in October 2016, or Constitution, some of these differences may result in you having greater difficulties in protecting your interests as our Company's shareholder than you would have as a shareholder of a United States corporation. This affects, among other things, the circumstances under which transactions involving an interested director are voidable, whether an interested director can be held accountable for any benefit realized in a transaction with us, what rights you may have as a shareholder to enforce specified provisions of the Mauritius Companies Act or our Company's Constitution, and the circumstances under which we may indemnify our Company's directors and officers.
Share Price & Shareholder Rights - Risk 15
Investors may not be able to enforce a judgment of a foreign court against our Indian subsidiaries, certain of our Company's directors, or our key management, except by way of a suit in India on such judgment.
All of our operating subsidiaries are incorporated under the laws of India. In addition, certain of our Company's directors and substantially all of our key management personnel reside in India, and all or a substantial portion of our assets and such persons are located in India. As a result, it may not be possible for investors to effect service of process upon such persons outside India, or to enforce judgments obtained against such parties outside India. In India, recognition and enforcement of foreign judgments are provided for under Section 13 and Section 44A of the Civil Procedure Code, 1908 (the "Civil Code") on a statutory basis. Section 13 of the Civil Code provides that a foreign judgment shall be conclusive regarding any matter directly adjudicated upon, except: (i) where the judgment has not been pronounced by a court of competent jurisdiction; (ii) where the judgment has not been given on the merits of the case; (iii) where it appears on the face of the proceedings that the judgment is founded on an incorrect view of international law or a refusal to recognize the law of India in cases to which such law is applicable; (iv) where the proceedings in which the judgment was obtained were opposed to natural justice; (v) where the judgment has been obtained by fraud; and (vi) where the judgment sustains a claim founded on a breach of any law then in force in India.
Under the Civil Code, a court in India shall, upon the production of any document purporting to be a certified copy of a foreign judgment, presume that the judgment was pronounced by a court of competent jurisdiction unless the contrary appears on record.
India is not a party to any international treaty in relation to the recognition or enforcement of foreign judgments. Section 44A of the Civil Code provides that where a foreign judgment has been rendered by a superior court, within the meaning of such section, in any country or territory outside India, which the Indian government has by notification declared to be a reciprocating territory, it may be enforced in India by proceedings in execution as if the judgment had been rendered by the relevant court in India. However, Section 44A of the Civil Code is applicable only to monetary decrees not being in the nature of any amounts payable in respect of taxes, other charges of a like nature or in respect of a fine or other penalty and does not apply to arbitration awards. Further, the execution of the foreign decree under Section 44A of the Civil Code is also subject to the exceptions under Section 13 of the Civil Code.
The United Kingdom, Singapore and Hong Kong (among others) have been declared by the Indian government to be reciprocating territories for the purposes of Section 44A. However, the United States has not been declared by the Indian government to be a reciprocating territory for the purposes of Section 44A of the Civil Code. Accordingly, a judgment of a court in a country which is not a reciprocating territory may be enforced in India only by a fresh proceeding suit instituted in a court of India and not by proceedings in execution. Such a suit has to be filed in India within three years from the date of the judgment in the same manner as any other suit filed in India to enforce a civil liability in India. It is unlikely that a court in India would award damages on the same basis as a foreign court would, if an action were brought in India. Further, it is unlikely that an Indian court would enforce foreign judgments if that court were of the view that the amount of damages awarded was excessive or inconsistent with Indian public policy. A party seeking to enforce a foreign judgment in India is required to obtain approval from the RBI to repatriate outside India any amount recovered pursuant to the execution of such judgment and such amount may be subject to income tax in accordance with applicable laws. In addition, any judgment awarding damages in a foreign currency would be converted into Indian Rupees on the date of the judgment and not the date of payment. We cannot predict whether a suit instituted in an Indian court will be disposed of in a timely manner or be subject to considerable delay.
Accounting & Financial Operations6 | 8.7%
Accounting & Financial Operations - Risk 1
The accounting treatment for many aspects of our solar projects is complex and any changes to the accounting interpretations or accounting rules governing our solar projects could have a material adverse effect on our U.S. GAAP reported results of operations and financial condition.
The accounting treatment for many aspects of our solar projects is complex, and our future results could be adversely affected by changes in the accounting treatment applicable to our solar projects. In particular, any changes to the accounting rules regarding the following matters may require us to change the manner in which we operate, finance and account for our solar projects:
- foreign loans accounting; - derivative contracts; - asset retirement obligations; - share based compensation including ESOPs, SARs and RSs; - revenue recognition and related timing; - accounting for convertible debt and equity instruments; - income taxes; - foreign holding company tax treatment; - useful lives of project assets; - government grants; - leases; - estimated credit losses; and - investment in joint ventures/subsidiaries.
Accounting & Financial Operations - Risk 2
Our Company will have to rely principally on dividends and other distributions on equity paid by its operating subsidiaries and limitations on their ability to pay dividends to our Company could adversely impact your ability to receive dividends on our Company's equity shares.
Since our Company cannot borrow from our Indian subsidiaries, dividends and other distributions on equity paid by our operating subsidiaries will be our Company's principal source for cash in order for it to fund its operations including corporate expenses. Accordingly, our Company may need to issue additional equity or borrow funds, either of which may be unavailable on attractive terms, if at all.
If our Company's operating subsidiaries incur debt on their own behalf in the future, the instruments governing the debt may restrict their ability to pay dividends or make other distributions to our Company. As our key operating subsidiary is established in India, it is also subject to certain limitations with respect to dividend payments. As of the date of this annual report, AZI has not paid any cash dividends on its equity shares and does not intend to pay dividends to its equity shareholders, including our Company, in the foreseeable future. Moreover, as our Company does not own 100% of AZI, any dividend payment made by AZI to our Company will also involve a payment to the other shareholders of AZI.
Accounting & Financial Operations - Risk 3
Our Company does not expect to pay any cash dividends on our Company's equity shares.
Our Company has not paid dividends on any of our Company's equity shares to date and our Company currently intends to retain our future earnings, if any, to fund the development and growth of our Company's business. As a result, capital appreciation, if any, of our Company's equity shares are likely to be your sole source of gain for the foreseeable future. Consequently, you will likely only experience a gain from your investment in our Company's equity shares if the price of our Company's equity shares increases.
In addition, our Company's ability and decisions whether to pay dividends in the future will depend on our earnings, financial condition and capital requirements. Dividends to U.S. holders may be negatively affected by foreign currency fluctuations. We may not generate sufficient income to cover our operating expenses and pay dividends to our Company's shareholders, or at all. Our Company's ability to pay dividends also could be restricted under financing arrangements that our Company may enter into in the future and our Company may be required to obtain the approval of lenders in the event it is in default of its repayment obligations. Our Company may be unable to pay dividends in the near or medium term, and our Company's future dividend policy will depend on our capital requirements, financing arrangements, results of operations and financial condition. As per Amendment in Finance Act, 2020 during previous year, Indian Companies are required to deduct tax at source in respect of dividend paid at rates applicable from time to time. Considering the same from Fiscal year 2020-21 onwards, dividend payments to its shareholders by companies are taxable in the hands of shareholders.
Accounting & Financial Operations - Risk 4
Changed
We are not profitable in the current fiscal year, previous fiscal year or past several fiscal years and we may not be able to continue to be profitable in the foreseeable future.
We have incurred losses since our inception. Although we had a net profit for the fiscal year ended March 31, 2019, we were not profitable in the current fiscal year ended March 31, 2021, previous fiscal year ended March 31, 2020 or for the fiscal years prior to the fiscal year ended March 31, 2019. During the fiscal year ended March 31, 2020 and March 31, 2021, we had a net loss of INR 2,337 million and INR 4,201 million (US$ 57.2 million), respectively and we may not be profitable in future periods. In addition, our costs may increase in the future, reducing our margins for our significant future investment in renewable projects.
A significant number of power projects are presently Contracted and under construction, and we may be only able to monetize them, if at all, after each project is completed, which is subject to several factors, including receiving regulatory approvals, obtaining project funding, entering into transmission arrangements with the central or state transmission utilities, and acquiring land for projects. In addition, even after a project is operational, the monetization process may be quite long term with contracts running up to 25 years. Moreover, we may not succeed in addressing certain risks, including our ability to successfully develop or supervise the commissioning, operations and maintenance of our projects or maintain adequate control of our costs and expenses. Also, we may find that our growth plans are costlier than we anticipate and that they do not ultimately result in commensurate increases in revenue. Our results of operations will depend upon numerous factors, some of which are beyond our control, including the availability of other subsidies, global liquidity and competition. In addition, the global crisis due to the COVID-19 pandemic, could hamper growth, increase our costs, and may result in losses. As a result, we may not be profitable in the foreseeable future. For a full discussion of the risks to our business associated with the COVID-19 pandemic, see "Risks to our Business related to the COVID-19 pandemic".
For instance, to optimize cost and to enhance returns on invested capital, in Fiscal 2021, we identified certain subsidiaries to sell off on a going concern basis which currently form part of our Rooftop business. Out of this identified portfolio, subsequent to March 2021, we entered a sales contract with Radiance to the Rooftop Subsidiaries having an operating capacity of 153 MW for INR 5,350 million (US$ 73.1 million), subject to certain purchase price adjustments. We reported a loss of INR 2,598 million (US$ 35.5 million) on assets classified as held for sale, which is reported separately in our Consolidated Statement of Operations and related assets (net) are reported at their fair value. Further, we also recognized an impairment loss of INR 657 million (US$ 9.0 million) in relation to the Property, Plant and Equipment of the Rooftop Subsidiaries not shown as "Assets classified as held for sale", which are expected to be settled beyond 12 months after March 31, 2021. For detailed information relating to loss on rooftop business sale, see "Our Company may not be able to successfully complete its Rooftop asset sale entered into in March 2021 and may not complete other asset sales or at the price that we desire".
Accounting & Financial Operations - Risk 5
Our limited operating history, especially with large-scale solar projects or managing such a large portfolio, may not serve as an adequate basis to judge our future prospects, results of operations and cash flows.
We began our business in 2008 and have a limited operating history. We established our first utility scale solar plant in India in 2009. As of March 31, 2021, we operated 45 utility scale projects with a combined rated capacity of 1,990 MWs. As of March 31, 2021, we were also constructing a combined rated capacity of 965 MWs comprising utility scale projects of 65 MWs of Assam 1, 300 MWs of Rajasthan 6, 300 MWs of Rajasthan 8 and 300 MWs of Rajasthan 9. We also had an additional 4,000 MWs Contracted & Awarded, bringing our total Operating, Contracted & Awarded capacity to 6,955 MWs. Contracted & Awarded megawatts include 4,000 MWs for which we have received Letters of Award ("LOA"), but the Power Purchase Agreements ("PPAs") have yet to be signed. Accordingly, our relatively limited operating history, especially with large-scale projects, or managing such a large portfolio may not be an adequate basis for evaluating our business prospects and financial performance and makes it difficult to predict the future results of our operations. Period-to-period comparisons of our operating results, and our results of operations for any period should not be relied upon as an indication of our performance for any future period. In particular, our results of operations, financial condition, cash flows and future success depend, to a significant extent, on our ability to continue to identify suitable sites, acquire land for solar projects, obtain required regulatory approvals, arrange financing from various sources, construct solar projects in a cost-effective and timely manner, expand our project pipeline and manage and operate solar projects that we develop. If we cannot do so, we may not be able to expand our business at a profit or at all, maintain our competitive position, satisfy our contractual obligations, or sustain growth and profitability.
Accounting & Financial Operations - Risk 6
Our operating results may fluctuate from quarter to quarter, which could make our future performance difficult to predict and could cause our operating results for a particular period to fall below expectations, which may result in a severe decline in the price of our equity shares.
Our quarterly operating results are difficult to predict and may fluctuate significantly in the future. We have experienced seasonal and quarterly fluctuations in the past, especially in the winter months and we may experience similar fluctuations in the future. However, given that we are a rapidly growing industry, those fluctuations may be masked by our recent growth rates and thus may not be readily apparent from our historical operating results. As such, our past quarterly operating results may not be good indicators of future performance.
In addition to the other risks described in this "Risk Factors" section, the following factors could cause our operating results to fluctuate:
- the expiration or initiation of any central or state subsidies or incentives; - our ability to complete installations in a timely manner due to market conditions or due to unavailable financing; - our ability to continue to expand our operations, and the amount and timing of expenditures related to such expansions; - announcements by us or our competitors of significant acquisitions, strategic partnerships, joint ventures or capital-raising activities or commitments; - changes in auction rules; - changes in feed-in tariff rates for solar power, VGF, our pricing policies or terms or those of our competitors; - actual or anticipated developments in our competitors' businesses or the competitive landscape; - an occurrence of low global horizontal irradiation that affects our generation of solar power; - fluctuations due to the COVID-19 pandemic, related lockdowns and resulting operational disruptions;- - change in law or adoption of new accounting pronouncements; and significant volatility in market conditions (including, but not limited to foreign currency rates, interest rates and our share price) can directly impact our expenses such as foreign exchange gains and losses, derivative gains and losses, interest costs and Stock Appreciation Rights (SARs) expense.
For these or other reasons, the results of any prior quarterly or annual periods should not be relied upon as indications of our future performance. In addition, with respect to the above factors our actual revenue, key operating and financial metrics and other operating results in future quarters may fall short of the expectations of investors and financial analysts, which could have a material adverse effect on the trading price of our equity shares.
Debt & Financing7 | 10.1%
Debt & Financing - Risk 1
Counterparties to our PPAs may not fulfill their obligations which could result in a material adverse impact on our business, financial condition, results of operations and cash flows.
We generate electricity income primarily pursuant to PPAs entered into with central and state government-run utilities. Some of the customers may become subject to insolvency or liquidation proceedings during the term of the relevant contracts, and the credit support received from such customers may not be sufficient to cover our losses in the event of a failure to perform. There may also be delays associated with collection of receivables from government owned or controlled entities on account of the financial condition of these entities that deteriorated significantly in the past. Where we are selling power to non-governmental entities, we take into account the credit ratings assigned by rating agencies and our ability to collect when assessing the counterparties' creditworthiness. The Governmental entities to which we sell power generally may not have credit ratings for us to consider. For illustrative purposes, Moody's Investor Services Inc. and Standard and Poor's Financial Services LLC have rated the Indian government Baa3 during June'2020 and BBB-, respectively. As a result, many of the state governments in India, if rated, would likely rate lower than the Indian government. Although the central and state governments in India have taken steps to improve the liquidity, financial condition and viability of state electricity distribution utility companies, there can be no assurance that the utility companies that are currently our customers will have the resources to pay on time or at all.
In addition, our PPA customers may, for any reason, become unable or unwilling to fulfil their related contractual obligations, refuse to accept delivery of power delivered thereunder or otherwise terminate such agreements prior to the expiration thereof. If such events occur, our assets, liabilities, business, financial condition, results of operations and cash flows could be materially and adversely affected. For instance, Gujarat Urja Vikas Nigam Limited had filed a petition with the Gujarat Electricity Regulatory Commission, seeking recalculation of the tariff under its PPA based on actual cash flow required for development of solar projects and consequent revision of the tariff payable by it, in relation to certain solar power projects including our 10 MWs Gujarat 1 project. While the Gujarat Electricity Regulatory Commission and the Appellate Tribunal for Electricity dismissed the claims made by Gujarat Urja Vikas Nigam Limited, an appeal filed by Gujarat Urja Vikas Nigam Limited is pending before the Supreme Court of India. Further, On July 7, 2019, the Government of Andhra Pradesh vide an order bearing no. GO RT No 63 ("Order"), constituted a High-Level Negotiation Committee to revisit and review PPAs for solar & wind projects in the state of Andhra Pradesh with a view to bring down the tariffs. Pursuant to the same, a letter dated July 12, 2019, was issued by Andhra Pradesh Distribution Company to the developers to reduce the quoted tariff to INR 2.43 per unit for wind projects for the pending bills, and INR 2.44 per unit for solar projects from the date of commissioning and threatened termination of the PPA in case of refusal of the developers to accede to such reduction ("Letter"). The developers challenged both the Order and the Letter in the High Court at Vijayawada. The High Court vide order dated September 24, 2019, set aside both the Order and the Letter. However, as an interim measure, until the issue of possibility of reduction of existing tariff is decided by the Andhra Pradesh Electricity Regulatory Commission ("APERC"), directed to honor the outstanding and future bills of the developers, and pay at an interim rate of INR 2.43 and INR 2.44 per unit for wind and solar projects, respectively. This order of the single judge had been challenged in an appeal filed by the developers including Azure Power. The matter is listed for further hearing in the court and matter had been adjourned until disposal of the writ appeals before Vijayawada.
For instance, in connection with an extension of the date of commissioning of the 40 MWs project in Karnataka of one of our subsidiaries, our distribution company customer reduced its payable tariff under the PPA. After certain litigation, the subsidiary executed a supplementary PPA with the customer allowing extension of time without reducing the PPA tariff, however when the supplementary PPA went for the approval of the Karnataka Electricity Regulatory Commission ("KERC") the KERC, pursuant to an order directed our customer to retrospectively withdraw the extensions, and to enforce a reduced tariff and recover liquidated damages due to delay based on "actual commercial operation date". Against the order of the KERC, we filed an appeal before the Appellate Tribunal for Electricity ("APTEL"). The matter is pending adjudication before APTEL. Although, in a similar matter, pertaining to the same issue, we have received a favorable order from APTEL vide order dated February 28, 2020, where APTEL set aside the order of KERC, wherein the KERC had reduced the extension of time and reduced the tariff and imposed liquidated damages. We cannot provide any assurances, however, that our appeal at APTEL will ultimately be decided in our favor. Further, the commissioning of a 10 MWs project in Punjab by another of our subsidiaries faced delays due to a delay by the customer, and our subsidiary had sought an extension of the commercial operation date at the same tariff rate as per the PPA. This matter is also currently pending before the APTEL. We cannot provide assurances, however, that such proceedings will ultimately be decided in our favor. In respect of our 222 MWs capacity projects in Punjab, our offtaker Punjab State Power Corporation Limited (PSPCL) had refused to accept power generated from these projects for the first week of April 2020 on account of COVID-19. Further, PSPCL had also deducted 5% of billed amount relating to the months of April-June 2020. We had filed petition before Punjab State Electricity Regulatory Commission (PSERC) through the Solar Power Developer Association against the same. The matter is currently pending with the appellant authority. However, we cannot provide assurances that such proceedings will ultimately be decided in our favor.
Furthermore, to the extent any of our customers are, or are controlled by, governmental entities, bringing actions against them to enforce their contractual obligations is often difficult. Also, our counterparties may be subject to legislative or other political action that may impair their contractual performance.
Debt & Financing - Risk 2
Our obligations under our PPAs and the tariffs set under our PPAs may expose us to certain risks that may affect our future results of operations and cash flows.
Our profitability is largely a function of our ability to manage our costs during the terms of our PPAs and operate our power projects at optimal levels. If we are unable to manage our costs effectively or operate our power projects at optimal levels, our business and results of operations may be adversely affected. In the event we default in fulfilling our obligations under the PPAs, such as supplying the minimum amount of power specified in some of the PPAs or failing to obtain regulatory approvals, licenses and clearances with respect to our solar projects, we may be liable for penalties and in certain specified events, customers may also terminate such PPAs. Further, any failure to supply power from the scheduled commercial operation date may result in levy of liquidated damages and encashment of bank guarantees provided by us under the terms of certain PPAs. The termination of any of our projects by our customers would adversely affect our reputation, business, results of operations and cash flows.
Further, the tender which involves manufacturing of solar modules, wherein we had entered into a joint venture agreement with a local solar panel manufacturer, to set up a new facility in accordance with the terms of the contract, any deviation from the contract terms, or non-performance by the joint venture partner could cause adverse impact to us financially as well as reputationally.
Under a long-term PPA, we typically sell power generated from a power plant to state distribution companies at pre-determined tariffs. Our PPAs are generally not subject to downward revisions unless we elect to utilize accelerated rate of depreciation or if there is a delay in commissioning our projects, although we have entered into contracts that provide for downward adjustments in the past and may do so in the future. Accordingly, if there is an industry-wide increase in tariffs or if we are seeking an extension of the term of the PPA, we will not be able to renegotiate the terms of the PPA to take advantage of the increased tariffs. In addition, in the event of increased operational costs, we will not have the ability to reflect a corresponding increase in our tariffs. Further, any delay in commissioning projects or supplying electricity during the term of the PPA may result in reduction in tariffs, based on the terms of the PPA.
Therefore, the prices at which we supply power may have little or no relationship with the costs incurred in generating power, which may lead to fluctuations in our margins. All the above factors limit our business flexibility, expose us to an increased risk of unforeseen business and industry changes and could have an adverse effect on our business, results of operations and cash flows.
The term of most of our PPAs are also less than the life of the power projects they are tied to. We will need to enter into other offtake agreements, or seek renewals or extensions of the existing PPAs, for the balance of the life of those power projects. Moreover, there are often other restrictions on our ability to, among other things, sell power to third parties and undertake expansion initiatives with other consumers. Failure to enter into or renew offtake arrangements in a timely manner and on terms that are acceptable to us could adversely affect our business, results of operations and cash flows. There could also be negative accounting consequences if we are unable to extend or replace expiring PPAs, including writing down the carrying value of assets at such power project sites.
The Government also provides Viability Gap Funding ("VGF") to various companies to support infrastructure projects that are economically justified but fall short of financial viability. Benefits under VGF are linked to certain conditions as set by the Government like achievement of minimum Capacity Utilization Factor ("CUF") during the fiscal year. We have obtained VGF benefits in some of our projects. During fiscal year ended March 31, 2020, we could not avail the VGF for our Uttar Pradesh 40 MWs project due to our inability to meet the conditions. Further, there can be no assurance that we will be able to perform at a level that we are able to claim VGF in the future for our projects.
Additionally, under the PPAs, our remedies in case of delays in payment by our customers may also be limited. For example, certain PPAs only permit us to terminate the PPA on account of non-payment of dues upon 90 days of our inability to recover such dues. Such risks limit our business flexibility, expose us to an increased risk of unforeseen business and industry changes and could have an adverse effect on our business, results of operations and cash flows.
In addition, most of the government agencies we enter into PPAs with under the NSM or the relevant state policies require us to agree to their standard form contracts and we cannot negotiate for commercial terms or other terms of funding that are more favorable to us.
In respect of some of our rooftop projects, we faced several operational challenges in fiscal 2021 resulting further delays in the sign-off of Joint Meter Readings (JMR) by customers and delay in collections of revenues.
Debt & Financing - Risk 3
Our substantial indebtedness could adversely affect our business, financial condition, results of operations and cash flows.
As of March 31, 2021, we had INR 10,462 million (US$ 143.2 million) in current liabilities, excluding the current portion of long-term debt and short-term debt, and INR 103,523 million (US$ 1,415.4 million) in outstanding long-term borrowings, including the current portion of long-term debt and short-term debt. Generally, these borrowings relate to the financing for our projects and are secured by project assets.
Our debt could have significant consequences on our operations, including:
- reducing the availability of our cash flow to fund working capital, capital expenditures, acquisitions and other general corporate purposes as a result of our debt service obligations; - limiting our ability to obtain additional financing; - limiting our flexibility in planning for, or reacting to, changes in our business, the industry in which we operate and the general economy;- potentially increasing the cost of any additional financing; and - limiting the ability of our project operating subsidiaries to pay dividends to us for working capital or return on our investment.
In addition, our borrowings under certain project-specific financing arrangement have floating rates of interest. Therefore, an increase or decrease in interest rates will increase or decrease our interest expense associated with such borrowing. A significant increase in interest expense could have an adverse effect on our business, financial condition, results of operations and cash flows impacting our ability to meet our payment obligations under our debt.
Any of these factors and other consequences that may result from our substantial indebtedness could have an adverse effect on our business, financial condition, results of operations and cash flows impacting our ability to meet our payment obligations under our debt. Our ability to meet our payment obligations under our outstanding debt depends on our ability to generate significant cash flow in the future. This, to some extent, is subject to general economic, financial, competitive, legislative and regulatory factors as well as other factors that are beyond our control. In addition, US$850.0 million of our debt is in the form of Green Solar bonds, which may be subject to refinancing risk, when they become due, as market conditions may not be possible to refinance the bonds at all or to refinance the bonds on favorable terms. In addition, our hedges on these bonds are covered up to INR 90.0/US$ and INR 93.0/US$ for the US$ 500.0 million and US$ 350.0 million bonds, respectively, which may expose us to additional hedging costs in the future. There has been a rating downgrade of the Government of India by Moody's during June'2020. In case there is a negative outlook for the Government of India, it may make global access to funds difficult.
In addition, US$500.0 million of our debt in form of solar green bonds are due for refinancing in fiscal 2023. We are unable to make any assurance that we will be able to refinance these solar green bonds or refinance the bonds on favorable terms.
Debt & Financing - Risk 4
Our growth prospects and future profitability depend to a significant extent on global liquidity and the availability of additional funding options with acceptable terms.
We require a significant amount of cash to fund the installation and construction of our projects and other aspects of our operations, and expect to incur additional borrowings in the future, as our business and operations grow. We may also require additional cash due to changing business conditions or other future developments, including any investments or acquisitions we may decide to pursue in order to remain competitive.
Historically, we have used loans, equity contributions, and government subsidies to fund our project development. We expect to expand our business with proceeds from third-party financing options, including any bank loans, equity partners, financial leases and securitization. However, we cannot guarantee that we will be successful in locating additional suitable sources of financing in the time periods required or at all, or on terms or at costs that we find attractive or acceptable, which may render it impossible for us to fully execute our growth plan. In addition, rising interest rates could adversely impact our ability to secure financing on favorable terms. In addition, a global or domestic economic crisis such as the current crises related to the COVID-19 pandemic, can cause a global or domestic recession or could adversely impact our ability to secure financing on favorable terms. Exchange rate fluctuations impact our ability to import capital goods as per the budget cost or on favorable terms. For a full discussion of the risks to our business associated with the COVID-19 pandemic, see "Risks to our Business related to the COVID-19 pandemic".
Installing and constructing solar projects requires significant upfront capital expenditure and there may be a significant delay before we can recoup our investments through the long-term recurring revenue of our solar projects. Our ability to obtain external financing is subject to a number of uncertainties, including:
- our future financial condition, results of operations and cash flows; - the general condition of global equity and debt capital markets; - our credit ratings and past credit history; - the prevailing exchange rate of Indian rupee against major currencies, in particular, the U.S. dollar; - regulatory and government support in the form of tax incentives, preferential tariffs, project cost subsidies and other incentives; - the continued confidence of banks and other financial institutions in Azure Power and the solar power industry; - economic, political and other conditions in the jurisdictions where we operate; and - our ability to comply with any financial covenants under our debt financing.
Any additional equity financing may be dilutive to our Company's shareholders and any debt financing may contain restrictive covenants that limit our flexibility going forward. Furthermore, our credit ratings may be downgraded, which would adversely affect our ability to refinance debt and increase our cost of borrowing. Failure to manage discretionary spending and raise additional capital or debt financing as required may adversely impact our ability to achieve our intended business objectives.
Debt & Financing - Risk 5
If we fail to comply with financial and other covenants under our loan agreements, our financial condition, results of operations, cash flows and business prospects may be materially and adversely affected.
We expect to continue to finance a significant portion of our project development and construction costs with project financing. The agreements with respect to our existing project-level indebtedness contain financial and other covenants that require us to maintain certain financial ratios or impose certain restrictions on the disposition of our assets or the conduct of our business. In addition, we typically pledge our solar project assets or accounts or trade receivables, and in certain cases, shares of the special purpose vehicles, to raise debt financing, and we are restricted from creating additional security over our assets. Such accounts or trade receivables generally includes all income generated from the sale of electricity in the solar projects.
Our financing agreements also include certain restrictive covenants whereby we may be required to obtain approval from our lenders to, among other things, incur additional debt, undertake guarantee obligations, enter into any scheme of merger, amalgamation, compromise, demerger or reconstruction, change our capital structure and controlling interest, dispose of or sell assets, transfer shares held by major shareholders to third parties, invest by way of share capital, lend and advance funds, make payments, declare dividends in the event of any default in repayment of debts or failure to maintain financial ratios, place deposits and change our management structure. Most of our lenders also impose significant restrictions in relation to our solar projects, under the terms of the relevant project loans taken by our respective subsidiaries. For example, we are required to obtain lenders' consent to make any changes to, or terminate, project documents, waive any material claims or defaults under the project documents, make any changes to financing plans relating to our projects, and replace suppliers or other material project participants. There can be no assurance that such consent will be granted in a timely manner, or at all. In the event that such lender consents are granted, they may impose certain additional conditions on us, which may limit our operational flexibility or subject us to increased scrutiny by the relevant lenders. The time required to secure consents may hinder us from taking advantage of a dynamic market environment. These agreements also grant certain lenders the right to appoint nominee directors on the Board of Directors of AZI or its subsidiaries and require us to maintain certain ratings or other levels of credit worthiness. If we breach any financial or other covenants contained in any of our financing arrangements, we may be required to immediately repay our borrowings either in whole or in part, together with any related costs.
Our failure to comply with financial or restrictive covenants or periodic reporting requirements or to obtain our lenders' consent to take restricted actions in a timely manner or at all may result in the declaration of an event of default by one or more of our lenders, which may accelerate repayment of the relevant loans or trigger cross defaults under other financing agreements. We cannot assure you that, in the event of any such acceleration or cross-default, we will have sufficient resources to repay these borrowings. Failure to meet our obligations under the debt financing agreements could have an adverse effect on our cash flows, business and results of operations. Furthermore, a breach of those financial and other covenants or a failure to meet certain financial ratios under these financing agreements could also restrict our ability to pay dividends.
We have issued two Solar Green Bonds, consisting of 5.65% Solar Green Bonds for US$ 350.0 million in September 2019 and 5.5% Solar Green Bonds for US$ 500.0 million in August 2017, collectively ("the Green Bonds"). If we are unable to comply with the covenants as per the Green Bond indentures, or future debt obligations and other agreements, there could be a default under the terms of these agreements. In the event of a default under these agreements, the holders of the debt could accelerate repayment of the principal and interest accrued on the outstanding debt and declare all outstanding amounts due and payable or terminate the agreements, as the case may be. Furthermore, some of our debt agreements, including the Indenture for the green bonds, contain cross-acceleration provisions. As a result, our default under one debt agreement may cause the acceleration of repayment of not only such debt but also other debt, result in a default under our other debt agreements, increase pricing of loans or lender's holding debt disbursement. If any of these events occur, our assets and cash flow may not be sufficient to repay in full all of our indebtedness, and we may not be able to find alternative financing on terms that are favorable or acceptable to us.
Debt & Financing - Risk 6
Changed
The delay between making significant upfront investments in our solar and other renewable energy projects and receiving revenue could materially and adversely affect our liquidity, business, results of operations and cash flows.
There are generally several months between our initial bid in renewable energy auctions to build solar or other renewable energy projects and the date on which we begin to recognize revenue from the sale of electricity generated by such projects. Our initial investments include, without limitation, legal, accounting and other third-party fees, costs associated with project analysis and feasibility study, payments for land rights, payments for interconnection and grid connectivity arrangements, government permits, engineering and procurement of solar panels, balance of system costs or other payments, which may be non-refundable. Our projects may not be fully monetized for 25 years given the average length of our PPAs, but we bear the costs of our initial investment upfront. Furthermore, we have historically relied on our own equity contribution, international lenders and bank loans to pay for costs and expenses incurred during project development. Solar and other renewable energy projects typically generate revenue only after becoming commercially operational and starting to sell electricity to the power grid through offtakers. There may be long delays from the initial bid to projects becoming shovel-ready, due to the timing of auctions, obtaining permits and the grid connectivity process. Between our initial investment in the development of permits for solar projects and their connection to the transmission grid, there may be adverse developments, such as unfavorable environmental or geological conditions, pandemics, labor strikes, panel shortages or monsoon weather. For instance, in respect of some of our rooftop projects, we had faced several operational challenges resulting further delays in sign-off of Joint Meter Readings (JMR) by customers and ultimate collections of revenues. Same had also resulted in financial issues amid high operational and maintenance cost. Furthermore, we may not be able to obtain all of the permits as anticipated, permits that were obtained may expire or become ineffective and we may not be able to obtain project level debt financing as anticipated. In addition, the timing gap between our upfront investments and actual generation of revenue, or any added delay due to unforeseen events, such as delays associated with COVID-19 could put strains on our liquidity and resources, and materially and adversely affect our profitability, results of operations and cash flows. For a full discussion of the risks to our business associated with the COVID-19 pandemic, see "Risks to our Business related to the COVID-19 pandemic".
Debt & Financing - Risk 7
Our ability to raise foreign capital may be constrained by Indian law.
Our Indian subsidiaries are subject to exchange controls that regulate borrowing in foreign currencies. Such regulatory restrictions limit our financing sources and hence could constrain our ability to obtain financings on competitive terms and refinance existing indebtedness. In addition, we cannot assure you that the required approvals will be granted to us without onerous conditions, or at all. Limitations on raising foreign debt may have an adverse impact on our business growth, financial condition, results of operations and cash flows.
Corporate Activity and Growth1 | 1.4%
Corporate Activity and Growth - Risk 1
Added
We may not be able to successfully complete its Rooftop asset sale entered into subsequent to March 2021 and may not complete other asset sales or complete such asset sales at the prices that we desire.
To optimize cost and to enhance returns on invested capital, in Fiscal 2021, we had decided to sell off certain subsidiaries on a going concern basis, which currently form part of our Rooftop business. Out of this identified portfolio, subsequent to March 2021, we entered a sales contract (the "Rooftop Sale Agreement") with Radiance Renewables Pvt. Ltd. ("Radiance") to sell certain subsidiaries (the "Rooftop Subsidiaries") having an operating capacity of 153 MW, for INR 5,350 million (US$ 73.1 million), subject to certain purchase price adjustments. Pursuant to the Rooftop Sale Agreement, Radiance will acquire 100% of the equity ownership of the Rooftop Subsidiaries owned by the Company's subsidiaries Azure Power India Pvt. Ltd. and Azure Power Rooftop Pvt. Ltd, as more fully described below.
The sale of Rooftop Subsidiaries having 94.4 MWs operating capacity is expected to be consummated within the next 12 months and accordingly the assets and related liabilities of these subsidiaries are shown as "Assets classified as held for sale" in our consolidated balance sheet as of March 31, 2021. We recognized an impairment loss of INR 2,498 million (US$ 34.1 million) in our Consolidated Statement of Operations in this regard.
Further, under the terms of our Rooftop Sale Agreement with Radiance, 48.6% of the equity ownership in the 43.2 MWs operating capacity will be transferred to Radiance within next 12 months, and pursuant to the terms of the Green Bond Indentures, the remaining 51.4% may only be transferred to Radiance after our obligations under our Green Bonds are satisfied or such Green Bonds are refinanced. All of the cash flows related to such 43.2 MWs will continue to service our Green Bond obligations until the remaining 51.4% equity ownership in the 43.2 MWs is transferred to Radiance. As the refinancing of our Green Bonds is not anticipated to occur within 12 months, the assets and liabilities of these subsidiaries are not presented as "Assets classified as held for sale" and instead continue to be classified within the respective balance sheet captions as of March 31, 2021. In the event transference does not occur, we must reimburse Radiance the equity value of the assets not transferred along with an 10.5% per annum equity return, which could have a material adverse effect on our financial condition, results of operations and cash flows. Based on management's assessment the above sale transactions are probable over the period defined in the agreement.
There is also a restriction on transfer of equity ownership relating to the 16 MW project with Delhi Jal Board (DJB), wherein 49% of the equity ownership will be transferred to Radiance by the closing date with in next 12 months, and the remaining 51% will be transferred on or after March 31, 2024. Accordingly, the related assets and liabilities of the DJB 16 MW project are not presented as "Assets classified as held for sale" and instead continue to be classified within the respective balance sheet captions as of March 31, 2021.
We determined that the decision to sell the Rooftop Subsidiaries and the subsequent execution of the Rooftop Sale Agreement are indicators of impairment, and therefore, we undertook an impairment assessment for the Rooftop Subsidiaries. Management used the sale price in the Rooftop Sale Agreement as our best estimate of the recoverable value of the Rooftop Subsidiaries. The impairment loss recorded in relation to the Property, Plant and Equipment of the Rooftop Subsidiaries not shown as "Assets classified as held for sale" was INR 657 (US$ 9.0 million).
The Company has further identified a subsidiary for sale, on a going concern basis at expected consideration of INR 123 million (US$ 1.7 million). Subsequent to year end, Company has entered into a sale agreement with buyer and pursuant there to, 100% of the ownership of this subsidiary was transferred to the buyer on receipt of consideration. The Company has recognized an impairment loss of INR 100 million (US$ 1.4 million) in the Consolidated Statement of Operations in this respect.
We recognized an impairment loss in relation to the rooftop subsidiaries aggregating to INR 3,255 million (US$ 44.5 million) during the fiscal year ended March 31, 2021 on account of the sale of the Rooftop Subsidiaries.
In addition, we may sell other assets when suitable opportunities arise to recycle capital for future growth. However, our ability to consummate divestitures is subject to various risks and uncertainties, including:
- failure to identify suitable investors and reach agreement on commercially reasonable terms; - failure to obtain regulatory approvals and third-party (lenders, offtakers etc.) consents necessary to consummate the proposed divestiture; and - other companies may provide similar assets depressing valuations for the targeted assets.
Legal & Regulatory
Total Risks: 13/69 (19%)Below Sector Average
Regulation6 | 8.7%
Regulation - Risk 1
Substantially all of our business and operations are located in India and we are subject to regulatory, economic, social and political uncertainties in India.
Substantially all of our business and employees are located in India, and we intend to continue to develop and expand our business in India. Consequently, our financial performance will be affected by changes in exchange rates and controls, interest rates, changes in government policies, including taxation policies, social and civil unrest and other political, social and economic developments in or affecting India.
The Indian government has exercised and continues to exercise significant influence over many aspects of the Indian economy. The Indian governments have generally pursued policies of economic liberalization and financial sector reforms, including by significantly relaxing restrictions on the private sector. Nevertheless, the role of the Indian central and state governments in the Indian economy as producers, consumers and regulators has remained significant and we cannot assure you that such liberalization policies will continue. The rate of economic liberalization could change, and specific laws and policies affecting solar power producers, foreign investments, currency exchange rates and other matters affecting investments in India could change as well, including exposure to possible expropriation, nationalization or other governmental actions.
A significant change in India's policy of economic liberalization and deregulation or any social or political uncertainties could significantly harm business and economic conditions in India generally and our business and prospects. Recently there have been ongoing mass protest by farmers, against three farm acts which were passed by the Parliament of India in September 2020. The introduction of the law caused protests in several parts of the country like Delhi, Haryana and Punjab. In case there are mass protests leading to civil unrest, such incidents could impact both our construction as well as operations and maintenance activities.
Regulation - Risk 2
Changing laws, rules and regulations and legal uncertainties, including adverse application of corporate and tax laws, may adversely affect our business, financial condition, results of operations, cash flows and prospects.
The regulatory and policy environment in which we operate is evolving and subject to change. Such changes, including the instances mentioned below, may adversely affect our business, financial condition, results of operations, cash flows and prospects, to the extent that we are unable to suitably respond to and comply with any such changes in applicable law and policy.
- A comprehensive national goods and services tax ("GST") regime that combines taxes and levies by the central and state governments into a unified rate structure has been in effect since July 1, 2017, unifying and replacing various indirect taxes applicable earlier. The GST rules were amended multiple times since the effective date. The GST led to an increase in the cost of operations of the Indian subsidiaries part of the Green Bond ("Restricted Subsidiaries") at increased rates of GST ranging from 5% to 18%. Under the earlier value added tax ("VAT") regime, the VAT rate on major items like modules and invertors was Nil and the VAT rate on various other items like mounting structure, transmission lines, AC cable, DC cable, AC electrical materials, DC electrical materials, combiner boxes, connectors and Balance of System ("BOS") was 2%. However, under the current GST regime, the GST rate on these items was increased to 5%. We have filed change-in-law petitions before relevant electricity regulatory commissions, and we have also received favorable orders allowing our change in law petitions from some of the electricity regulatory commissions. We have incurred incremental costs due to the introduction of GST in connection with our Telangana 100 MW project and started receiving monthly annuities for the projects Andhra Pradesh 3 (50 MW) and Uttar Pradesh 3 (40 MW). We, however, can make no assurances that our offtakers and the electricity regulatory commissions will revise relevant tariffs or allow lump sum payment along with late payment surcharge, sufficiently to cover our increased expenses from GST. To the extent we are unable to pass on the impact of the imposition of GST to our offtakers in part or in whole under any of our PPAs, our increased costs of purchase of products and services due to GST could adversely affect our operating results, cash flows and financial condition. While electricity regulatory commissions have allowed pass through on projects under construction, it rejected claims on O&M contracts except for Chhattisgarh 1.1, 1.2 and 1.3 (30 MW) projects in which we have received favorable order. While the impact of GST on O&M is minor and going forward, we have eliminated margins on O&M operations by shifting O&M operations to project SPVs, we have also filed appeals before APTEL. On December 31, 2018, the Ministry of Finance issued a notice that 70% of the gross consideration of the supplies under a Composite EPC Contract will be taxed at 5% (GST rate applicable on the supply of specified renewable energy goods) and 30% of the gross consideration of the supplies under the Composite EPC Contract will be taxed at 18%, (GST rate applicable on the supply of construction, engineering, installation, or other technical services in relation to renewable power generating devices), an increase from the earlier tax rate of 5%. The notification resulted in an increase in the effective tax rates under the GST laws from 5% to 8.9% (on gross consideration) on the Composite EPC Contracts with effect from January 1, 2019. While our change in law petitions are pending before electricity regulatory commissions seeking pass through of the additional tax under the Composite EPC Contracts, the Maharashtra Electricity Regulatory Commission has rejected our claim, and hence there can be no assurances that we will get favorable orders in other cases.
- The Indian government also amended the Income Tax Act, 1961 in respect of the manner of determining the ‘tax residency' of a company in India with effect from April 1, 2017. Previously, a foreign company could be a tax resident of India only if its control and management was situated wholly in India. Under the amended rules, a company will be treated as tax resident of India if (i) it is an Indian company; or (ii) its place of effective management ("POEM") is in India. POEM is defined in the Income Tax Act, 1961, to mean a place where key management and commercial decisions that are necessary for the conduct of the business of an entity as a whole are, in substance, made. The Indian government also issued the final guidelines for determining the POEM of a company on January 24, 2017. The applicability of the amended provisions and the treatment of our subsidiaries under such provisions is uncertain. - The provisions of the General Anti-Avoidance Rules ("GAAR") came into effect on April 1, 2017. The GAAR provisions can be invoked once an arrangement is regarded as an "impermissible avoidance arrangement", which is any arrangement, or a part of it, the main purpose of which is to obtain a tax benefit and which satisfies at least one of the following tests: (i) creates rights, or obligations, which are not ordinarily created between persons dealing at arm's length; (ii) results, directly or indirectly, in misuse, or abuse, of the provisions of the Income Tax Act, 1961; (iii) lacks commercial substance or is deemed to lack commercial substance, in whole or in part; or (iv) is entered into, or carried out, by means, or in a manner, which is not ordinarily employed for bona fide purposes. The onus to prove that the transaction is not an "impermissible avoidance agreement" is on the assessee, i.e. an arrangement shall be presumed, unless it is proved to the contrary by the assessee. If GAAR provisions are invoked, then the tax authorities have wide powers, including denial of tax benefit or a benefit under a tax treaty the consequences and effects of which are not determinable at present. Such effects could materially and adversely affect our business, prospects, cash flows, financial condition and results of operations. - The Indian Government has proposed to replace the existing Income Tax Act, 1961 with a new Direct Tax Code. A draft report on the Direct Tax Code, which is currently not in the public domain, was placed before the Indian Finance Minister for her consideration. The consequences and effects of changes in India's income tax policy and law on this account are not determinable at present.
Uncertainty in the applicability, interpretation or implementation of any amendment to, or change in, governing law, regulation or policy in the jurisdictions in which we operate, including by reason of an absence, or a limited body, of administrative or judicial precedent may be time consuming as well as costly for us to resolve and may impact the viability of our current business or restrict our ability to grow our business in the future.
Regulation - Risk 3
Our international corporate structure and operations require us to comply with anti-corruption laws and regulations of the United States government and various non-U.S. jurisdictions. If we are not in compliance with applicable legal requirements, we may be subject to civil or criminal penalties and other remedial measures.
We are subject to the U.S. Foreign Corrupt Practices Act, or the FCPA, which prohibits, in relevant part, U.S. nationals, companies that have securities registered in the U.S. and any officer, director, employee, or agent of such issuer or any shareholder thereof acting on behalf of such issuer from bribing foreign officials for the purpose of obtaining or keeping business or otherwise obtaining favorable treatment and imposes obligations to keep accurate books and records and maintain appropriate internal controls. We have been and will continue to be subject to anti-corruption, anti-bribery and anti-facilitation payment legislation in other jurisdictions, which in certain circumstances go beyond the scope of the FCPA rules and regulations, including in India.
The current and future jurisdictions in which we operate our business may have experienced governmental corruption to some degree, and in certain circumstances, strict compliance with anti-bribery and anti-facilitation payment laws may conflict with local customs and practices, which is likely to negatively impact our results of operations. We have developed and implemented formal controls and procedures to ensure that we are in compliance with the FCPA as well as anti-corruption, anti-bribery and anti-facilitation payment laws. However, compliance with these new controls and procedures could make it more difficult for us to obtain timely permits or otherwise complete our projects on schedule in jurisdictions where strict compliance with anti-corruption and anti-bribery laws may conflict with local customs and practices.
Any historic or future violations of these laws, regulations and procedures by our employees, independent contractors, subcontractors and agents could be costly and time-consuming to investigate and expose us to administrative, civil or criminal penalties or fines (including under U.S. and Indian laws and regulations as well as foreign laws). If we were to be investigated for, charged with, or convicted of, violating these laws and regulations, our reputation could be harmed and it could cause some of our investors to sell their interests in our company to be consistent with their internal investment policies or to avoid reputational damage, and some investors might forego the purchase of our equity shares, all of which may negatively impact the trading prices of our equity shares. In addition, any administrative, civil or criminal penalties or fines could have a material adverse effect on our business results of operations and cash flows.
Regulation - Risk 4
Foreign investment laws in India include certain restrictions, which may affect our future assets sales, acquisitions or investments in India.
India regulates ownership of Indian companies by non-residents, and although some restrictions on foreign investment have been relaxed in recent years others, such as investments from countries bordering India, have been subject to more regulation. Pursuant to the Consolidated Foreign Direct Investment Policy, 2020 (the "FDI Policy"), investments can be made by non-residents in Indian companies to the extent of the percentage of the total capital of the Indian company specified in the FDI Policy. At present, the FDI Policy permits 100% foreign direct investment in Indian companies engaged in the power sector. Under current Indian regulations, transfers of shares between non-residents and residents are permitted (subject to certain exceptions) if they comply with, among other things, the Foreign Exchange Management (Non-debt Instruments) Rules, 2019, as amended from time to time, in relation to pricing and valuation of such shares and certain reporting requirements for such transactions specified by the Reserve Bank of India. If the transfer of shares is not in compliance with such pricing guidelines or reporting requirements or falls under any of the exceptions specified by the Reserve Bank of India, the prior approval of the Reserve Bank of India will be required before any such transfer may be consummated. We may not be able to obtain any required approval from the Reserve Bank of India or any other Indian regulatory authority on any particular terms or at all.
For example, under the FDI policy, the Indian government provides additional requirements for foreign investments in India, including requirements with respect to downstream investments by Indian companies owned or controlled by non-resident entities and the transfer of ownership or control, from resident Indian persons or entities to non-residents, of Indian companies in sectors with limits on foreign investment. As substantially all of AZI's and AZR's equity shares are directly held by Azure Power Global Limited, it would be considered an entity owned and controlled by non-residents under applicable Indian laws. Accordingly, any downstream investment by AZI or AZR into another Indian company will have to be in compliance with conditions applicable to such Indian entity, in accordance with the FDI policy. In addition, there may be investors who may not be able to buy assets we wish to sell in future. There are guidelines in relation to pricing and valuation of shares and restrictions on sources of funding for such investments. While these guidelines currently do not materially limit our planned investments or asset sales in our Indian subsidiaries, to the extent they become more restrictive, they may restrict our ability to make further equity investments in India, including through Azure Power Global Limited.
Further, India's Foreign Exchange Management Act, 1999, as amended, and the rules and regulations promulgated thereunder ("FEMA") prohibit us from borrowing from our Indian subsidiaries. We are permitted to lend to our Indian subsidiaries subject to compliance with India's policy on external commercial borrowings as notified by the Reserve Bank of India from time to time, which specifies certain conditions, including in relation to eligible lenders and borrowers, permitted end use and limits on the all-in-cost.
Regulation - Risk 5
If we are unsuccessful in our efforts to establish and/or maintain our compliance with the local content requirements in certain states, our financial results could be adversely affected.
In some cases, we are required by the central government in national auctions to procure solar panels solely from Indian manufacturers. Certain states or others may, in the future, require us to procure a defined portion of our solar system components from their designated geographical locales. Such requirements are commonly referred to as "local content requirements." In order to satisfy these local content requirements, we may need to undertake localization initiatives in such geographical locale. Some of our competitors with more significant capital resources may implement or expedite their own localization efforts in these geographical locales, and those efforts may result in competitive advantages for them. We may be faced with shortages or quality issues if projects we bid on impose local content requirements. Our costs may also be higher as a result of these requirements. Our failure to successfully implement appropriate localization initiatives, or otherwise acquire and maintain the capability to satisfy applicable local content requirements, could result in our losing business to our competitors and/or our breaching the terms of agreements, potentially resulting in damages, including monetary penalties. Depending on the value to us of lost business or the amounts of any contractual penalties, these consequences could have a material adverse effect on our results of operations and cash flows.
Regulation - Risk 6
Our operations are subject to governmental, health, safety and environmental regulations, which require us to obtain and comply with the terms of various approvals, licenses and permits. Any failure to obtain, renew or comply with the terms of such approvals, licenses and permits in a timely manner or at all may have a material adverse effect on our results of operations, cash flows and financial condition.
The power generation business in India is subject to a broad range of environmental, health, safety and other laws and regulations. These laws and regulations require us to obtain and maintain a number of approvals, licenses, registrations and permits for developing and operating power projects. Additionally, we may need to apply for more approvals in the future, including renewal of approvals that may expire from time to time. For example, we require various approvals during construction of our solar projects and prior to the commissioning certificate is issued, including capacity allocation and capacity transfer approvals, approvals from the local pollution control boards, evacuation and grid connectivity approvals and approval from the chief electrical inspector for installation and energization of electrical installations at the solar project sites. In addition, we are required to comply with state-specific requirements. Certain approvals may not be obtained in a timely manner, as a global crisis such as the COVID-19 pandemic may lead to limited operations or no operations at Government offices, resulting in delays in obtaining approvals. Certain approvals may also be granted on a provisional basis or for a limited duration and require renewal. If the conditions specified therein are not satisfied at a later date, we may not be able to evacuate power from these projects. For example, with respect to our Assam 1 project, there were delays in obtaining an approval to adopt the discovered tariff and to approve the PPA from the appropriate commission.
In addition, we could be affected by the adoption or implementation of new safety, health and environmental laws and regulations, new interpretations of existing laws, increased governmental enforcement of environmental laws or other similar developments in the future. For instance, we currently fall under an exemption granted to solar photovoltaic projects that exempts us from complying with the Environment Impact Assessment Notification, 2006, issued under the Environment (Protection) Act, 1986. While we are not required to obtain consents under the Water (Prevention and Control of Pollution) Act, 1974, Air (Prevention and Control of Pollution) Act, 1981 and the Hazardous Waste (Management, Handling and Transboundary Movement) Rules, 2008, certain procedural requirements, such as informing the Pollution Control Board, exists. However, there can be no assurance that we will not be subject to any such consent requirements in the future, and that we will be able to obtain and maintain such consents or clearances in a timely manner, or at all, or that we will not become subject to any regulatory action on account of not having obtained or renewed such clearances in any past periods. Furthermore, our government approvals and licenses are subject to numerous conditions, some of which are onerous and require us to make substantial expenditure. We may incur substantial costs, including clean up or remediation costs, fines and civil or criminal sanctions, and third-party property damage or personal injury claims, as a result of any violations of or liabilities under environmental or health and safety laws or noncompliance with permits and approvals, which, as a result, may have an adverse effect on our business and financial condition. In addition, during a global crisis such as the COVID-19 pandemic, we may be required to obtain special permits from Government authorities to start construction at project sites, and we may not be able to obtain such consents or clearances in a timely manner leading to an adverse impact on us.
We cannot assure you that we will be able to apply for or renew any approvals, licenses, registrations or permits in a timely manner, or at all, and that the relevant authorities will issue any of such approvals, licenses, registrations or permits in the time frames anticipated by us. Further, we cannot assure you that the approvals, licenses, registrations and permits issued to us would not be subject to suspension or revocation for non-compliance or alleged non-compliance with any terms or conditions thereof, or pursuant to any regulatory action. Any failure to apply for, renew and obtain the required approvals, licenses, registrations or permits, or any suspension or revocation of any of the approvals, licenses, registrations and permits that have been or may be issued to us, or any onerous conditions made applicable to us in terms of such approvals, licenses, registrations or permits may impede the successful commissioning and operations of our power projects, which may adversely affect our business, results of operations and cash flows. For instance, a petition had been filed in 2019 before the Supreme Court of India aimed at the conservation of two species of birds, the Great Indian Bustard and the Lesser Florican, which are endangered species majorly existing in the states of Rajasthan and Gujarat. The petitioner through an Interlocutory Appeal ("IA") had further sought directions to ensure predator proof fencing, barring installation of overhead power lines, and installation of solar infrastructure in priority and potential habitats for conservation of these two species. In an interim order in the IA proceedings, the Supreme Court on April 19, 2021, has ordered for immediate installation of diverters, as well as conversion of all overhead power lines to underground lines in priority and potential areas. However, for high voltage line due to complexity any technical non feasibility if identified can be referred for technical evaluation by a committee set up by the Supreme Court in this regard. The conversion of overhead cables into underground power lines, wherever considered feasible by such committee, is to take place within a period of one year. As per the order, any costs incurred on account of implementation of such steps would be compensated by the respective state governments/ authorities, and such cost could be passed on to the ultimate consumer, subject to approval of the competent regulatory authority. If the order necessitates for implementation of undergrounding after all provisions under the order are exercised and or otherwise, then we might face difficulties in recovering costs for such corrective measures from the respective state governments/authorities in a timely manner and may also face resistance from the regulators when we seek an increase in tariff rates. This may lead to disputes and impact our business, financial condition, results of operations and cash flows. We estimate majority of our projects currently located in Rajasthan, may be adversely impacted by the order. It may also impact our current awarded capacity, which we may install in the region.
Litigation & Legal Liabilities2 | 2.9%
Litigation & Legal Liabilities - Risk 1
We may become involved in costly and time-consuming litigation and other regulatory proceedings, which require significant attention from our management.
We may, in the ordinary course of our business, become involved in litigation, administrative or arbitral proceedings. For example, we are, and may become subject to additional demands from Indian governmental or tax authorities, including, but not limited to, on account of differing interpretations of central and state tax statutes in India, which are extensive and subject to change from time to time. Changes in regulations or tax policies, or adoption of differing interpretations of existing provisions, and enforcement thereof by governmental, taxation or judicial authorities in India may become the subject of legal proceedings involving us from time to time.
Additionally, claims may be brought against or by us from time to time regarding, for example, defective or incomplete work, defective products, personal injuries or deaths, damage to or destruction of property, breach of warranty, late completion of work, delayed payments, breach of module supply contracts, intellectual property rights or regulatory compliance labor issues, environmental issues and ownership rights. These claims may subject us to litigation, arbitration and other legal proceedings, which may be expensive, lengthy, disruptive to normal business operations and require significant attention from our management.
If we were found to be liable on any of the claims against us, we would incur a charge against earnings to the extent a reserve had not been established for coverage. If amounts ultimately realized from the claims by us were materially lower than the balances included in our financial statements, we would incur a charge against earnings to the extent profit had already been accrued. Charges and write-downs associated with such legal proceedings could have a material adverse effect on our financial condition, results of operations and cash flow. Moreover, legal proceedings, particularly those resulting in judgments or findings against us, may harm our reputation and competitiveness in the market.
For example, Gujarat Urja Vikas Nigam Limited had filed a petition with the Gujarat Electricity Regulatory Commission, seeking recalculation of the tariff under the PPA on the basis of actual cash flow required for development of solar projects and consequent revision of the tariff payable by it, in relation to certain solar power projects including our 10 MWs Gujarat 1 project. While the Gujarat Electricity Regulatory Commission and the Appellate Tribunal for Electricity dismissed the claims made by Gujarat Urja Vikas Nigam Limited, an appeal filed by Gujarat Urja Vikas Nigam Limited is pending before the Supreme Court of India. An unfavorable outcome in this appeal will result in significant cost to us.
Further, in Andhra Pradesh, on July 7, 2019, the Government of Andhra Pradesh vide an order set up a High-Level Negotiation Committee to revisit and review PPAs for solar and wind projects in the state of Andhra Pradesh with a view to reduce tariffs in these PPAs. A letter dated July 12, 2019, was issued by Andhra Pradesh Distribution Company to developers to reduce tariffs to INR 2.43 per unit for wind projects, and INR 2.44 per unit for solar projects from the date of commissioning and threatened termination of the PPA in the case of the refusal of the developers to accede to the reduction.
The developers challenged both the order and the letter in the High Court at Vijayawada. The High Court vide order dated September 24, 2019, set aside both the order and the letter and as an interim measure until the issue is decided by the APERC, directed the Andhra Pradesh Distribution Company to honor outstanding and future bills of the developers and pay at an interim rate of INR 2.43 and INR 2.44 per unit for wind and solar projects respectively. This above-mentioned Court order of single judge had been challenged in an appeal filed by the developers including Azure Power. The matter is listed for further hearing in the court and the matter adjourned in APERC till disposal of writ appeals before High Court at Vijayawada. An unfavorable outcome could potentially result in a significant expense to us. Further, other states might also violate binding contractual PPA tariffs following the unfavorable outcome.
Litigation & Legal Liabilities - Risk 2
We are subject to claims, arbitration claims and other legal proceedings pertaining to executive compensation or other stock-related matters in addition to other litigation in the ordinary course of business.
As further discussed under Item 8 of this Annual Report, we are involved in two arbitration proceedings concerning matters of executive compensation and stock purchase with former chief executive officer. Our Company and our subsidiary, Azure Power India Private Limited, are respondents in arbitration proceedings initiated by our former Chairman, CEO and Managing Director of our Company, Mr. Inderpreet Singh Wadhwa ("IW") and erstwhile COO Mr. H.S Wadhwa ("HSW"), in relation to the purchase price of the shares of IW's and HSW's in Azure Power India Private Limited before Singapore International Arbitration Centre (SIAC). The arbitration has been concluded and the award is awaited. We believe in the merits of our case; however, an unfavorable outcome in these proceedings could potentially have a material adverse effect on our results of operations, cash flows and financial condition.
In addition, our Company and our subsidiary Azure Power India Private Limited are respondents to arbitration proceedings initiated by IW in relation to his transition agreement before the Mumbai Centre for International Arbitration ("MCIA"). The arbitration has been concluded and the award is awaited. We believe in the merits of our case; however, we cannot ensure the outcome of the proceedings. The claim could have an adverse impact on our results however, the amount is not material to our financial position.
In addition to the arbitration proceedings pertaining to executive compensation and the stock purchase, we are regularly involved in other litigation matters in the ordinary course of business. While we believe that these litigation matters should not have a material adverse impact on our business, financial condition, results of operations or future prospects, we may be unable to successfully defend or resolve any current or future litigation matters.
Taxation & Government Incentives4 | 5.8%
Taxation & Government Incentives - Risk 1
Our Company may become subject to unanticipated tax liabilities that may have a material adverse effect on our Company's results of operations.
Our Company is structured as a Global Business Company ("GBC") in Mauritius. A GBC must at all times:
(i) Carry out its core income generating activities in or from Mauritius by:
- employing either directly or indirectly a reasonable number of qualified persons to carry out the core activities, and - having a minimum level of expenditure, which is proportionate to its level of activities (ii) Be managed and controlled from Mauritius; and (iii) Be administered by a Management Company.
In a circular addressed to Management Companies dated October 12, 2018, the Financial Services Commission in Mauritius have advised that going forward, in assessing the exact substance requirements to be met by a GBC, they shall consider the nature and level of core income generating activities conducted (including the use of technology) by the GBC and taking into account the circumstances of each GBC, based on the following indicative guidelines:
Non-financial services activities Minimum expenditure Employment in Mauritius (direct or indirect) (U.S. dollar) Investment holding (excluding IP rights) 12,000 No minimum employment specified Non-investment holding 15,000 If annual turnover is: -Less than US$100 million – minimum of one -More than US$100 million – minimum of two
After 30 June 2021, the Deemed Tax Credit will not be applicable to our Company and will be replaced with a new tax regime. The income tax rate for GBCs is at 15%, but subject to meeting certain prescribed conditions, and meeting the substance requirements issued by the Financial Services Commission for a GBC, our Company may benefit from a partial exemption of 80% on certain types of income such as foreign source dividend and interest. Where our Company derives income, which is subject to foreign tax, and where the said partial exemption has not been applied, the amount of foreign tax paid may be allowed as a credit against income tax payable in Mauritius in respect of that income.
Taxation & Government Incentives - Risk 2
You may be subject to Indian taxes on income arising through the sale of our equity shares.
Pursuant to recent amendments to the Indian Income Tax Act, 1961, as amended, income arising directly or indirectly through the sale of a capital asset, including any share or interest in a company or entity registered or incorporated outside of India, will be liable to tax in India, if such share or interest derives, directly or indirectly, its value substantially from assets (whether tangible or intangible) located in India and whether or not the seller of such share or interest has a residence, place of business, business connection, or any other presence in India. The share or interest of the company or entity registered or incorporated outside of India is deemed to derive its value substantially from the assets located in India if the value of such Indian assets exceeds INR 100 million and represents at least 50% of the value of all the assets owned by the company or entity registered or incorporated outside of India. Substantially all of our assets are located in India.
However, if the transferor of share or interest in a company or entity registered or incorporated outside of India (along with its associated enterprises), neither holds the right of management or control in the company or entity registered or incorporated outside of India nor holds voting power or share capital or interest exceeding 5% of the total voting power or total share capital or interest in the company or entity registered or incorporated outside of India, at any time during the twelve months preceding the date of transfer, such small shareholders are exempt from the indirect transfer provisions mentioned above. The amendments also do not deal with the interplay between the amendments to the Indian Income Tax Act, 1961, as amended, and the existing Double Taxation Avoidance Agreements that India has entered into with countries such as the United States in case of an indirect transfer. Accordingly, the implications of the recent amendments are presently unclear. If it is determined that these amendments apply to a holder of our equity shares, such holder could be liable to pay taxes in India on such income.
Taxation & Government Incentives - Risk 3
Our Company may be classified as a passive foreign investment company, which could result in adverse U.S. federal income tax consequences to certain U.S. investors of our Company's equity shares.
Our Company believes that it was not a passive foreign investment company ("PFIC") for our taxable year ending March 31, 2021 and that, based on the present composition of its income and assets and the manner in which it conducts its business, our Company will not be a PFIC in our Company's current taxable year or in the foreseeable future. Whether our Company is a PFIC is a factual determination made annually, and our Company's status could change depending, among other things, upon changes in the composition and amount of our gross income and the relative quarterly average value of its assets. In particular, if our Company generate a small amount of gross income that is attributable to passive income in a taxable year, then there is a risk that our Company may be a PFIC for that year. If our Company was a PFIC for any taxable year in which you hold our Company's equity shares, you generally would be subject to additional taxes on certain distributions and any gain realized from the sale or other taxable disposition of our equity shares regardless of whether our Company continued to be a PFIC in any subsequent year, unless you mark your equity shares to market for tax purposes on an annual basis. You are encouraged to consult your own tax advisor as to our Company's status as a PFIC and the tax consequences to you of such status. A U.S. Holder will not be able to elect to treat us as a qualified electing fund ("QEF") because we do not intend to prepare the information needed to make a QEF election. See "Item 10. Additional Information - E. Taxation - U.S. Federal Income Taxation - Passive Foreign Investment Company Status."
Taxation & Government Incentives - Risk 4
Changed
The reduction, modification or elimination of central and state government incentives may reduce the economic benefits of our existing solar projects and our opportunities to develop or acquire suitable new renewable energy projects.
The development and profitability of renewable energy projects in the locations in which we operate are dependent on policy and regulatory frameworks that support such developments. Further, the Indian Income Tax Act, 1961 as amended, provides for certain tax benefits, including 100% tax deductions of the profits derived from generation of power for any 10 consecutive years, out of the first 15 years, beginning from the year in which project is completed. However, the exemption was only available to the projects completed on or before March 31, 2017. In addition, certain state policies also provide economic incentives like single window clearance system and setting up of solar parks. In addition, as per The Taxation Laws (Amendment) Act, 2019, the Government reduced corporate taxes for certain companies to 25%. However, any companies that benefit from the reduced tax rate are not able to avail themselves of any exemptions or incentives such as an 80IA exemption or additional depreciation. As per 80-IA exemption, projects which were completed on or before March 31, 2017, qualified for a tax holiday for a period of ten consecutive years out of 15 years beginning from the year in which the undertaking first generates power (referred to as the tax holiday period). For newly incorporated manufacturing companies incorporated after October 1, 2019, the rate had been reduced to 15%. Further, there is also a reduction in the Minimum Alternate Tax ("MAT"). However, income tax rules are subject to change and such benefits may not be available in the future.
The availability and size of such incentives depend, to a large extent, on political and policy developments relating to environmental concerns in India and are typically available only for a specified time. Generally, the amount of government incentives for solar projects has been decreasing as the cost of producing energy has dropped below grid parity. None of the projects we have won in the last three fiscal years have received direct incentives or subsidies other than ISTS waiver.
Changes in central and state policies could lead to a significant reduction in or a discontinuation of the support for renewable energy. Reductions in economic incentives that apply to future solar projects could diminish the availability of our opportunities to continue to develop or acquire suitable renewable energy projects. Such reductions may also apply to existing renewable energy projects, which could significantly reduce the economic benefits we receive from our existing solar projects. Moreover, some of the renewable energy program incentives expire or decline over time, are limited in total funding, require renewal from regulatory authorities or require us to meet certain investment or performance criteria. In addition, although various SERCs have specified Renewable Purchase Obligation (RPOs) for their distribution companies, the implementation of RPO schemes has not been uniform across Indian states.
Additionally, we may not continue to qualify for such incentives. We may choose to implement other renewable energy projects that are outside the scope of such incentives. Further, increased emphasis on reducing greenhouse gas emissions and the possibility of trading carbon dioxide emission quotas has led to extra duties being levied on sources of energy, primarily fossil fuels, which cause carbon dioxide pollution. The imposition of these duties has indirectly supported the expansion of power generated from renewable energy and, in turn, solar projects in general. If such direct and indirect government support for renewable energy were terminated or reduced, it would make producing electricity from renewable energy projects less competitive and may reduce demand for renewable energy projects.
A significant reduction in the scope or discontinuation of government incentive programs in our markets could have a material adverse effect on our business, financial condition, results of operations, cash flows and prospects.
Environmental / Social1 | 1.4%
Environmental / Social - Risk 1
Our long-term growth depends in part on the Indian government's continued commitment to solar and renewable energy.
In 2015 the Government of India (the "Government" or "GoI") set a target of 175 GW renewable energy capacity by 2022. However, actual capacity additions historically have been lower than the GoI's announced targeted capacity additions. According to the MNRE, the installed capacity as of March 31, 2021 was approximately 94 GW, which includes approximately 39 GW of solar capacity. In 2020, Prime Minister of India announced a target of 450 GWs for India's renewable energy capacity to be achieved by the year 2030. Any subsequent revision of targets by the GoI including a change in focus on other alternative sources for any reason (due to an economic slowdown resulting from the COVID-19 pandemic or other policy reasons), may have material impact on our long term growth and adversely affect our ability to achieve our long-term business objectives, targets and goals.
Production
Total Risks: 12/69 (17%)Below Sector Average
Manufacturing5 | 7.2%
Manufacturing - Risk 1
Any constraints in the availability of the electricity grid, including our inability to obtain access to transmission lines in a timely and cost-efficient manner could adversely affect our business, results of operations and cash flows.
Delivering power to our power purchasing customer is our responsibility. We generally rely on transmission lines and other transmission and distribution facilities that are owned and operated by transmission or distribution utilities. Where we do not have access to available transmission and distribution networks, we may engage contractors to build transmission lines and other related infrastructure. In such a case, we will be exposed to additional costs and risks associated with developing transmission lines and other related infrastructure, such as the ability to obtain right of way from land owners for the construction of our transmission lines, which may delay and increase the costs of our projects. We may not be able to secure access to the available transmission and distribution networks at reasonable prices, in a timely manner or at all.
In addition, India's physical infrastructure, including its electricity grid, is less developed than that of many developed countries. As a result of grid constraints, such as grid congestion and restrictions on transmission capacity of the grid, the transmission and dispatch of the full output of our projects may be curtailed. We may have to stop producing electricity during the period when electricity cannot be transmitted. Such events could reduce the net power generation of our projects. If construction of renewable energy projects outpaces transmission capacity of electricity grids, we may be dependent on the construction and upgrade of grid infrastructure by the transmission utilities. We cannot assure you that the relevant Transmission utilities will do so in a timely manner, or at all. The curtailment of our power projects' output levels will reduce our electricity output and limit operational efficiencies, which in turn could have an adverse effect on our business, results of operations and cash flows.
Manufacturing - Risk 2
Maintenance and expansion of power generation facilities involve significant risks that could result in reduced power generation and financial results.
Our facilities may require periodic upgrading and improvement. Any unexpected operational or mechanical failure, including failure associated with breakdowns and forced outages, and any decreased operational or management performance, could reduce our facilities' generating capacity below expected levels and reduce our revenues as a result of generating and selling less power. Degradation of the performance of our projects above levels provided for in the related PPAs may also reduce our revenues. Unanticipated capital expenditures associated with maintaining, upgrading or repairing our facilities may also reduce profitability, especially because our costs are fixed in the PPAs and we may not be able to pass through any unexpected costs in relation to the projects to our customers. Furthermore, we are not able to mitigate such project risks by shifting some or all of the risk to a third-party EPC or O&M contractor since we provide most of these services in-house. A global crisis such as the recent COVID-19 pandemic has caused the lock downs ordered by the Ministry of Home Affairs, which had impacted the free movement of goods and services. This had impacted some of our O&M activities, and adversely affected our revenues. For example, in case of our rooftop business, we were unable to get the access of various sites and in several cases, we faced delays in getting approval for site access. Due to this, our maintenance and power generation facilities were negatively which resulted in reduced power generation and adverse impact on financial results. This impact we may not be able to recover through insurance. If the situation worsens there could be a further adverse impact on our revenues.
Changes in technology may require us to make additional capital expenditures to upgrade our facilities. The development and implementation of such technology entails technical and business risks and significant costs of employee implementation.
Manufacturing - Risk 3
Changed
Construction and operation of power generation facilities involves significant environmental risks and hazards that could be materially adverse to our business, financial condition, results of operations and cash flows. We may not have adequate insurance to cover these risks and hazards.
Construction and generation of power from solar power generation facilities and plants involves the use of large tracts of land. Although the Company undertakes to comply with all applicable laws including environmental laws, construction and generation of solar power risks contamination of, or damage to the environment. In addition, power generation involves hazardous activities, including delivering electricity to transmission and distribution systems. Natural risks such as earthquake, flood, lightning, hurricane and wind, other hazards, such as fire, structural collapse and machinery failure are inherent risks in our operations. These and other hazards can cause significant personal injury or loss of life, severe damage to and destruction of property, plant and equipment and contamination of, or damage to, the environment and suspension of operations. The occurrence of any one of these events may result in our being named as a defendant in lawsuits asserting claims for substantial damages, including for environmental cleanup costs, personal injury and property damage and fines and/or penalties. We maintain an amount of insurance protection that we consider adequate, but we cannot provide any assurance that our insurance will be sufficient or effective under all circumstances and against all hazards or liabilities to which we may be subject. Furthermore, our insurance coverage is subject to deductibles, caps, exclusions and other limitations. A loss for which we are not fully insured could be materially adverse to our business, financial condition, results of operations or cash flows. Further, due to rising insurance costs and changes in the insurance markets, we cannot provide any assurance that our insurance coverage will continue to be available at all or at rates or on terms similar to those presently available. Any losses not covered by insurance could have a material adverse effect on our business, financial condition, results of operations and cash flows.
Manufacturing - Risk 4
Changed
We may not be able to find suitable sites for the development of renewable energy projects.
Renewable energy projects require resource availability (for example wind resource for wind projects and solar insolation for solar projects) that is not uniformly available in all areas. Further, large utility scale renewable projects must be interconnected to the power grid to deliver electricity, which requires us to find suitable sites with capacity on the power grid available. We may encounter difficulties registering certain leasehold/sale interest in such sites. Even when we have identified a desirable site for a project, our ability to obtain site control with respect to the site is subject to growing competition from other renewable power producers that may have better access to local government support or financial support or other resources. If we are unable to find or obtain site control for suitable sites on commercially acceptable terms, our ability to develop new projects on a timely basis or at all might be harmed, which could have a material adverse effect on our business, financial condition, and results of operations. Moreover, our land leases for projects are typically for 30 to 35 years, but our PPAs are generally for a term of 25 years. If we are not able to sell the power produced by our systems after the initial PPA has expired, it may impact our future cash flows.
Manufacturing - Risk 5
Imposition of anti-dumping, safeguard duties or basic custom duties on solar equipment imports may increase our costs and adversely impact our margins.
The Ministry of Finance of the Indian government imposed a 25% safeguard duty on import of solar panels from July 30, 2018 to July 29, 2019, which has been gradually lowered to 14.5% up to July 29, 2021 and nil after July 29, 2021. While certain solar power producers approached the High Court of Orissa and obtained an interim stay in July 2018, the Supreme Court of India overturned the stay order on September 11, 2018. Although the issue on the validity of the imposition of this safeguard duty is pending in Supreme Court of India, the safeguard duty continues to be in effect. The Ministry of Commerce and Industry issued a notification dated March 3, 2020, whereby the Director General, initiated a review investigation, for examining the need for continued imposition of safeguard duty on solar cells whether or not assembled in modules or panels. Further, vide notification dated July 29, 2020, the designated authority in its final findings has recommended continued imposition of the safeguard duty on imports of the subject goods, in order to remove injury to the domestic industry.
The Finance Act, 2020, enacted by the parliament of India, implemented a Basic Custom Duty on imports of solar cells and modules as a replacement for the safeguard duty. The Finance Act, 2020, levied a tax of 20% on the import of Solar Modules, which had been exempted for Solar Modules through till March 31, 2021. The MNRE post approval from Ministry of Finance, through its notification dated March 9, 2021, extended the exemption for Basic Custom Duty on solar cells and modules further up to March 31, 2022. Effective April 1, 2022, the Basic Custom Duty shall be levied on import of solar modules at the rate 40% and on solar cells at the rate of 25%. Further, the MNRE vide its notification, dated February 25, 2021, discontinued the benefit of concessional custom duty in respect of items imported for initial setting up of solar power projects with effect from February 2, 2021. Our PPAs typically contain change-in-law provisions which permit us to pass on such increases to our offtakers with an upward revision of tariff by obtaining an order to this effect from the relevant electricity regulatory commissions. We are in process of filing change-in-law petitions before relevant electricity regulatory commissions. However, we cannot assure you that the offtaker/ electricity regulatory commissions will revise relevant tariffs or allow lump sum payment along with late payment surcharge, sufficiently to cover our increased expenses from the tariffs. To the extent we are unable to pass on the impact of the imposition of safeguard duty to our offtakers in part or in whole under any of our PPAs, our increased costs of purchase of solar panels could adversely affect our operating results, cash flows and financial condition.
Further, with the objective of building energy security for the country and ensuring reliability of Solar PV Cells and Modules, the MNRE had issued Order dated January 2, 2020, regarding an approved list of Models & Manufacturers (ALMM) for Solar PV cells & modules, providing for enlistment of models and manufacturers of solar PV cells and modules, complying with the BIS Standards. The ALMM Order stipulates that after effective date, all Solar PV Power Projects which are Government owned/Government assisted/bid out as per Central Govt's Standard Bidding Guidelines, shall mandatorily procurer solar PV cells and modules for such projects from the manufacturers approved and included in the ALMM Lists after effective date. Considering the recommendations of a committee constituted to review the implementation of ALMM order and inspections reports submitted by National Institute of Solar Energy (NISE), the Minister for Power and New & Renewable Energy (NRE) has approved the ALMM list for Solar PV Modules and Manufacturers for Solar PV Modules. Accordingly, ALMM order in respect of Listed Modules shall be applicable on all such bids whose last date of bid submission is on or after April 10, 2021. Since most of our purchases are made from import vendors and because several of our existing module manufacturers may not be empaneled under ALMM, we may not be able to procure modules from foreign vendors for new project. Considering the same, we may not be able to procure modules of desired quality from Indian suppliers at competitive prices. This may have a consequential impact on increase in project cost and higher tariffs, which may reduce attractiveness of solar power.
Employment / Personnel4 | 5.8%
Employment / Personnel - Risk 1
Any damages caused by fraud or other misconduct by our employees could adversely affect our business, results of operations and financial condition.
We are exposed to operational risk arising from inadequacy or failure of internal processes or systems. In addition, we are exposed from risk associated with fraud or misconduct of our employees. In the past five fiscal years we have not experienced any fraud or misconduct by employees which has materially affected our business, results of operations or financial condition. However, we may not be safeguarded against all fraud or misconduct by employees or outsiders, unauthorized transactions by employees and operational errors. Employee or executive misconduct could also involve the improper use or disclosure of confidential information, data breach or other illegal acts, which could result in regulatory sanctions and reputational or financial harm, including harm to our brand. Our management information systems and internal control procedures are designed to monitor our operations and overall compliance. However, they may not be able to identify non-compliance and/or suspicious transactions in a timely manner or at all. In addition, certain internal control processes are carried out manually, which may increase the risk that human error, tampering or manipulation will result in losses that may be difficult to detect. For example, the Company has recently received complaints and several anonymous whistleblower reports, which made various claims against certain of the Company's Key Managerial Personnel, related to their and the Company's actions in relation to the acquisition of and use of land in Rajasthan, Assam, and Uttar Pradesh, as well as certain other corporate actions. The Company, through its Audit Committee, and with the assistance of external counsel and forensic auditors, has undertaken an investigation to determine whether the allegations made in the complaints or contained in the whistleblower reports are substantive. The investigation did not substantiate the allegations made in the complaints or contained in the whistleblower reports. Nevertheless, the Company has determined that a review of certain of its processes is required to ensure continued compliance with its internal policies and procedures.
Were our employees, including Key Managerial Personnel, to commit fraud or other misconduct, we may suffer monetary losses, including contractual liabilities and penalties, which may not be covered by our insurance and may thereby adversely affect our business, results of operations and financial condition.
Employment / Personnel - Risk 2
Rising employee costs may harm our business and increase our operation costs.
As of March 31, 2021, we employed 471 persons to perform a variety of functions in our daily operations. Failure to obtain stable and dedicated employee support may cause disruption to our business that harms our operations. Furthermore, employee costs have increased in India in recent years and may continue to increase in the near future. To remain competitive, we may need to increase the salaries of our employees to attract and retain them. Our employee payroll and related costs (excluding SAR expense) amounted to INR 871 million, INR 864 million and INR 652 million (US$ 8.9 million) for the years ended March 31, 2019, 2020 and 2021, respectively. The SAR expense for the years ended March 31, 2020 and 2021 was 170 million and INR 1,319 million (US$ 18.0 million). Any abnormal increase in employee costs may harm our operating results, cash flows and financial condition. During fiscal 2021, there has been significant fluctuations to the trading price of our Company's shares which impacted our Stock Appreciation Rights (SARs) expense. Any significant volatility in share price of our Company in future years may have impact on SARs expense, which could have an adverse impact on our financial condition, results of operations, and cash flows.
The COVID-19 pandemic and associated lockdowns and stay-at-home orders may impact the availability of skilled labor at a reasonable cost, as there have been mass movements of labor during the period. For a full discussion of the risks to our business associated with the COVID-19 pandemic, see "Risks to our Business related to the COVID-19 pandemic".
Employment / Personnel - Risk 3
Stringent labor laws may harm our ability to have flexible human resource policies and labor union problems could negatively affect our processing capacity, construction schedules, cash flows and overall profitability.
India has stringent labor legislation that protects the interests of workers, including legislation that sets forth detailed procedures for dispute resolution and employee removal, imposes financial obligations on employers upon employee layoffs and regulates contract labor. These laws may restrict our ability to have human resource policies that would allow us to react swiftly to the needs of our business, discharge employees or downsize. We may also experience labor unrest in the future, which may delay our construction schedules or disrupt our operations. If such delays or disruptions occur or continue for a prolonged period of time, our processing capacity and overall profitability could be negatively affected. We also depend on third party contract labor. It is possible under Indian law that we may be held responsible for wage payments to these laborers if their contractors' default on payment. We may be held liable for any non-payment by contractors and any such order or direction from a court or any other regulatory authority may harm our business, results of our operations and cash flows.
Further during the current year, the Social Security Code, 2020 ("SS Code") has been passed by the Parliament of India and also received Presidential assent on September 28, 2020. The SS Code has been enacted to amend and consolidate the laws relating to social security with the goal of extending social security to all employees and workers. However, due to second wave of COVID-19 pandemic, implementation of these labour reforms has been delayed and now are expected to be implemented in fiscal 2022. We are awaiting the issuance of final guidelines by central and state governments on the new SS code, we are under process of evaluating related impacts of these codes.
Employment / Personnel - Risk 4
Our ability to implement our strategy and our future success depend significantly on the continued service of our senior management team and our ability to attract, train and retain qualified personnel.
Our future success depends on the continued services and performances of the members of our management in our business for project implementations, management and running of our daily operations and the planning and execution of our business strategy. We depend on our experienced management team, and the loss of one or more key executives could have a negative impact on our business. We also depend on our ability to retain and motivate key employees and attract qualified new employees. Other than our Chief Executive Officer ("CEO") and Chief Operating Officer ("COO"), none of our executive officers nor our key employees are bound by employment agreements for any specific term, and we may be unable to replace key members of our management team and key employees in the event we lose their services. There is intense competition for experienced management personnel with technical and industry expertise in the renewable energy business and if we lose the services of any of these individuals and are unable to find suitable replacements in a timely manner, our ability to realize our strategic objectives could be impaired. Integrating new employees into our management team could prove disruptive to our operations, require substantial resources and management attention and ultimately prove unsuccessful. An inability to attract and retain sufficient managerial personnel who have critical industry experience and relationships could limit or delay our strategic efforts, which could have a material adverse effect on our business, financial condition, results of operations and cash flows.
Supply Chain1 | 1.4%
Supply Chain - Risk 1
Changed
We may incur unexpected cost overruns and expenses if the suppliers of components in our solar projects default in their warranty obligations or delay in the delivery of products and services for any reason.
We enter into contracts with our suppliers to supply components in our solar projects. If our suppliers do not perform their obligations, we may have to enter into new contracts with other suppliers at a higher cost or may suffer schedule disruptions. In addition, our suppliers may have difficulty fulfilling our orders and incur delivery delays, or charge us higher prices, higher up-front payments and deposits, which would result in higher-than-expected prices or less favorable payment terms to develop our projects. Delays in the delivery of ordered components in our solar projects could delay the completion of our under-construction projects. In addition, our relationship with our suppliers may worsen or lead to disagreements or litigation which could have a material adverse effect on our business, financial condition, results of operations and cash flows.
Fluctuations in prices of material and the inability to secure the on-time delivery of components and raw materials could have a material adverse effect on our business, financial condition, results of operations and cash flows. In fiscal 2021, we faced several challenges in receipt of material from its suppliers relating to the Rajasthan-6 and Assam projects. In a high demand environment, certain suppliers refused to provide material at the prices agreed under the terms of our agreements and asked for price increases. We have agreed to certain price increases in this regard, but, if the prices continue to climb, returns on our projects could be impacted and our business, financial condition, results of operations, cash flows could be adversely affected.
In addition, COVID-19 and related lockdowns has and continue to impact our supply of components and raw materials for our projects. See "COVID-19 and related lockdowns have subjected and may continue to subject our construction activities to delays and cost overruns as well as component shortages and supply delays from suppliers" and "Risks to our Business related to the COVID-19 pandemic" above.
Furthermore, the solar panels, inverters and other system components utilized in our solar projects are generally covered by manufacturers' warranties, which are typically for 5 to 25 years. In the event any such components fail to operate as required, we may be able to make a claim against the applicable warranty to cover all or a portion of the expense or losses associated with the faulty component. However, the warranties may not be sufficient to cover all of our expense and losses. In addition, these suppliers could cease operations and no longer honor the warranties, which would leave us to cover the expense and losses associated with the faulty component. Our business, financial condition, results of operations and cash flows could be materially and adversely affected if we cannot recover the expense and losses associated with the faulty component from these warranty providers.
Further during the year, we also received notices related to the non-execution of contracts, however, no legal proceedings have been commenced against us. Our business, financial condition, results of operations and cash flows could be materially and adversely affected in case such claim is settled against the Company.
Costs2 | 2.9%
Costs - Risk 1
Added
Our construction activities may be subject to cost overruns or delays which may adversely affect our business, financial condition, results of operations and cash flows.
Construction of our solar and other renewable energy projects may be adversely affected by circumstances outside of our control, including inclement weather, adverse geological and environmental conditions, failure to receive regulatory approvals on schedule or third-party delays in providing supplies and other materials. Changes in project plans or designs, or defective or late execution may increase our costs from our initial estimates and cause delays. Increases in the prices of our materials may increase procurement costs. In particular, we have not yet placed orders for all equipment required to construct and operate all of our power projects that are presently Contracted and under construction. There can be no assurance that the prices of the equipment required for our power projects that are presently Contracted and under construction will not change, which may cause the economic returns available from these projects to differ from our initial projections. For example, during last two quarters of current year, there had been increase in price of components mainly due to a shortage of raw material such as poly silicon, glass and ethylene-vinyl acetate (EVA). Also, we faced several challenges in receipt of raw material from its suppliers mainly in respect of our Rajasthan 6 and Assam projects, where our suppliers refused to provide raw materials at the prices agreed under the terms of our agreements with these suppliers. Any further, fluctuations in prices of raw material could have a material adverse effect on our business, financial condition, results of operations and cash flows. If we experience unexpected increases in procurement costs, our forecasted revenues and cash flows could be materially adversely affected.
Labor shortages, work stoppages, labor disputes or disruptions in transportation bringing in labor for projects could also significantly delay a project, increase our costs or cause us to breach our performance guarantees under our PPAs, particularly because strikes and labor transportation disruptions are not considered a force majeure event under many of our PPAs. Moreover, local political changes and delays, for instance, caused by state and local elections, as well as demonstrations or protests by local communities and special interest groups could result in, or contribute to, project time and cost overruns for us.
In addition, we sometimes utilize and rely on third-party sub-contractors to construct and install portions of our renewable energy projects. If our sub-contractors do not satisfy their obligations or do not perform work that meets our quality standards or if there is a shortage of third-party sub-contractors or if there are labor strikes that interfere with the ability of our employees or contractors to complete their work on time or within budget, we could experience significant delays or cost overruns.
We may not be able to recover any of these losses in connection with construction cost overruns or delays. Certain PPAs require that we connect to the transmission grid by a certain date. If a project is significantly delayed, such PPAs may be terminated or require us to pay liquidated damages computed based on number of days of delay in commissioning of the projects or reduction in the PPA tariff. In addition, if we are unable to meet our performance guarantees, most of our PPAs require us to pay liquidated damages to the offtaker in proportion to the amount of power not supplied, and also grant the offtaker a right to draw on bank guarantees posted by us, including up to 100% of certain bank guarantees. Also, certain PPAs provide that we are liable for government fines and penalties if we fail to deliver electricity required by the offtakers to meet their RPO requirements. Furthermore, in the case of projects with viability gap funding ("VGF"), 50% of which is paid out in the first year with the remaining 50% paid out over the course of next five years, if the project fails to generate power for a long period of time, the government agency can suspend the VGF and demand repayment of previously paid sums. During fiscal 2021, we faced various operational challenges in respect of our rooftop projects like delays in site clearances resulting in further delays in construction of projects, including short closure of projects, lower PLF reported on projects, higher maintenance cost and lower operational efficiencies in comparison to the size of the rooftop sites. Also, in some cases relating to rooftop projects, our customers forfeited VGF entitlements as we were not able to meet the conditions. Further, there can be no assurance that we will be able to perform at a level that we are able to claim VGF in the future for our projects, as there have been instances in the past wherein we have been unable to claim the benefit on certain projects.
Any of the contingencies discussed above could lead us to fail to generate our expected return from our solar and other renewable energy projects and result in unanticipated and significant revenue and earnings losses.
Costs - Risk 2
Changed
A certain portion of the land on which our renewable energy projects are or will be located, are not owned by us. In the event we are unable to purchase the land, or enter into or renew lease agreements, our business, results of operations, cash flows and financial condition could be adversely affected.
Some of our solar projects are located, or will be located, on land that is owned by the state governments or on land acquired/leased or to be acquired/leased from private parties. The timeline for transfer of title in the land is dependent on the type of land on which the power projects are, or will be, located, and the policies of the relevant state government in which such land is located.
We cannot assure you that the outstanding approvals would be received, or that lease or sub-lease deeds would be executed in a timely manner, such that the operation of our solar projects will continue unaffected. Further, the terms of lease and sub-lease agreements may also not be co-terminus with the lifetime of the power projects, taken together with the period of time required for construction and commissioning of the project. Accordingly, we will have to obtain extensions of the terms of such leases and sub-leases for the remainder of the terms of the corresponding PPAs. In the event, that the relevant state authorities/ private parties do not wish to renew the lease or sub-lease agreements, we may be forced to remove our equipment at the end of the lease, and we may not be able to find an alternative location in the short term or at all. Any of the foregoing factors could lead to a material adverse effect on our business, results of operations, cash flows and financial condition.
Macro & Political
Total Risks: 9/69 (13%)Above Sector Average
Economy & Political Environment3 | 4.3%
Economy & Political Environment - Risk 1
A slowdown in economic growth in India could cause our business to suffer.
Since inception, all of our revenue has been derived directly from sales in India. The performance and growth of our business are necessarily dependent on economic conditions prevalent in India, which may be significantly harmed by political instability or regional conflicts, a general rise in interest rates, inflation and economic slowdown including due to COVID-19 elsewhere in the world or otherwise. The Indian economy also remains largely driven by the performance of the agriculture sector which depends on the quality of monsoon, which is difficult to predict. Although the Indian economy has continued to grow in the past few years, any future slowdown in the Indian economy or a further increase in inflation could have a material adverse effect on the demand for power and, as a result, on our financial condition, results of operations and cash flows.
India's trade relationships with other countries and its trade deficit may significantly harm Indian economic conditions. If trade deficits increase or are no longer manageable, the Indian economy, and therefore our business and our financial performance could be significantly harmed.
India also faces major challenges in sustaining its growth, which include the need for substantial infrastructure development and improving access to healthcare and education. If India's economic growth cannot be sustained or otherwise slows down significantly, our business and prospects could be significantly harmed.
Economy & Political Environment - Risk 2
Natural calamities could have a negative impact on the Indian economy and adversely affect our business and project operations.
India experienced natural calamities such as earthquakes, tsunamis, floods and drought in the past few years. In May 2020, massive forest fires broke out in Srinagar of Pauri Garhwal district in Uttarakhand, India and during August 2020, heavy rainfalls in the monsoon season caused severe floods that affected several areas in Kerala, India. The extent and severity of these natural disasters determines their impact on the Indian economy. If climatic conditions or natural disasters occur in areas where our projects and project teams are located, project development, connectivity to the power grid and the provision of O&M services may be adversely affected. In particular, materials may not be delivered as scheduled and labor may not be available. Substantially all of our operations and employees are located in India and there can be no assurance that we will not be adversely affected by natural disasters in the future. Furthermore, the COVID-19 pandemic has significantly impaired the Indian and world economy. For a full discussion of the risks to our business associated with the COVID-19 pandemic, see "Risks to our Business related to the COVID-19 pandemic".
Economy & Political Environment - Risk 3
The global economy may be adversely affected by economic developments and major events in some markets.
The global financial and securities markets, and also the global economy, are influenced by economic and market conditions in some markets worldwide. The global economy may be influenced by shocks from some markets. Although economic conditions vary from country to country, investors' reactions to events occurring in one country sometimes demonstrate a "contagion" effect in which an entire region or class of investment is avoided by international investors. Consequently, there can be no assurance that the global and India's financial system and securities markets will not continue to be adversely affected by events in developed countries' economies or events in other emerging markets, which could in turn, adversely affect the global and India's economy and, indirectly, our business, financial condition and results of operations, and the market value of our equity shares. Furthermore, global events like the COVID-19 pandemic can materially impact the global economic conditions and reduce the flow of funds through equity or debt in India. For a full discussion of the risks to our business associated with the COVID-19 pandemic, see "Risks to our Business related to the COVID-19 pandemic".
Natural and Human Disruptions4 | 5.8%
Natural and Human Disruptions - Risk 1
War, terrorist acts and other acts of violence involving India or other neighboring countries could significantly harm our operations directly or may result in a more general loss of customer confidence and reduced investment in these countries that causes significant harm to our business, results of operations, cash flows and financial condition.
Terrorist attacks and other acts of violence or war involving India or other neighbouring countries may significantly harm the Indian markets and the worldwide financial markets. The occurrence of any of these events may result in a loss of business confidence, which could potentially lead to economic recession and generally cause significant harm to our business, results of operations, cash flows and financial condition. In addition, any deterioration in international relations may result in investor concern regarding regional stability, which could decrease the price of our equity shares.
South Asia has also experienced instances of civil unrest and hostilities among neighbouring countries from time to time. There have also been incidents in and near India such as terrorist attacks in Kashmir, troop mobilizations along the Pakistan and Chinese borders and an aggravated geopolitical situation in the region. Such military activity or terrorist attacks in the future could significantly harm the Indian economy by disrupting communications and making travel more difficult. Resulting political tensions could create a greater perception that investments in Indian companies involve a high degree of risk. Furthermore, if India were to become engaged in armed hostilities, particularly hostilities that were protracted or involved the threat or use of nuclear weapons, we might not be able to continue our operations. Our insurance policies for a certain part of our business do not cover terrorist attacks or business interruptions from terrorist attacks or for other reasons.
Natural and Human Disruptions - Risk 2
Changed
The generation of electricity from solar and wind sources depends on suitable meteorological conditions. If weather conditions are unfavorable, our electricity generation, and therefore revenue from our renewable energy projects, may be below our expectations.
The electricity produced and revenues generated by our renewable energy projects are highly dependent on suitable solar and wind conditions and associated weather conditions and air pollution, which are beyond our control. Furthermore, components of our systems, such as solar panels and inverters, could be damaged by severe weather, such as dust-storms, tornadoes or lightning strikes. We generally will be obligated to bear the expense of repairing the damaged solar energy systems that we own, and replacement and spare parts for key components may be difficult or costly to acquire or may be unavailable. Unfavorable weather, high levels of air pollution and atmospheric conditions could impair the effectiveness of our assets or reduce their output beneath their rated capacity or require shutdown of key equipment, impeding operation of our solar assets and our ability to achieve certain performance guarantees pursuant to our PPAs, forecasted revenues and cash flows. Sustained unfavorable weather could also unexpectedly delay the installation of renewable energy systems, which could result in a delay in us acquiring new projects or increase the cost of such projects. We guarantee the performance of our solar power plants and could suffer monetary consequences if our plants do not produce to our contracted levels. Generally, our plants are in remote locations, that are far from densely populated and polluted areas; however, such areas may be subject to pollution from sources for which we may not have the visibility at the time of setting up of plants.
We base our investment decisions with respect to each solar project on the findings of related solar studies conducted on-site prior to construction. However, actual climatic conditions at a project site may not conform to the findings of these studies and therefore, our facilities may not meet anticipated production levels or the rated capacity of our generation assets, which could adversely affect our business, financial condition, results of operations and cash flows.
Natural and Human Disruptions - Risk 3
Changed
COVID-19 and related lockdowns have subjected and may continue to subject our construction activities to delays and cost overruns as well as component shortages and supply delays from suppliers.
Our contracts with our suppliers and contractors all contain provisions for force majeure. Due to the impact of COVID -19 related lockdowns in India and other parts of the world some of our suppliers have issued force majeure notices to us requesting a suitable time extension for delivery. In case the situation continues for a long period of time we may have to terminate these contracts.
The commissioning of our 65 MW projects in Assam faced delays due to force majeure reasons due to the COVID-19 and lockdowns in fiscal 2021, for which we had filed extension petitions in the regulatory commission, which was not admitted. We have filed an appeal against the said order before APTEL, disposal of which is pending. We believe in the merits of the case, however, we cannot provide assurances, that such proceedings will ultimately be decided in our favor. For a full discussion of the risks to our business associated with the COVID-19 pandemic, see "Risks to our Business related to the COVID-19 pandemic".
During fiscal 2021, vide notification dated June 30, 2020, the MNRE directed all Renewable Energy (RE) implementing agencies of the MNRE to treat the lockdown due to COVID-19, as force majeure, and provided that these agencies may grant extensions of time for RE projects equivalent to the period of lockdown and additional 30 (thirty) days for normalization after end of such lockdown. Further, as per notification dated August 13, 2020, the MNRE conveyed that all RE projects under implementation as on the date of lockdown, i.e. 25th March 2020, through RE implementing agencies designated by the MNRE or under various schemes of the MNRE, shall be given a time extension of five months from March 25, 2020 to August 24, 2020. This blanket extension, if invoked by the RE developers, will be given without case-to-case examination and no documents or evidence will be asked for such extension. The developers of the projects may also pass on the benefit of such time-extension by way of granting similar time-extensions to other stakeholders down the value chain like engineering procurement construction (EPC) contractors, material equipment suppliers and original equipment manufacturers (OEMs). Further MNRE through its subsequent clarifications dated February 9, 2021 and March 30, 2021 communicated that further time-extension beyond 5 months can be granted by implementing agencies in exceptional cases. However, for any time-extension totaling beyond 6 months, a reference shall be made to MNRE.
Subsequent to year end, amid outbreak of second wave of COVID-19, MNRE vide their notification dated May 12, 2021, clarified that RE projects having their Scheduled Commissioning date (SCOD) on or after 1st April 2021 will be eligible to claim time-extension for completion of their project activities, provided such time-extensions are not used as a ground for claiming termination of Power Purchase Agreement (PPA) or for claiming any increase in the project cost. The actual quantum of time-extension shall be decided in due course depending on the COVID-19 related developments that take place in the coming future. However, implementing agency/ off taker shall not initiate any coercive action on the project for recovery of penalty on delayed commissioning, till the time-extension request is decided upon. We are uncertain what additional extensions will be allowed by the MNRE in light of the second wave and related state lockdowns. If MNRE, does not provide support to the RE developers in providing extension, our business, results of operations, could be adversely affected in the form of penalties for delays and other costs.
Natural and Human Disruptions - Risk 4
The COVID-19 pandemic's adverse impacts on our business, financial position, results of operations, and prospects could be significant.
The COVID-19 pandemic has created disruptions to the global economy and to the lives of individuals throughout the world. Governments, businesses, and the public have taken unprecedented actions to contain the spread of COVID-19 and to mitigate its effects, including quarantines, travel bans, shelter-in-place orders, closures of businesses and schools, fiscal stimulus, and other regulatory changes. The Government of India imposed a nationwide lockdown in India on March 25, 2020 which continued until May 31, 2020, while gradually relaxing restriction during the period. Due to this lockdown, construction work on our solar projects stopped for several weeks, which resulted in some impact to our construction timelines. A second wave of COVID-19 infections have severely impacted India in April, May and June 2021. This second wave in India has seen new peaks in daily cases, daily deaths, active cases and positivity rates. The second wave has resulted in significant strain on the health infrastructure in the country resulting in several states announcing lockdown measures. Due to this second wave of infection in India, several state governments including Maharashtra, Rajasthan and the National Capital Region announced partial lockdowns during the months of April, May and June 2021. These lock downs and the COVID-19 pandemic have impacted and continue to impact construction work on our projects and the availability of labor, components and material. Even after the lockdowns are lifted or eased, we may continue to experience disruption in our construction activities and supply of components and materials till the supply chains are fully restored. Several of our employees have also been infected with the COVID-19 virus over in Fiscal 2021 and in Fiscal 2022 during the first and second wave. Accordingly, we have and may continue to lose key management and employee hours due to COVID-19 related illness and related issues.
Governments and organizations have broadly revised Gross Domestic Product ("GDP") growth forecasts downward in response to the economic slowdown caused by the spread of COVID-19 and it is possible that the COVID-19 outbreak may cause a prolonged economic crisis or recession. While the scope, duration and full effects of the second wave of COVID-19 are rapidly evolving and not fully known, the pandemic and related efforts to contain it have disrupted global and domestic economic activity, adversely affected the functioning of financial markets, impacted interest rates, increased economic and market uncertainty, and disrupted trade and supply chains. While these impacts continue, they will result in sustained economic stress or recession in India and many of the risk factors identified in this Risk Factors section of our annual report could be exacerbated and such effects could have a material adverse impact on us in a number of ways related to liquidity, operations, customer demand, interest rate risk, and human capital, as described in more detail below.
- Liquidity risk: Our success may be affected by a variety of external factors that may affect the price or marketability of our products and services, including disruptions in the capital markets, changes in interest rates that may increase our funding costs, reduced demand for our solar products due to economic conditions and the various response of governmental and nongovernmental authorities. The COVID-19 pandemic has significantly increased economic and demand uncertainty and has led to disruption and volatility in the global and domestic capital markets, which could increase the cost of capital and adversely impact access to capital. A period of extremely volatile and unstable market conditions would likely increase our funding costs and negatively affect market risk mitigation strategies. Furthermore, the volatility in global and domestic capital markets may cause increased volatility in currency exchange rates reducing our ability, or increase the costs, to mitigate these risks. Any depreciation of the Indian rupee could result in higher hedging cost and increased costs of imports for us. In addition, foreign exchange hedges on our restricted groups have a cap and heightened volatility in foreign exchange rates may result in additional payments.
- Strategic risk: As a result of the business shutdown and facilities closures, the global and domestic economy has significantly slowed down, resulting in reduced electricity demand in India and globally. Customer demand for electricity may not swiftly recover to pre-COVID-19 level or at all, due to the potential of a prolonged global or domestic economic crisis or recession. Economic downturns may alter the priorities of governments (including the Government of India) to subsidize and/or incentivize participation in markets in which we operate. The global economic crisis may also prompt the Indian government to enact emergency measures such as electricity tariff adjustments to ease the financial burden on economically disadvantaged customers, each of which could have an adverse impact on our financial conditions, results of operations, and cash flows.
- Operational risk: Current and future restrictions on our workforce's access to any of our facilities and the health and availability of our workforce in constructing our solar projects could limit our ability to meet customer expectations and have a material adverse effect on our operations. We may experience increased difficulties in receiving payments from our distribution customers. These customers may not have adequate liquidity or may have greater difficulties in settling their electricity bills. Further, in response to COVID-19, our employees are working remotely from their homes but technology in employees' homes may not be as robust as in our offices and could cause the networks, information systems, applications, and other tools available to employees to be more limited or less reliable than in our offices. The continuation of work-from-home measures introduces additional operational risk, especially cybersecurity risk. These cyber risks include greater phishing, malware, and other cybersecurity attacks, vulnerability to disruptions of our information technology infrastructure and telecommunications systems for remote operations, increased risk of unauthorized dissemination of confidential information, limited ability to restore systems in the event of a systems failure or interruption, and a greater risk of a security breach resulting in destruction or misuse of valuable information.
Due to inadequate medical infrastructure in India, our employees may be at risk of not being able to access healthcare to treat COVID. Several of our employees have also been infected with the COVID-19 virus over in Fiscal 2021 and in Fiscal 2022 during the second wave.
Moreover, we rely on many suppliers and contractors. During the current year, we have faced several challenges and continue to face challenges currently to obtain materials from our suppliers and materials we do obtain often are at higher prices than in the past year. Certain suppliers have refused to provide material at the prices agreed under the terms of our supply agreements with them and have asked for price increases. Any further, fluctuations in prices of material could have a material adverse effect on our business, financial condition, results of operations and cash flows. We also rely on local and federal government agencies, offices, and other third parties in obtaining permits, conducting construction of our projects and transporting our solar products. In light of responses to the pandemic, these entities may limit the availability and access of their services. For example, we rely on frequent facility maintenance and improvement through operation and maintenance ("O&M") activities to maintain efficient operation of our facilities. The COVID-19 pandemic could potentially limit our O&M activities due to labor shortages, materials, and limited availability of third-party service providers, resulting in an adverse impact on our revenues which may not be covered through insurance, as COVID-19 related risks are not covered under several of our existing insurance policies. If suppliers and third-party service providers continue to have limited capacities for a prolonged period or if additional limitations or potential disruptions in these services materialize, it may negatively affect our operations. Further, we may have disputes with suppliers, contractors or customers that could lead to litigation or arbitration due to contractual force majeure notices.
- Delay in legal matters: The extension of the nationwide lockdown due to COVID-19 or other localised lockdowns/disruptions pandemic have delayed important legal hearings relating to legal proceedings to which we are a party. The commissions and courts during such period have only been hearing matters of urgent nature. If courts and commissions continue to have limited hearings for a prolonged period, it may lead to delay in finalization of our legal cases and may have negative impact on our operations.
Because there have been no comparable recent global pandemics that resulted in a similar global impact, we do not yet know the full extent of COVID-19's effects on our business, operations, or the global economy as a whole. The extent to which the COVID-19 outbreak impacts our business, results of operations and financial condition will depend on future developments, including the timeliness and effectiveness of actions taken or not taken to contain and mitigate the effects of COVID-19 both in India and internationally by governments, central banks, healthcare providers, health system participants, other businesses, and individuals, which are highly uncertain and cannot be predicted. The uncertain future development of this crisis could materially and adversely affect our business, operations, operating results, financial condition, liquidity or capital levels.
Capital Markets2 | 2.9%
Capital Markets - Risk 1
A decline in India's foreign exchange reserves may adversely affect liquidity and interest rates in the Indian economy.
According to the weekly statistical supplement of the Reserve Bank of India Bulletin, India's foreign exchange reserves totalled US$ 579.3 billion as of March 26, 2021. A sharp decline in these reserves could result in reduced liquidity and higher interest rates in the Indian economy. Reduced liquidity or an increase in interest rates in the economy following a decline in foreign exchange reserves could have a material adverse effect on our financial performance and ability to obtain financing to fund our growth on favorable terms or at all.
Capital Markets - Risk 2
Fluctuations in foreign currency exchange rates may negatively affect our revenue, cost of sales and gross margins and could result in exchange losses.
As the functional currency of our Indian subsidiaries is the Indian rupee, our operating expenses are denominated primarily in Indian rupees. However, some of our capital expenditures, and particularly those for equipment imported from international suppliers, such as solar panels, are denominated in foreign currencies. To the extent that we are unable to match revenue received in our functional currency with costs paid in foreign currencies, exchange rate fluctuations in any such currency could have an adverse effect on our profitability. Substantially all of our cash flows are generated in Indian rupees and, therefore, significant changes in the value of the Indian rupee relative to the other foreign currencies could have a material adverse effect on our financial condition and our ability to meet interest and principal payments on debts. In addition to currency translation risks, we incur currency transaction risks whenever we or one of our projects enter into a purchase or sales transaction using a currency other than the Indian rupee. We expect our future capital expenditures in connection with our proposed expansion plans to include significant expenditures in foreign currencies for imported equipment and machinery.
A significant fluctuation in the Indian rupee to U.S. dollar or other foreign currency exchange rates therefore could have a significant impact on our results of operations. The exchange rate between the Indian rupee and these currencies, primarily the U.S. dollar, has fluctuated in the past and any appreciation or depreciation of the Indian rupee against these currencies can impact our profitability and results of operations. Our results of operations have been impacted by such fluctuations in the past and may be impacted by such fluctuations in the future. For example, the Indian rupee had depreciated against the U.S. dollar in four of the last five years, which may impact our results of operations in future periods. Such depreciation impacts the value of your investment. Furthermore, we have borrowings denominated in U.S. dollars and, as such, an annual decline in the Indian rupee against the U.S. dollar effectively adds to the functional interest rate of our borrowings and the INR equivalent needed to repay the borrowings, when they fall due. Any amounts we spend in order to hedge the risks to our business due to fluctuations in currencies may not adequately hedge against any losses we incur due to such fluctuations. Further, depreciation of the Indian rupee to the U.S. dollar, could result an increase in foreign currency related transaction and translation losses.
Tech & Innovation
Total Risks: 4/69 (6%)Below Sector Average
Innovation / R&D2 | 2.9%
Innovation / R&D - Risk 1
We face uncertainties in our ability to acquire the rights to develop and generate power from new solar projects due to highly competitive PPA auctions and possible changes in the auction process.
We acquire the rights to develop and generate power from new projects through a competitive bidding process, in which we compete for project awards based on, among other things, pricing, technical and engineering expertise, financial conditions, including specified minimum net worth criteria, availability of land, financing capabilities and track record. The bidding and selection processes are also affected by a number of factors, including factors which may be beyond our control, such as market conditions or government incentive programs. If we misjudge our competitiveness when submitting our bids or if we fail to lower our costs to submit competitive bids, we may not acquire the rights on new solar projects. Furthermore, we have expected prices for system components to decline as part of our bidding process, and if that does not occur, our project economics may be harmed, and we may not remain economically viable.
In addition, rules of the auction process may change. Each state in India has its own regulatory framework and several states have their own renewable energy policy. The rules governing the various regional power markets may change from time to time, in some cases, in a way that is contrary to our interests and adverse to our financial returns. For example, most national auctions currently use the reverse auction structure, in which several winners take part in the same project. There can be no assurance that the central and state governments will continue to allow us to utilize such bidding structures and any shift away from the current structures, such as to a Dutch auction, could increase the competition and adversely affect our business, results of operations and cash flows.
For information on the risk of not executing PPAs in respect of our 4GW manufacturing linked tender, see "We may not be able to sign PPAs in respect of the 4 GWs manufacturing linked tender for which a letter of award has been received."
Innovation / R&D - Risk 2
Changed
Renewable energy project development is challenging, and our growth strategy may ultimately not be successful, which can have a material adverse effect on our business, financial condition, results of operations and cash flows.
The development and construction of renewable energy projects involve numerous risks and uncertainties and require extensive research, planning and due diligence. As a result, we may be required to incur significant capital expenditures for land and interconnection rights, regulatory approvals, preliminary engineering, permits, and legal and other expenses before we can determine whether a renewable energy project is economically, technologically, or otherwise feasible. The projects which are now awarded may not be viable in the future.
We may expand our business significantly with several new projects in both new and existing jurisdictions in the future. As we adopt new projects, we expect to encounter additional challenges to our internal processes, external construction management, capital commitment process, project funding infrastructure, financing capabilities and regulatory approvals and compliance. Our existing operations, personnel, systems, and internal controls may not be adequate to support our growth and expansion and may require us to make additional unanticipated investments in our infrastructure. To manage the future growth of our operations, we will be required to improve our administrative, operational, and financial systems, procedures, and controls, and maintain, expand, train, and manage our growing employee base. We will need to hire and train project development personnel to expand and manage our project development efforts. If we are unable to manage our growth effectively, we may not be able to take advantage of market opportunities, execute our business strategies successfully or respond to competitive pressures. As a result, our business, prospects, financial condition, results of operations and cash flows could be materially and adversely affected.
Success in executing our growth strategy is contingent upon, among others:
- accurately prioritizing geographic markets for entry, including estimates on addressable market demand; - managing local operations, capital investment or components sourcing in compliance with regulatory requirements; - negotiating favorable payment terms with suppliers; - collecting economic incentives as expected, and - signing PPAs or other arrangements that are commercially acceptable, including adequate financing.
Cyber Security1 | 1.4%
Cyber Security - Risk 1
Weaknesses, disruptions, failures of cyber security events in our IT systems could adversely impact our business.
We rely on IT systems in connection with financial controls, risk management and transaction processing. We may be subject to disruptions of our IT systems, arising from events that are wholly or partially beyond our control (for example, damage or incapacitation by human error, natural disasters, electrical or telecommunication outages, sabotage, computer viruses, or loss of support services from third parties such as internet backbone providers). We may also be subject to attempted hacking or phishing incidents. In the past five fiscal years, we have not had incidents of system failures, cyber-attacks and frauds, hacking, phishing, trojans and theft of data with a material adverse effect on our business, results of operations or financial condition. In the event we experience systems interruptions, errors, downtime, incidents of hacking, phishing, or breaches of our data security systems, this may give rise to deterioration in customer service and loss or liability to us and it may materially and adversely affect our reputation, business, results of operations and financial condition.
Further, we are dependent on various external vendors for certain elements of our operations and are exposed to the risk that external vendors or service providers may be unable to fulfil their contractual obligations to us (or will be subject to the same risk of operational errors by their respective employees) and the risk that their (or their vendors) business continuity and data security systems prove to be inadequate. If our external vendors or service providers fail to perform any of these functions, it could materially and adversely affect our business and results of operations.
We rely on the security of such platforms for the secure processing, storage and transmission of confidential information. Examples of significant cyber security events are unauthorized access, computer viruses, deceptive communications (phishing), ransom ware, malware or other malicious code or cyber-attack, catastrophic events, system failures and disruptions and other events that could have security consequences (each, a "Cyber Security Event"). A Cyber Security Event could materially impact our ability to adequately manage and value our loan portfolio, provide efficient and secure services to our customers, and regulators, and to timely and accurately report our financial results. Although we have implemented controls and have taken protective measures to reduce the risk of Cyber Security Events, we cannot reasonably anticipate or prevent rapidly evolving types of cyber-attacks and such measures may be insufficient to prevent a Cyber Security Event. Cyber Security Events could expose us to a risk of loss or misuse of our information, litigation, reputational damage, violations of applicable privacy and other laws, fines, penalties or losses that are either not insured against or not fully covered by insurance maintained. We may be required to expend significant additional resources to modify our protective measures or to investigate and remediate vulnerabilities. Further, in response to COVID-19, we had to modify our business practices with several of employees of the Company work remotely from their homes. Moreover, technology in employees' homes may not be as robust as in our offices and could cause additional operational risk, especially including increased cybersecurity risk. For a full discussion of the risks to our business associated with the COVID-19 pandemic, see "Risks to our Business related to the COVID-19 pandemic".
Technology1 | 1.4%
Technology - Risk 1
The extent and reliability of Indian infrastructure could significantly harm our results of operations, cash flows and financial conditions.
India's physical infrastructure is less developed than that of many developed nations. Any congestion or disruption with respect to communication systems or any public facility, including transportation infrastructure, could disrupt our normal business activity. Any deterioration of India's physical infrastructure would harm the national economy, disrupt the transportation of people, goods and supplies, and add costs to doing business in India. These disruptions could interrupt our business operations and significantly harm our results of operations, cash flows and financial condition. For the risk of congestion or disruption with respect to India's electricity grid and transmission lines, see "- Risks Relating to Us and Our Industry - Any constraints in the availability of the electricity grid, including our inability to obtain access to transmission lines in a timely and cost-efficient manner, could adversely affect our business, results of operations and cash flows." Further, on account of COVID-19, a number of Government and state government offices have not been operating at full capacity. Due to the COVID-19 crisis, there also may be a delay in the receipt of cash from the Government or state governments, which could potentially impact our operations and cash flows. Although, we have been successful in collecting a large part of our receivables so far, there can be no assurance that we will continue to successfully collect the receivables in the future. For a full discussion of the risks to our business associated with the COVID-19 pandemic, see "Risks to our Business related to the COVID-19 pandemic".
Ability to Sell
Total Risks: 2/69 (3%)Below Sector Average
Competition1 | 1.4%
Competition - Risk 1
We face significant competition from traditional and renewable energy companies.
We face significant competition in the markets in which we operate. Our primary competitors are local and international developers and operators of solar projects and other renewable energy sources. We also compete with utilities generating power from conventional fossil fuels. Recent deregulation of the Indian power sector and increased private sector investment have intensified the competition we face. The Electricity Act, 2003, or the Electricity Act, removed certain licensing requirements for power generation companies, provided for open access to transmission and distribution networks and also facilitated additional capacity through captive power projects. These reforms provide opportunities for increased private sector participation in power generation. Specifically, the open access reform enables private power generators to sell power directly to distribution companies and, ultimately, to the end consumers, enhancing the financial viability of private investment in power generation. Competitive bidding for power procurement further increases competition among power generators and there have been bids that were less than INR 2.00 per kWh, almost 20% lower than our lowest PPA. Furthermore, given the decline in electricity demand in India including due to COVID-19, there could potentially be surplus power capacity. We cannot assure you that we will be able to compete effectively, and our failure to do so could result in an adverse effect on our business, results of operations and cash flows.
Furthermore, our competitors may have greater operational, financial, technical, management or other resources than we do and may be able to achieve better economies of scale and lower cost of capital, allowing them to bid in the same auction at more competitive rates. Our competitors may also have a more effective or established localized business presence or a greater willingness or ability to operate with little or no operating margins for sustained periods of time. Our market position depends on our financing, development and operation capabilities, reputation and track record. Any increase in competition during the bidding process or reduction in our competitive capabilities could have a significant adverse impact on our market share and on the margins, we generate from our projects.
Our competitors may also enter into strategic alliances or form affiliates with other competitors to our detriment. As our competitors grow in scale, they may establish in-house engineering, procurement and construction ("EPC"), and O&M capabilities, which may offset a current advantage we may have over them. Moreover, suppliers or contractors may merge with our competitors which may limit our choices of suppliers or contractors and hence the flexibility of our overall project execution capabilities. For example, some of our competitors may have their own internal solar panel manufacturing capabilities. As the renewable energy industry grows and evolves, we may also face new competitors who are not currently in the market. There can be no assurance that our current or potential competitors will not win bids for projects or offer services comparable or superior to those that we offer at the same or lower prices or adapt to market demand more quickly than we do. Increased competition may result in price reductions, reduced profit margins and loss of market share.
In addition, we face competition from developers of other renewable energy facilities, including biomass and nuclear , as well as other forms of renewable electricity generation. Competition from such producers may increase if the technology used to generate electricity from these other renewable energy sources becomes more sophisticated, or if the Indian government elects to further strengthen its support of such renewable energy sources. As we also compete with utilities generating power from conventional fossil fuels, a reduction in the price of coal or diesel would make the development of solar energy less economically attractive and we would be at a competitive disadvantage. Hence, we cannot guarantee that some of our competitors do not or will not have advantages over us in terms of larger size, internal access to solar panels and greater operational, financial, technical, management, lower cost of capital or other resources. For example, French state-controlled energy group, Electricité de France (EDF) has made a binding offer to build six third-generation European Pressurised Reactor (EPR) nuclear reactors at Jaitapur in Maharashtra, which will be "world's most powerful" nuclear plant in India. On April 22, 2021, EDF submitted to the Nuclear Power Corporation of India (NPCIL), the offer to supply engineering studies and equipment for the construction of six, third-generation EPR reactors at the Jaitapur in Maharashtra. The project once completed will produce 10 gigawatts (GW) of electricity enough to power 70 million Indian households. Considering, the Indian Government's commitment to grow India's nuclear power capacity as part of its infrastructure development programme a shift of focus to other sources of renewable energy in future years may adversely impact our ability to achieve our intended business objectives.
Demand1 | 1.4%
Demand - Risk 1
There are a limited number of strong credit purchasers of utility scale quantities of electricity which exposes us, and our utility scale projects to risk.
In fiscal year 2020 and 2021, we derived 72.2% and 71.5%, respectively, of our revenue from our top five customers. Since the transmission and distribution of electricity are either monopolized or highly concentrated in most jurisdictions, there are a limited number of possible purchasers for utility scale quantities of electricity in a given geographic location, including transmission grid operators and central and state-run utilities. For instance, for projects established pursuant to the NSM, solar project developers are required to enter into PPAs with specified implementation agencies/DISCOMs. As a result, there is a concentrated pool of potential buyers for electricity generated by our plants and projects, which may restrict our ability to negotiate favorable terms under new PPAs and could impact our ability to find new customers for the electricity generated by our generation facilities should this become necessary.
Furthermore, if the financial condition of these utilities and/or power purchasers deteriorate or the NSM or other solar policy to which they are currently subject and that compel them to source renewable energy supplies change, demand for electricity produced by our plants could be negatively impacted.
See a full breakdown of risk according to category and subcategory. The list starts with the category with the most risk. Click on subcategories to read relevant extracts from the most recent report.
FAQ
What are “Risk Factors”?
Risk factors are any situations or occurrences that could make investing in a company risky.
The Securities and Exchange Commission (SEC) requires that publicly traded companies disclose their most significant risk factors. This is so that potential investors can consider any risks before they make an investment.
They also offer companies protection, as a company can use risk factors as liability protection. This could happen if a company underperforms and investors take legal action as a result.
It is worth noting that smaller companies, that is those with a public float of under $75 million on the last business day, do not have to include risk factors in their 10-K and 10-Q forms, although some may choose to do so.
How do companies disclose their risk factors?
Publicly traded companies initially disclose their risk factors to the SEC through their S-1 filings as part of the IPO process.
Additionally, companies must provide a complete list of risk factors in their Annual Reports (Form 10-K) or (Form 20-F) for “foreign private issuers”.
Quarterly Reports also include a section on risk factors (Form 10-Q) where companies are only required to update any changes since the previous report.
According to the SEC, risk factors should be reported concisely, logically and in “plain English” so investors can understand them.
How can I use TipRanks risk factors in my stock research?
Use the Risk Factors tab to get data about the risk factors of any company in which you are considering investing.
You can easily see the most significant risks a company is facing. Additionally, you can find out which risk factors a company has added, removed or adjusted since its previous disclosure. You can also see how a company’s risk factors compare to others in its sector.
Without reading company reports or participating in conference calls, you would most likely not have access to this sort of information, which is usually not included in press releases or other public announcements.
A simplified analysis of risk factors is unique to TipRanks.
What are all the risk factor categories?
TipRanks has identified 6 major categories of risk factors and a number of subcategories for each. You can see how these categories are broken down in the list below.
1. Financial & Corporate
Accounting & Financial Operations - risks related to accounting loss, value of intangible assets, financial statements, value of intangible assets, financial reporting, estimates, guidance, company profitability, dividends, fluctuating results.
Share Price & Shareholder Rights – risks related to things that impact share prices and the rights of shareholders, including analyst ratings, major shareholder activity, trade volatility, liquidity of shares, anti-takeover provisions, international listing, dual listing.
Debt & Financing – risks related to debt, funding, financing and interest rates, financial investments.
Corporate Activity and Growth – risks related to restructuring, M&As, joint ventures, execution of corporate strategy, strategic alliances.
2. Legal & Regulatory
Litigation and Legal Liabilities – risks related to litigation/ lawsuits against the company.
Regulation – risks related to compliance, GDPR, and new legislation.
Environmental / Social – risks related to environmental regulation and to data privacy.
Taxation & Government Incentives – risks related to taxation and changes in government incentives.
3. Production
Costs – risks related to costs of production including commodity prices, future contracts, inventory.
Supply Chain – risks related to the company’s suppliers.
Manufacturing – risks related to the company’s manufacturing process including product quality and product recalls.
Human Capital – risks related to recruitment, training and retention of key employees, employee relationships & unions labor disputes, pension, and post retirement benefits, medical, health and welfare benefits, employee misconduct, employee litigation.
4. Technology & Innovation
Innovation / R&D – risks related to innovation and new product development.
Technology – risks related to the company’s reliance on technology.
Cyber Security – risks related to securing the company’s digital assets and from cyber attacks.
Trade Secrets & Patents – risks related to the company’s ability to protect its intellectual property and to infringement claims against the company as well as piracy and unlicensed copying.
5. Ability to Sell
Demand – risks related to the demand of the company’s goods and services including seasonality, reliance on key customers.
Competition – risks related to the company’s competition including substitutes.
Sales & Marketing – risks related to sales, marketing, and distribution channels, pricing, and market penetration.
Brand & Reputation – risks related to the company’s brand and reputation.
6. Macro & Political
Economy & Political Environment – risks related to changes in economic and political conditions.
Natural and Human Disruptions – risks related to catastrophes, floods, storms, terror, earthquakes, coronavirus pandemic/COVID-19.
International Operations – risks related to the global nature of the company.
Capital Markets – risks related to exchange rates and trade, cryptocurrency.